91-007 Sidewalk Grinding Proj. 91-106 91-007 SIDEWALK GRINDING 1 of 2
PROD. 91-106
Cit,4 of Cuperti"o
10300 Torre Avenue P.O. Box 580
Cupertino.California 95014 Cupertino,California 95015
Telephone* (408) 252-4505
M11 h 8, 1991
P & F Construction
1010 39th Avenue
Oakland, CA 94601
CONTRACT FOR P[JUIC WORIZ - SIDEStiALK GRINDING, PROJECT 91-106
We are enclosing to you for your files one (1) copy of the Contract. for
Public Works by and between the City of Cupertino and P & F Construction
which has been fully executed by City Officials.
Enclosed please find your bid bond.
Sincerely, y
DOFDM CORNELIUS
CITY CM ERK
CITY OF CUPERTINO
DC/so
encl.
s
CONRAC.r FCt PUBIZC WORKS
C70NTR ►Cr made on February 19, 1991 by the CITY OF CUPERrM, a municil al
corporation of the State of California, hereinafter called the CITY, and
P & F ON, INC., hereinafter called the CWMCMR.
IT IS FMM ACC by the parties as follows:
1. = CQN RAcr DocamE 'S. The ccuplete contract consists of the
following contract docents:
A. Plans and Specifications for SIDEMUZ GRINDING, PRO= 91-106
B. Faithful Performance Bond, Labor and Materials Bond, Insurance
Certificate
C. This Contract
D. Bid Proposal referred to as Edxibit A
Any and all obligations of the CrrY and the 00NrRACMR are fully set
forth and described herein.
All of the above docents are intended to cooperate so that any work
called for in one and not mentioned in the other, or vice versa, is to be
executed the same as if mentioned in all of said docents. The documents
comprising the complete contract are sometimes hereinafter referred to as
the Contract Documents. In case of conflict between the Plans and the
Specifications on the one hand, and this Contract on tree other, the Plans
and Specifications shall prevail.
2. Tim WORK. The Contractor agrees to furnish all of the tools,
equipment, apparatus, facilities, labor, transprjrtation, and material
necessary to perform and couplets in a good and workmanlike. meaner, the
work of SIDOQM GRINDING as called for, and in the manger designated in,
and in strict conformity with, the Plans and Specifications prepared by:
Mr. Bert J. Vi.skovich, Director of Public Works and adopted by the City,
which Plans and Specifications are entitled, respectively, SID34TALK
GRIND=, Project 91-106 and which Plans and Specifications are identified
by the signatures of the parties to this fact.
Z
• It is understood and agreed that said tools, Wit, apparatus,
facilities, labor, transportation, and material shall be furnished, and
that said work shall be performed and aoopleted as required in said Plans
and Specifications under the sole direction of the Contractor, but subject
to the iv Lion and approval of the City, or its representative. The
City hereby designates as its representative for the purpose of this
Contract: Mr. Bert J. Viskovich, Director of Public Works.
kt
w 3. CCT PRICE. The City agrees to Pay, and the Contractor agrees
to accept, in full payment for the work above agreed to be done, the sum
of: FUM FIVE 1TKX)SAND, SLVF3M TME DOLLARS AND No f 100 ($45,073.00)
subject to additions and deductions as provided in the Contract Documents,
per Ekhibit "A" attached hereto.
4. DISp4JTF5 PFRAINII"AG To PAYmEn Fm wom. Should any dispute arise
respecting the true value of the work done, or any work omitted, or of any
extra work which the Omrticactor may be required to do, or respecting the
size of any payment to the Contractor during the performance of this
Contract, said dispute shall be determined either by reference to the unit
of prices, if applicable, or in accordance with the agreement of prices,
if applicable, or in accordance with the agreement of the parties, or in
accordance with the rules of the American Arbitration Association if the
parties are unable to agree.
5. PML►.IS, OMTLTANCE WIZH 1M. The Contractor shall, at his expense,
obtain all necessary pexmits and licenses, easements, etc., for the
construction of the project, give all necessary notices, pay all fees
recriireci by law, and oanply with all laws, oa^bnances, rules and
regulations relating to tha work and to the preservation of the public
health and safety.
6. INSPECTION By THE CTTY. The Contractor shall at all times maintain
proper facilities and provide safe access for inspection by the City to
all parts of the work, and to the shops wherein the work is in
preparation. where the Specifications require work to be specially tested
or approved, it shall not be tested or covered up without timely notice to
the City of its readiness for inspection and without the approval thereof
cr consent thereto by the latter. Should any such work be covered up
without such notice, approval, or consent, it must, if required by the
City, be uncovered for examination at the Contractor's expense.
7. EffM OR ADDITIONAL WORK AND Qom. Should the City at any time
during the progress of the work require any alterations, deviations,
additions or cmissions from the Specifications or Plans or the Contract
Documents, it shall have the right to do so, and the same shall in no way
affect cr make void the contract, but the cost or value thereof will be
added to, or deducted fx , the amount of the contract price, as the case
may be, by a fair and ale valuation, which valuation shall be
determined) either by reference to the unit prices, if applicable, or in
aa-r+darce with the aft of the parties, or in accordance with the
rules of the American Arbitration Association if the parties are unable to
agree. No extra work shall be performed or change be made e=ept by a
written order from the City, duly authorized by resolution of its
governing body, and by all agencies whose approval is required by law,
stating that the extra work or change is authorized, and no claim for an
addition to the contract sum shall be valid unless so ordered.
2
g. CHANGES TO MEEr ENVIMNMERIAL REQUEREMENTS. fine Ci t%- shall have the
right to make changes in this contract during the course of cionstruction
to bring the ccupleted iu roveme tts into comp]ianoe with enviLomerrtal
requiremm-tts or standards established by State and Feral statutes and
regulations after the Contract has been awarded or entered into. The
Contractor shall be paid for by :'uth charges either by refere m to the
unit prices, if applicable, or in ac=rdance Ath the agreement of the
parties, or in accordance with the rules of the American Arbitration
Association if the parties are unable to agree.
9. MMON, AMENEMEWS or MMIF ICATIC NS. This Contract may be
terminated, amended or modified, with the manual consent of the parties.
The coapensation payable, if any, for such termination, went or
modifications, shall be determined either by reference to the unit price,
if applicable, or in accordance with the agreement of the parties, or in
accordance with the rules of the American Arbitration Association if the
parties are unable to agree.
10. TIM FOR COMPLEMON. All work under this Contract shall be
ccupleted: 45 WOR UM SAYS
If the contractor shall be delayed in the work by the acts or neglect of
the City, or its erployees, or those under it by contract or otherwise, or
by changes ordered in the work, or by strikes, lockouts by others, fire,
unusual delay in transportation, unavoidable casualties or any causes
beyond the contractor's control, or by delay authorized by the City, or by
any cause which the City shall determine justifies the delay, then the
time of oompletion shall be extPitled aceorrlirgly.
This paragraph does not exclude the recovery of damages for delay by
either party under other provisions in the Contract Documents.
11. INSPBMCN AND TE9rING OF MAT UALS. The Contractor shall notify
the City a sufficient time in advance of the manufacture or production of
materials to be supplied by him under this Contract, in order that the
City may arrange for mill or factory inspection and testing of the same,
if the City requests such notice from the Contractor.
12. , MIAT10N FOR S WxH, Ex. If the contractor should be adjudged a
bankrupt, or if he should make a general assignment for the benefit of his
creditors, or if a receiver should be appointed on account of his
insolvency, or if he or any of his subcontractors should violate any of
the provisiosis of the Contract, the City may serve written notice upon him
and his surety of its intention to terminate the contract, such notice to
tr contain e reasons for such intention to terminate the Contract, and
unless within ten days after serving of such notice, such vi:,Nlation shall
ease and satisfactory arran3ements for corrections thereof be made, the
Contract shall, upon the expiration of said ten days, ease and
terminate. In the event of any such termination, the City shall
; ;�tely serve written notice thereof upon the surety and the
Contractor, and the surety shall have the right to take over and perform
the Contract; provided, ha ever, that, if the surety within fifteen days
after the serving upon it of notice of termination does not give the City
written notice of its intention to take over and perform the contract, or
dyes not oommence performarx-e thereof within thirty days from the date of
3
the serving of such notice, the City may take over the work and pate
the same to omgDletion by contract, or by any other snet2sod it may deem
advisable, for the ao=ust and at the expertise of the Contractor, and the
contractor and his surety shall be liable to the City for any excess cost
occasioned by the City thereby, and in such event the City may, without
liability for so doing, take possession of, and utilize in completing the
work, such materials, appliances, plant and other property belonging to
the Contractor as may be on the site of the work and rrexmsary therefor.
13. THE C3TY'S RICM TO WITIIOM C MAIN AMDLNM AM MAKE APPLICATIM
THEPMF. In addition to the anauut which the City may retain under
Paragraph 21 of this contract until the final completion and acceptance of
all work covered by the Contract, the City may withhold from payment to
the Contractor such an amount or amounts as in its jitkynent may be
r4cessary to pay just claims against the Contractor or any subcontractors
for labor and service rendered and materials furnished in and about the
work. The City may apply such withheld amount or amounts to the payment
of such claims in its discretion. In so doing, the City shall be deemed
the agent of the om-ttractror, and any payment so made key the City shall be
considered as a payment made under the Contract by the City to the
Contractor, and the City shall not be liable to the Contractor for any
such n+.. ment, made in good faith. such payment: may be made without prior
jucli.c.iai determination of the claim or claims. With reap2at to any
retention of payment by the City to erasure performarx a of the Ca*stract,
Contractor will be entitled to substitute securitie3 as provided in
Section 4590 of the California CuvPxnmuent Code as more i°ully described in
the City's Nctice to Contractors.
14. NOTICE AND SEm(m T*MRB0F. Any notice from one party to the other
under this Contract shall be in writing, and shall be dated and signed
either by the party giving such notice, car by a duly authorized
representative of such party. Ar:y such notice shall not be effective fcr
any purpose whatsoever unless served in the following manner: (a) if the
notice is given to the City either by personal delivery thereof to the
City Manager of the City, or by depositing the same in the United States
mails, enclosed in a sealed em-elope, addressed to the City, postage
prepaid and certified; (b) if the notice is given to the Contractor,
either by personal delivery thereof to the Contractor, or to his duly
authorized representative at the site of the project, or by depositing the
same in the United States mails, enclosed in a sealed envelope, addressed
to said Contractor at: 1010 39TH AVENUE, oAKLAND, CA 94601 stage
prepaid and certified; and (c) if the notice is given to the surety or any
other person, either by personal delivery to such sty or other person,
or by depositing the same in the United States mails, enclosed in a sealed
envelope, addraessed to such surety or Person, as the case may be, at the
address of such surety or persons last c crazzaeated bry him to the party
giving the notice:, postage prepaid and certified.
15. ASSICNmm of CIDPNI'RACT. Neither the Contract, nor any part thereof,
nor moneys duce or to beoom due tom, may be assigned by the
Contractor without the prior written approval of the City.
4
16. COMPLIANCE WITH SPB=CATICNS OF MATERIALS. Whenever in the
specifications, arry material or process is indicated or specified by
patent or proprietary nauaa, or by name of manufacturer, such
Specifications must be mac by Contractor, unless the City rgrees in
writing to same other material, process or article offered by Contractor
which is equal in all respects to the one specified.
17. cOelma T SEcURMY. The Contractor shall furnish a surety band in an
amount at least equal to one hundred percent (100%) of the contract price
as security for t a faithful performarjoe of this Contract. The
Cont:cactor shall also furnisa a separate surety band in an amount at least
equal to one hundred percent (100%) of the contract price as security for
the payment of all persons for furnishing materials, provisions,
provender, or other supplies, used in, upon, for or about the performance
of the work contracted to be done, or for performing any work or labor
thereon of any kind, and for the payment of amounts due under the
unemployment Insurance Code with respect to such work or labor in
connection with this Contract, and for the payment of a reasonable
attorney s fee to be f ixed by the court in case suit is brought upon the
band.
18. INSURANCE. The Contractor shall not commence work under this
Contract until he has obtained all insurance required by the City. nor
shall th; Contract= allow ar_y subcontractor to comence work on his
subcontract witil all similar insurance required of the subcontractor has
been so obtained and approved. The Contractor shall furnish the City with
satisfactory proof of the carriage of insurance required, and there shall.
be a specific contractual liability endorsm&nt extending the Contractor's
coverage to include the contractual liability assumed by the Contractor
pursuant, to this Contract and particularly Paragraph 19 hereof. Any
policy of insurance requited of the Contractor under this contract shall
also contain an endorsement providing that thirty (30) days' notice must
be given in writing to the City of any pending change in the limits of
liability or of any cancellation or modification of the policy.
(a) WORKER'S C OMENSATIC N INSURANCE AND EMPICYER I S LIABILITY
INSURANCE. The Contractor shall take out and maintain during the, life
of this contract Worker's Cation Insurance and Employer's
Liability Insurance for all of his empiloyees employee at the site of
the project and, in rase any work is sublet, the Contractor shall
require the pub=tractor similarly to provide Worker's Cmqensation
Insurance and Employer's Liability Insurance for all of the lather's
emp .oyees unless such employees are covered by the protection afforded
lay the Contractor.
In signing , this contract the Contractor makes the following
cmrtification, required by Section 1861 of the Labor code:
"I am aware of the provisions of Section 3700 of the Labor Code which
require every employer to be insured against liability for worker's
compensation or to undertake self insurance in accordance with the
provisions of the Code, and I will comply with such provisions before
commencing the performance of the work of this contract".
5
(b) LLWZ ZTY DvbMNM. The Contract r shall take out and maintain
during the life of this Contract such Bodily Injury Liability and
Property Damage Liability Insurance as shall protect him and any
performing work covered by this Om tract from claims for
t , including party y , to include
coverage on popery in the care, custody and con of the
C mytraotor, and also excluding what are commonly known as the "X, C,
and LP' elusions (having to do with blasting, collapse, and
underground property fie), which may arise from Contractor's
operations under this Contract, whether such operations be by himself
or by any subcontractor or by anyone directly or indirectly employed
by either of then and the amounts of such insurance shall be ads
follows:
Bodily Injury Liability Insurance in an amount not less than
$500,000.00 for injuries, including accidental death, to arry one
person, and subject to the same limit for e�d,,, person, in an amount
not less than $1,000,000.00 on account of ov:t accident, and Property
Damage Liability Ins in an am=,vt not less than $250,000.00.
The City and its officers and employees shall be named as additional
irLsur,eds on any such policies of ins , which shall also contain a
provision that the im—wane afforded thereby to the City, its
officers and employees, shall be primary insurance to the full limits
of liability of the policy and that if the City, or its officers and
employees, have other ins=anee against a loss coverers by such policy,
such other insurance shall be excess insurance only.
19. HOD HAMLESS. The. Contractor will save, keep, and hold harmless
the City and all officers, employees, and agents thereof from all damages,
costs, or expenses, in law or in equity, that may at any time arise or be
set up because of personal injury or damage to property sustained by any
person or persons by reason of, or in the course of the performance of
said work, or by reason of any infringement or alleged infringement of the
patent rights of any person or persons, firm or corporation in consequence
of the use in, on, or about said work, of any article or material supplied
or installed under this Contract. Notwithstanding the above, the
Contractor shall wherever it is necessary keep and maintain at his sole
cost and expense during the course of his operations under this Contract
such warnings, signs, and barriers as may be required to protect the
public. The provisions of the preceding sentence shall not inpose any
liability upon the City and are for the express benefit of the general
public.
20. HOURS OF 6IOW. Eight hours of labor during any one calendar day and
forty hours of '.abor during any one calendar week shall constitute the
maximum hauxs of service upon all work done hereunder, and it is expressly
stipulated that .no laborer, workman, or mechanic employed at any time by
the Mntractor or by any suboontractm or suboontractors under this
Contract, upon the work or upon any part of the work dated by this
Contract, shall be required or permitted to work them more than eight
hours during any one calendar day and forty hours during any one calendar
week, except, as provided by Section 1815 of the Labor Code of the State
of California, work performed by employees of Contractors in esooess of
eight hours per day and forty hours during any ors week shall be p=armitted
upon public work upon compensation for all hours worked in excess of eight
6
A
hairs per day at riot less than one and one-half times the basic rate of
pay. It is further expressly stipulated that Ior each and every violaticn
of Sections 1811-1815, inclusive, of the Laboa` Code of the State of
California, all the provisions whereof are dew to be inoorporated
herein, the Contractor shall forfeit, as a penalty to the City,
twenty-five dollars ($25.00) for each laborer, worker, or mechanic
employed in the execution of this Contract by Contractor, or by any
subcontractor under this Contract, for each calendar day during which said
laborer, worker, or mechanic is required Or permitted to work more than
eight hours in any one calendar day and forty hours in any one calendar
week in violation of the vrovisions of said sections of the Labor Cate.
The Contractor, and each subcontractor, shall keep an accurate recor3
showing the names of and actual hours worked each calendar day and each
calendar week by all laborarrs, workmen, and m..'zanics employed by him in
connection with the work contemplated by this Contract, which record shall
be open at all reasonable hours lot the inspection of the City of its
officers or agents and to the Division of Labor Law Enforcement of the
Department of Industrial Relations of the State of California.
21. WAGE RATES. Pursuant to the Lair Code Of the State Of California,
or local law thereto applicable, the City has ascertained the general
prevailing rate of per diets wages and rates for holidays and overtime in
the locality in which this work is to be performed, for each craft,
classification, or type of labozer, workman, or mechanic needed to execute
this Contract. The prevailirr; wages so determined are set forth in the
Specifications and made a pent hereof. Neither the notice inviting bids
nor this Contract shall conc-titute a representation of fact as to the
prevailing wage rates upon which the Contractor or any subcontractor under
him may base any claim against the City.
1776. (a) Each Contractor and suboontractor shall keep an accurate
payroll record, showring the name, address, social security number, work
classification, straight time arxi overtime hours worked each day and week,
and the actual per diem wages paid to each journeyman, apprentice, worker,
or other employee employed by him or her connection with the public work.
(b) The payroll records enumerated under subdivision (a) shall be
certified and shall be available for inspection at all reasonable hours at
the principal office of the Contractor on the following basis:
(1) A certified copy of an euployrae°s payroll record shall be made
available for inspection or furnished to such employee or his or her
authorized xnesentative on request.
(2) A certified copy of all payroll records enumerated in subdivision
(a) shall be made available for inspection or furnished upon request
to a representative of the batty awarding the contract, the Division of
Labor standards atforcanent and the Divis:;cm of Apprenticeship
Standards of the Department of Industrial Relations.
(3) A certified copy of all payroll records enumerated in subdivision
(a) shall be made available upon request to the public for inspection
or copies thereof made, provided, however, that a request by the
public shall be made through either the body awarding the contract,
the Division of Apprenticeship Standards, or the Division of Labor
7
Standards tine public shall not be given access to such
re= at the principal offlue of the Contractor.
(c) &ci Contractor shall file a certified copy of the records
ernzaerated in subdivision (a) with the entity that requested such records
within ten (10) days after receipt of a written request.
(d) Any copy of reocr ; umde available for inspection as copies and
furnished upon request to the )public or any public agency by the awarding
bids, the Division of Apprenticeship Standards or the Division of Labor
Standards E ffe tt sh- ll be marked Lr obliterated in such a manner as
to prevent disclosure of an individual°s name, address and social security
numbed. 7he name and adds of the Contractor awarded the contract or
performing the contract shall not be marked or obliterated.
(e) The Contractor shall inform the body awarding the eont-ract of the
location of the records enumerated under subdivision (a), including the
street address, city and county and shall, within five working days,
provide a notice of a change of location and address.
(f) In the event of noncompliance with the requirements of this section,
the Wntractor shall havo ten (10) days in which to comply subsequent to
receipt of written notice specifying in what respects such Contractor must
fly with this section.. Should noncompliance still be evident after
such ten (10) day period, the Contracto& shall, as a penalty to the state
of political subdivision on whose behalf the contract is made or awarded,
forfeit twenty-five dollars ($25.00) for each calendar day or portion
thereof, for each worker, until strict cnlrr�plianee is effectuated. Upon
the request of the Division of Apprenticeship Standards or the Division of
Labor Standards Miforcement, such penalties shall be withheld from
progress payments then due-
(g) The body awarding the contract shall cause to be inserted in the
contract stipulations to effectuate this section. Such stipulations shall
fix the responsibility for compliance with this section on the prime
Contractor.
(h) The director shall adopt rules consistent with the ,:alifornia Public
Records Act, (Ch. 3.5 (camrencing with Section 6250) of Div. 7, Title
1. Gov. Ch.) and the Information Practices Act of 1977, (Title 1.8
(commencing with Sec. 1798) Pt. 4, Div. 3, Civ. C.) governing the release
of such records, including the establishment of reasonable fees to be
charged to reproducing copies of records required by this section. (Added
by Stats. 1978, Ch. 1249) .
1775.5 Nothing in this chapter shall prevent the employment of properly
registered apprentices upon public work.
Every such apprentice shall be paid the standard wage paid to apprentices
under the regulations of the craft or trade at which he is employed, and
shall be employed only at 'the work of the craft or trade to which he is
registered.
8
Only apprentices, as defined in Section 3077, who are in training under
apprenticeship standards and written apprentice agents under Chapter 4
(commencing with Section 3070) , Division 3, of the Labor Code, are
eligible to be employed on public works. Mie employment and training of
each apprentice shall be in accordance with the provisions of the
apprenticeship standards and apprentice agreements under which he is
training.
When the Contractor to whom the contract is awarded by the State or any
political subdivision, or any subcontractor under him, in performing any
of the work under the contract or subcontract, employs workmen in any
apprenticeable craft or trade, the Contractor and subcontractor shall
apply to the joint apprenticeship ecitnittee administering the
apprenticeship standards of the craft or trade in the area of the site or
the public work for certificate approving the Contractor or subcontractor
under the apprenticeship standards for the employment and training of
apprenticeships in the area or irktistry affected; provided, however, that
the approval as established by the joint apprenticeship committee or
committees shall be subject to the approval of the Administrator of
Apprenticeship. The joint apprenticeship or cmnittees, subsequent to
approving the subject contractor or subcontractor, shall arrange for the
dispatch of apprentices to the Contractor or subcontractor in order to
comply with tt-iis section. There shall be an affirmative duty upon the
joint appreentir-u2ship committee or ccmanittees iministering the
apprenticeship standards of the craft or trade in the area of the site of
the public work to ensure equal employment and affirmative action in
apprenticeship for women and minorities. Contractors or subcontractors
shall not be rewired to submit individual applications for approval to
local joint apprenticeship committees provided they are already covered by
the local apprenticeship standards. The ratio of apprentices to
journeymen who shall be employed in the craft or trade on the public work
may be the ratio stipulated in the apprenticeship standards under which
the joint apprenticeship committee operates but in no case shall the ratio
be less than one apprentice for each five journeymen, except as otherwise
provided in this section.
The Contractor or subcontractor, if he is covered by this section, upon
the issuance of the approval certificate, or if he has been previously
approved in such craft or trade, shall employ the number of apprentices or
the ratio of apprentices to journeymen stipulated in the apprenticeship
standards. Upon proper showing by the Contractor that he employs
apprentices in such craft or trade in the state on all of this contract on
an annual average of not less than one apprentice to each five journeymen,
the Division of Apprenticeship Standards may grant a certificate exempting
the Contractor for the 1-to-5 ratio as set forth in this section. This
section shall nat. apply to contracts of general contractors involving less
than thirty thousand ($30,000.00) or twenty (20) working days or to
contracts of specialty contractors not bidding for work through a general
or prima contractor, involving less than two thousand dollars ($2,000.00)
or fewer than five (5) working days.
"App entioeablp craft or trade," as used in this section, shall mean a
craft or trade determined as an apprenticeable occupation in accordance
with rules and regulations prescribed by the Apprenticeship Council. The
joint apprenticeship om=i.ttee shall have the discretion to grant a
9
certificate, which shall be subject to the approval of the Administrator
Of Apprenticeship, exempting a contractor from the 1-to-5 ratio set forth
in this section when it finds that any one of the following canitions are
met:
(a) In the event unemployment for the previous three month period in
such area exceeds an average of 15 percent, or
(b) In the event the number of apprentices in training in such area
exceeds a ratio of 1-to-5, or.
(c) If there is a showing that the apprenticeable craft or trade is
replacing at least one-thirtieth of its journeymen annually through
apprenticeship training, either (1) on a statewide basis, or (2) on a
local basis.
(d) If assignment of an apprentice to any work performed under a public
works contract would crate a condition which would jeopardize his life or
the life, safety, or property of fellow employees of the public at large
if the specific task to which the apprentice is to be assigned is of such
a nature that training cannot be provided by a journeyman.
When such exemptions are granted to an organization which represents
Contractors in a specific trade from the 1 to 5 ratio on a local or
statewide bast: the fimrd.-er Contractors will not be required to sutmit
individual applications for approval to local joint apprexrtic whip
ccemnittees, provided they are already covered by the local apprenticeship
standards.
A contractor to whom the contract is awarded, or any subcontractor under
him, who, in performiM any of the work, under the contract, employs
journeymen or apprentices in any apprenticeable craft or trade and who is
not contributing to a fund or funds to administer and conduct the
apprenticeship program in any such craft or trade in the area of the site
of the public work, to which fund or funds other Contractors in the area
of the site of the public work are contributing, shall contribute to the
fund or funds in each craft or trade in which kee employs journeymen or
apprentices on the public work in the same amount or upon the same basis
and in the -.am manner as the other Contractors do, but where tree trust
fund administrators are unable to accept such funds, contractors not
signatory to the trust agreement shall pay a like amount to the California
Apprenticeship Council. The Contractor or subcontractor may add the
amount of such contributions In eD1puting his bid for the contract. Zhe
Division of Labor Standards Enforcement is authorized to enforce tha
payment of sucks contributions to the fund or funds as set forth in Section
227.
The body awarding the contract shall cause to be insertad in the contract
stipulations to effectuate this section. Such stipulations shall fix the
responsibility of compliance with this section for all apprenticeable
occupations with the prime contractor.
All decisions of the joint apprenticeship committee under this section
are subject to the provisions of Section 3081. (Amended by Stats, 1976,
Ch. 1179)
10
1777.6 Ze shall be unlawful ``;ar an Moyer of a labor union to refuse
to accept oUiezwise qualified employees as registered apycentiaes on any
public works, on the ground of the race, religious creed, cold, national
origin, ancestry, sex, or age, except as provided in Section 3077, of such
employee. (Amended by Stat. 1976, Ch. 1179)
1777.7 (a) In the event a Contractor willfully fails to comply with the
provisions of Section 1777.5, such Contractor shall:
(1) Be denied the right to bid on any public works contract for a
period of one year from the date the determination of non=Ppliance is
made by the Administrator of Apprenticeship; and
(2) Forfeit as a civil penalty in the sum of fifty dollars ($50,00)
for each calendar day of nonecapliance. Notwithstanding the
provisions of Section 1727, upon receipt of such a determination the
awarding body shall withhold frcan contract progress payments then due
or to become due such sum.
(b) Any such determination shall be issued after a full investigation, a
fair and impartial hearing, and reasonable notice thereof in accordance
with reasonable rules and procedures prescribed by the California
Apprenticeship Council.
(c) Any funds withheld by the awarding body Pursuit to this section
shall be deposited in the general fund if the awarding body is a state
entity, or in the equivalent fund of an awarding body if such awarding
body is an entity other than the state.
The interpretation and enforcement of Sections 1777.5 and 1777.7 shall be
in accordance with the rules and procedures of the California
Apprenticeship Council. (Amended by Stats. 1978, Ch. 1249) .
It shall be mandatory upon the Contractor, and upon any subcontractor
under him, to pay not less than the said specified rates to all laborers,
workmen, and mechanics employed in the execution of the Contract. It is
further expressly stipulated that the Contractor shall, as a penalty to
the City, forfeit twenty-five ($25.00) for each calendar day, or portion
thereof, for each laborer, workman, or mechanic paid less than the
stipulated prevailing rates for any work done under this Contract by him
or by any subcontractor under work done under this Contract by him or by
any subcontractor under him; and Contractor agrees to comply with all
provisions of Section 1775 of the Labor Code.
In case it becomes necessary for the Contractor or any subcontr iIJ—Or to
employ on the project under this contract, any person in a trade or
occupation (except executives, supervisory, administrative, clerical, or
other non-manual workers as such) for which no minimum wage rate is herein
specified, the Contractor shall immediately notify the City, who will
prwptly thereafter determine the prevailing rate for such additional
trade or occupation and shall furnish the Contractor with the min m= rate
based thereon. The minimum rate thus furnished shall be applicable as a
minimum for such trade or occupation from the time of the initial
employment of the person affected and during the continuance of such
employment.
11
22. ACC'IGENr PRLVEMION. Precaution shall be exercised at all times for
the protection of persons (including employees) and property. The safety
provisions of applicable laws, building and construction codes shall be
observed. Machinery, equipment, and other hazards shall. be guarded or
el>mu*atsd in accordance with the safety provisions of the Construction
Safety Orders issued by the Industrial Accident Cammissicn of the State of
California.
23. PAY+gI - Payment will be made in accordance with the attached
payment schedule. The City will make partial payment to the Contractor on
the basis of a duly certified approval estimate of the work performed and
materials ux=porated in the project, during the preceding calendar
month, by the Contractor, but the City will retain ten percent (10%) of
the amount of each of said estimates until the expiration of thirty-five
(35) days from the date of recording by the City of notice of acceptance
of campletion of all work covered by this Contract, if such notice be
recorded within ten days after the acceptance of completion of such
Contract as evidenced by resolution of its governing body; or, if such
notice be not so regarded within ten days, until the expiration of
ninety-five (95) days after the acceptance of completion of such work of
improvement as evidenced by resolution of its governing body, at which
time and not before, the City shall pay to the Contractor the whole of the
remaining ten percent (10%) of said contract price so held back as
provided; said certificates to be furnished by and obtauvA- from the
City's representative shall, before the last Tuesday of each month,
deliver said certificates under hand to the City, or in lieu of such
certificates, shall deliver to the Contractor, in writing, under his hand,
a just and true reason for not issuing the certificates, including a
statement of the defects, if any, to be remedied, to entitle the
Contractor to the certificate of completion. In event of the failure of
the City's representative to furnish and deliver said certificates or any
of them or in lieu thereof, the writing aforesaid, within ten (10) days
after the times aforesaid, and after written demand has been made upon him
for the same, the Contractor may file demand with the City, and, in event
said certificates are not furnished within ten (10) days thereafter, the
same shall become due and payable.
In case the City's representative delivers the writing aforesaid, in lieu
of the certificates, then a compliance by the Contractor with the
requirements of said writing shall entitle the Contractor to the
certificates.
The payment of progress payments by the City shall not be construed as an
absolute acceptance of the work done up to the time of such payments-, but
the entire work is to be subjected to the inspection and approval of the
City, and subject to whatever inspection and approval may be required by
law.
24. PROTDCI'ION OF PUBLIC UPILITIFS. The City shall be responsible as
between the parties to this Contract only, for the removal, relocation, or
protection of existing public utilities, if any, located on the site of
construction, but only if such public utilities are not identified by the
City in the Plans and Specifications made a part of the invitation for
bids. The City shall compensate the Contractor for costs incurred in
12
relocating or repairing damage to utility facilities not indicated in the
Plans and Specifications, other than service laterals when the presence of
such utilities on the construction site can be inferred from the pry
of such visible facilities as buildings, and meters and junctien boxes on,
or adjacent to, the construction site. The Contractor shall not be
assessed liquidated damages for delay in completion v the Contract
project, as provided in Paragraph 27 below, when such delay is caused by
the failure of the City, or other public utility, to provide for the
removal or relocation of the existing utility facilities. If the
Contractor while performing the Contract discovers utility facilities not
identified by the City in the Contract plans and Specifications, the
service laterals as hereinabove described, he shall imanediately notify the
City in writing.
25. CONTRACTOR'S RFSPONSIBI= FOR THE MRK. The Contractor shall not
be responsible for the cost of repairing or restoring damage to the work
caused by an Act of God. NEVEFffiMXS1.5, the Contractor shall, if the '
insurance premiums a separate bid item, obtain the insurance to indemnify
the City for any damage to the work caused by an Act of God. "Acts of
God" shall include only the following cmxurrences or conditions and
effects: earthquakes and tidal waves, when such occurrences or conditions
and effects have been proclaimed a disaster or state of emergency by the
Governor of the State of California or by the President of the United
States, or were of a magnitude at the site of the work sufficient to have
caused a proclamation of disaster or state of emergency having occurred in
a populated area. Subject to the foregoing, the City shall not, in any
way or manner, be answerable or suffer loss, damage, expense or liability
for any loss or damage that may happen to said building, work, or
equipment or any part thereof, or in, on, or about the same during its
construction. and before acceptance.
26. CONTRACTOR'S GLARAMEE. The Contractor unqualifiedly guarantees the
first-class quality of all workmanship and of all materials, apparatus,
and equipment used cr installed by him or by any subcontractor of supplier
in the project which is the. subject of this Contract, unless a lesser
quality is expressly authorized in the Plans and Specifications, in which
event the Contractor unqualifiedly guarantees such lesser quality; and
that the work as performed by the Contractor will conform with the Plans
and Specifications or any written authorized deviations therefrom. In
case of any defect in work, materials, apparatus or equipment, whether
latent or patent, revealed to the City within one (1) year of the date of
acceptance of completion of this Contract by the City, the Contractor will
forthwit1h remedy such defects without cost to the City.
27. LIQUIDATED DAMAGES. Time shall be of the essence of this
Contract. If the Contractor fails to complete, within the time fixed for
such completion, the work hereinbefore mentioned and described and hereby
contracted to be done and performed, he shall became liable to the City
for liquidated damages in the sum of ONE H1)NDRFD FIFTY DOLLARS ($150.00)
for each and every calendar day during which said work shall remain
uncompleted beyond such time for completion or unlawful extension thereof,
which stun shall be presumed to be the amount of damage thereby sustained
by the City since it would be impracticable or extremely difficult to fix
be deducted by the City from moneys due the Contractor hereunder, or his
assigns and successors at the time of oompletion, and his sureties shall
be liable to the City any excess.
28. ADDITIONAL PROVISIONS. None
13
STATE OF CALIFORNIA On this....25th.........day of....FEBRUARY...................in the year
ss. .........1991............ ....,before me,
COUNTY OF.....CONTRA.COSTA. ....ROSE.V.- FPAGOSO......•••.••,a Notary Public,State of California,
8 duly licensed and sworn,personally appeared..................................
6 ..............................FRANK.SPOSETO...............................
' personally known to me(or proved to me on the basis of satisfactory evidence)
to be the person who executed the within instrument as.ERES.IDEN'.1.........
or on behalf of the corporation therein named and acknowledged to me that
such corporation executed the within instrument pursuant to its by-laws or a
resolution of its board of directors.
iN WITNESfi WHEREOF I have hereu to set my hand and affixed
my official seal in the........................ .,.,Co_ ONTRA.COSTA
j no dmwmM a ody a 9eseral krm ancn may be wooer Mr use k some ........................ fOrtil a e In t111S C i tiflCate.
trerreet4om and n no tray acts,a m kaended k ait,as•auestinda kr Ore 1 i
o advice d W a•sMMY.The oar does not make arty WW8"000-esoroas or mgtied as to dre
"W vakd9y of try wo mM or M sukehaN of nose krms m"aoe&m traraecWn.
Cowdery's Form No.28—Acknowledgement to Notary Public.— Notary Public, _ of California
Corporation(C.C.Secs. 1190-1190.1)—(Rev. 1183) My commission expires
P. 0. No.
IN mMMSS NWWF, the parties have emaxted this Contract, in
dtipl.icate, the day and year first hereinabove written.
CITY OF CUP8RrM 1 l
Approved as to form mayor:
City Attorney f` City Clerk:
Date/City Clerk: 1 }
CONrRACIOR: �' CO�N�Ri � I .
j
Notary acknowle&fflent required.
If a corporation, corporate seal
and corporate notary
® acknowledrwnt required.
Project Name and Number: SIDBMLK GRINDING, PRW= 91-106
Contractor's Name: P & F CONS!nRUC'I'ION, INC.
Contractor's Address: 1010 39TH AVENUE, OAFLNM, CA 94601
Contract Anomt: FUM FIVE THOUSAND SE.VE2F1'.'L THREE DOLLARS AND N0/100
Contract Ac=mt Number: 110-8403-953
14
1991 CAPITAL IMPROVEMENT PAYMrMT SCHEDULE
QUANTITIES CUT OFF DATE CHECK RELEASE DATE
FRIDAY 5: 00 PM FRIDAY
------------------------ ------------------------
JANUARY 11 JANUARY 25
FEBRUARY 8 FEBRUARY 22
MARCH 8 MARCH 22
APRIL 5 APRIL 19
MAY 3 MAY 17
MAY 31 JUNE 14
JUNE 28 JULY 12
JULY 26 AUGUST 9
AUGUST 23 SEPTEMBER 6
SEPTEMBER 20 OCTOBER 4
OCTOBER 18 NOVEMBER 1
NOVEMBER 15 NOVEMBER 29
DECE.MBER 13 DECEMBER 27
"A"
BIDDERS PROPOSAL PAGE
SIDEWALK GRINDMG
YRWEM 91-106
GENrIM4.'V:
The below named and undersigned bidder hereby proposes to do all work
required to oaplete the said work in accordance with the specifications
and/or plans for the amounts set forth herein cn the incorporated
schedule.
All necessary preparation as well as cleanup is included in the prices bid
and no extra ration will be allowed. All work will be done in a
workmanlike manner and will meet or exceed the embodied requirements
and/or the standards stipulated by the City Erxjineer
The undersigned also understands that the quantities shown below are
estimates only, being given as a basis for the extension of the unit
prices bid. The extension will be the basis for cm arison of bids by the
Director of Public Works.
The work to be done consists of furnishing all labor, methods, or process,
tools, machinery and material required to ccuplete the sidewalk grinding
as described in the Special Provisions.
BID EST. QTY.
ITEM! UNIT UNIT PRICE TOTAL
1. 959 Ea Provide for grinding of P.C.C. $ �'1;00 /Ea $— ou
sidewalk where displacement is
greater than A°' and less than
or equal to 2"
FaR-tit�SI:Vi<N �r�o��aS
TOTAL BID: 5 7-3o
BID PROPOSAL PAGE 1 OF 6 (, P�,C 4
I, the signed agree that if this prcpasal is accepted, I will
enter into a coact with the City of Cupertino to provide all necessary
machinery, tools, apparatus, and other means of construction and to do all
the were specified in the contract in the manner and time specified.
I, the undersigned declare that this bid is made without connection
with any person, firm, or corporation making a bid for the same work, and
is in all respects fair, and without collusion or fraud.
I, the undersigned recognize that the Director of Public Works of
the city of Cupertino will reserve the right to establish the priority of
one jai over another and each acarting date where conflict of construction .
scheoules occur.
Attached hereto is the required certified check or bid bond in the
amount of $ I® /o , as required by law and the Notice to Bidders
(lot of bid amount)
BID pROPOSAL PACE 2 OF 6
A. SAID DOCU4F.MM, ContinuDd
BIOOFR QCVUIFICA77ON FDW
In further compl ix,, e with the specifications furnished, the
undersigned subn i t:s the f o l l aw ir►g statements as to his exper iencti and to
his qualifications as a lxv-t of this proposal, and the tru hfulniess and
utterance of the information is hereby guaranteed.
(?) How many ye-r- has your organization been in
bu--ines-; under its present name? jo,
(2) How many years ouperience in work con parable with
that required under the proposed contract has your
organization had by this or any other name? 3 0 -f-
(3) Contractor's License No. ?, ?G O O P-
state of California, Classification_A_,_P,,�-�3-
l,-)cpiration tkite •T -J t -0(
(4) List work similar ;r► character to that required in the
proposed contract which your organization or personnel in
your organization has completed within the past 3 years.
Year Class, Location of Work and for Whom Performed Contract Amount
`YJ
-
1 �_. _� LU�Lt?�L�� ►fir t�n ? M 2 0 3, .
M�CLL LLfNN RUN-D
BM PROPOSAL PAGE 3 OF 6
A. BID DOC("NM, 0ontinwed
Name of Pr4lxrec3 , if any
(lion 4104, Government Code)
1. N Cq N L
2.
3.
4.
5.
6.
Address if Shop or Office ofSub-Contractors
(Section 4104, Government Code)
1.
2.
3.
4.
5.
6.
Work to be Performed by Sub-Contractors
(Section 4104, Government Code)
1.
2.
3.
4.
5.
6.
BM PROPOSAL PAGE 4 OF 6
M7
A. BID D=M S, Continued
IF YOU ARE AN INDIVIDUAL, SO 9WE. IF YOU ARE A FIM OR OD-PAMWERSHIP,
STATE THE FIM NAME AND LIST THE NAMES OF ALL INDIVIDt AL OO-PAMM
t"X+t WD C: 2HE FI N. IF A OORPORA7.'gON, STATE LEx',AL HAPE OF CORPORATION,
ALSO NMIS OF PRESIDE', SFX kErARY-TRFASURM AND MMWIER. THE CORPORATE
SEAL MUST BE AFFIXED. THE INFVIWMON CONTAINED IN THIS BID IS BEING MADE
UNDER PF.'`�TY OF PERJURY.
TYPE OF BUSINESS: Individual:
Co►-Partnership .
corporation P Ii P= Con's 'FZl cc i oo I ILC--
.:,oint Venture
Other
(Describe)
Name and Signature of Bidder:
�Priflt)
v (Signature)
Address (Both ma'_ ' and location addresses) ;
C-
�1C)I Q 32z« A VL_KU
Telephone Number:
Date: FMU -- CiEt L
Adderydas Reoeived:
1 2 3 4 5
BID PROpOSAL PAGE 5 OF 6
NONCOLLUSION AFFMhVrr M BE EMLI= BY
BIDDER AND SUEW-P=® WrIli BID
State of California ss.
County of j)LP(V.jtMtj
ER(413 K 000 SE i U being first duly sworn, deposes
and says that he or she is ,P i=1SfDEAsp- of. P� F 66N5MUCrInN Sly,
the party roking the foregoing bid that the bid is not made in the
interest of, or on behalf of, any undisclosed person, partne ship►
company, a wociation, organization, or corporation; that the bid is
genuine and not collusive or sham; that the bidder has not directly or
indirectly induced, or solicited any other bidder to put in a false or sham
bid, and has not directly or indirectly oolluded, conspired, connived, or
agreed with any bidder or anyone else to put in a sham bid, or that anyone
shall refrain from bidding; that the bidder has not in any manner,
directly or indirectly, sought by agreement, communication, or aanference
with anyone to fix the bid price of the bidder or any other bidder, or to
fix any overhead, profit, or cost element of the bid price, or of that of
any other bidder, or to secure any advantage against the public body
awarding the contract of anyone interest in the proposed contract; that
all statements contained in the bid are true; and, further, that the
bidder has not, directly or indirectly, suYarutted his or her bid price or
any breakdown thereof, or the contents thereof, or divulged information or
data relative thereto, or paid, and will not pay, any fee to any
corporation, partnership, cLmTany association, organization, bid
depository, or to an_r member or agent thereof to effectuate a collusive or
sham bid.
Name and Signature of Bidder:
F1�ANK SP OLTO
(Print)
Date:F�M(Jkg-t
BID PROPOSAL PACE 6 OF 6
............ ...................
Fidelity aud Deposit Cumpany
HOME OFFICE OF MARYLAND r1A1.2-IN01?r. Mn. a1:0a
BID BOND
KNOW ALL MEN BY THESE PRESENTS:
That we..............................1...&...E..CONSTi;ll(:1:MN.,...1hLC..........................................................
........................
............
(A CALIFORNIA CORPORATION)
..................................................................................................................................................................................................
-•............................................................................I.........I....., as Principal. (hereinafter called the "Principal"), and
the I'1DLI-IT`i AND COMPANY OF MARYLAND, of Baltimore. Maryland, a corporation duly organized ,
under the laws of the State of Maryland, as Surety, (hereinafter called the "Surety"),are held and firmly bound I
unto................................CITY OF CUPERTINO
.................................................................................................................................................
..................................................................................................................................................................................................
..................................................................................................................as Obligee, (hereinafter called the "Obligee")s
in the sum of....t.r:l`�..PE.R CENT OF, THE AMOUNT BID ------------------- Dollars ( lOI`-----
... ....... ...............D $.. . — ....),
for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves,
our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
WHEREAS, the Principal has submitted a bid for..... ROJECT 91-106
.................................................................................................S IREWALK.-G II.I N ALN G..........................................................
..............................................................................................................................................................................•-..................
i
.......................................................................................................................................................................................-......... t
NOW,THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into
a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be
specified in the bidding; or contract documents with good and sufficient surety for the faithful performance of
such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the
event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal
shall pay to the Obligee the I 1!rence not to exceed the penalty hereof between the amount specified in said
bid and such larger amount for whirl, the Obligee may in good faith contract with another party to perform
the work covered by said bid, then this obligation shall be null and void,otherwise to retrain in full force and effect. i
i
12th '
Signed and sealed this............................................................day of...................F.L:IIBUARY..............t.D. I9_...gL. 1
i
y P h .. CONSTRUCTION, C. .....(SEAL
1'rinci
......_.._............................................. ....................
Witness BY: .:
.,........ .!•••••. ...f ..... .... :....,of......... y. ion.-
FIDELITY AND DEPOSIT COMPANY P�MARYLAND
cly
........................................................ ............................. I3y...i�.. ...... (SsAL)
Witness J. ALAN CAMPBELL 7'il/c
ATTORNEY—IN—FACT s� �
cJ1S t!
d—ISOM, �
Approved by The American Institute of Arrhitects.
A.I.A. Document No.A-310 February 1970 Ldiuon.
s
Power o/Attorney
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
It0hof Of f ILt.IM Itm011.MO.
KNow Af.L MEN IfY'llIESE PRF_SFNTS:'That Ilse FIUF.Lt,rY AND VIEPOSIT COMPANY OF SIARYLANI),a cotltnralion of the
Slate of h!arylauJ,by C. M. rer'.CU•r. JR. , Vice.President,and C. W. ROBBINS
Assisinnl Secretary,in pursuence of authority granted by Article V1.Seclio-n 1,of the By-Lawsof said Company,which
reads tes follows:
"I lie Chairnwr od list tinged,or file Presi'lenl,or any Farcut:ve VieOPfrlidrsti.m city of the Senior Vire•I'res:detus nr Vice-PresWenes
sperialty 41111...fired sa Oil.].?by Ilse Ileatd of Uireerors or by the Vareuti tie Committee.shall Isowe lsawe►,by and with elseeoncurrr"r-e of the Secretary
or ally one of the as•ivant'Srcrelsvie•,10 apf.oini Ilevidenl Vice-Pre stiletto I.Assistant Vire•f 1e.,iJettta and Asfosneys-moo-Fact as Ilse husinrss of else
Company may rr.luiur,or to sutbonse any prlmuo of persons to earcule fill behalf of the Cusopany any lonols,findertakiogs,teragnisancev,
at,pulai...ns,polities. Jeers,and rrieuses assJ ms:gontuol!all iudgemenit,decrees,14101(gape and instru,nenes iot she statute of
snoreg•frs,... a...1 1..Ilia Ilse seal of Ilse Co Itself 1lterelo."
does hereby nominate constitute and appoint J. Alan Campbell of Walnut Creek, Cal ifortt� ia�e
'11s ruc an I.awf ul nGcnt and Attorney-ii►•Fact,to �e,,cu`f,,s,,landdeli�,er. �and �beh,�Jrs surely,and as
its act and decd:any and all bonds and undertakings. .. . . . . . . . . . . .. . . .. . . . . . . . . . . . . .
Anil l 1c exectttium of such bonds or umlertakings in pursuance of these presents. shall be as binding upon said
Company,as fully and amply,to all inients and purposes,as if they lend been July executed and acknowledged by the
regularly elected officers of the Coneparey at its office in Baltimore, Md., in their own proper persons.
The said Assistant Secretary does hereby certify tome the aforrgoing is a true copy of Article Vt.Section 2,of the By-laws of ssiJ Company,and is
now in force.
IN Wi-i-NESS 1V11EII90F,file said Vice-Presidetit and Assistant Secretary leave hereunto subscribed their names and
affixed the Corporate Seal of the said FIUFLI-rY AND m..I'OSIT COMPANY OF MARYLAND, this ..........7 0.1.................day
of JatlU;try......................A.I). 19.R?....
„��•...� F1UELl'I'Y AND DEPOSIT COMPANY OF.INAItYLAND
)yl ro a'—01,,tr A 1,1 F:.ST:
SEAL
Lo
r' ........................................................................ By ................................ .........
��ti•rr' Auioant Secretary Vice•Pre,idrnl
STATT.or AIAaTtAlsU I UTV Or UALTIM011E :
}
On this 7Elf day of .Iattua ry .A.n. l 5 .before the suhscribrr,a Notary Public of flit State..(Maryland,in
and for lite I:iey of liveltimiar,duly eammitsiotted and qualireJ,came the showe•nam►.d Vice.I'ses.Jro o and Assistant Secretary of the 110rurT Also
Ile rally C.o•II',\lsY or AlArtmeeen,to nor lorren.tally known to he else iodieiJuals and u1f:rn s.Ir+erihrJ its an.l who executed Ilse precediog ifiairumrtit,
and thee lath ccknnwleJgeJ the eseeulsun of the same,and firing bJ the duly lower",sewrially and each(or himarif dip e4o, I sod u:th,elsat they age
the slit oflirrri of she Compgosy aloressid,mood that tlse seal dfiaeJ to tlor preceding iu•trumntl is lite Corporate So of said Company,meta diet Ilse
Be id C:orporete Sfat sod Ilicir signaller egos such officers were duly of fixed motel aubseribed to I lie!aid insiruonenf by Ilse authority slid direction of the
amid Corporation.
Iv"Iasi more►Witimur.t have he eunio set my hand and a(fiaed by 0(icial Seal,at the Giy ornfhim e,f ,day and ear list above written.
• .sorer i .........«.................s ..... .............................. ...................
Notary Public Comnetssion EapiresJulY...1......1.pR.L.
'�- Crlt'I'IFICA'I'l:
I,the oetdersigqevni,As.isexist Serretary of fire FIDELITY Also DrrtnfT COIAPAVY or IUAarlAnn,do hereby certify that else original Power of
Attorney of wllicIi else hurgnin(g�is a full,sue good correct copy,is in full farce tend effect one lit date of this teriifieale.and 1 do Luther certify that the
Vice-lot esidesee who executed I lm said I'ower of Auorney was one of I he additional Vice-I'res:JrotI specialty sufhorised by the loused of Direeluts to
appoint any Alto#ney-its'Fact as pro witted in Article Vt.Section 2 of Ilse By-l,wa of Ilse F'IDWTV Ana Utpus►TCuurAas of blAaeuno.
This Certificate may he signed by facsimile msder avid by authority of Ilse fulluwiesg resoiulion of he hoard of Directors of live FIDEutY Also
Dryosit Cuter vy 111'MAananu of a tnertissg duly called seed held on flit 161h day of July,190.
Ilf.WLVrrs:"that flit facsimile or mechanically rrprodueed signature of any Assistant Secretary artful Company,whether made hereto(ore or
hereafter,wherever.ppraeisog upon a eertilled cooly eel any tower of attorney issued by the Company.shall bee valid toed binding upon ilia Company
with Cite sine force need effect as ihouglo manually affised.' 12 th
In TESTIMONY WemAe.ur.1 have hereunto subscribed my name and affiaeJ lite corporate seal of the said Company.this............«..«»day
F E BRUARY t9 91
of..................................................,
P�
...................«...... ............................
< Iit '11 1111/ s•1•C'/••1•re•►1 1 e•s •s• •••.t• •.•160s 1• • •.s ••i••.,• • • • •• .•
CITY OF CUPERTINO
INTERDEPARTMENTAL Date Feb. 28, 1991
To City Clerk From Public Works--Sumi
CI Information MESSAGE:_ SIDEWALK GRINDING, PROJECT 91-106 (CC, 2/19/91)
C1 Implement
=1 Investigate
C1 Discuss 1. Three sets of contract for processing.
=1 See me 2_ One copy each faithful performance bond and labor and material
i 3 Reply
bond. Fidelity and Deposit Company of Maryland
Bond No. 30305422
3. Certificate of Insurance, 2/26/91.
Reply: sm P & F Construction, Inc.
attach. 1010 39th Avenue
8@kl--A- nA 0 6 1-
SIGNED: DATE
Send parts 1 and 2; retain part 3 for follow-up; part 2 to be returned with reply
ER
} THISCERTIFICATE iSfSSUED AS A MA T TER OF INFORMA T ION ONLY AND CONFERS
Curtis Day 81 Company ' '+ IrSUPONTI,ECERYF►CATS►OLD£R.THIS CERTIFICATE DOES NOT AMENO.
EXTENOOR ALTER THECOVERAGE AFFORDEDBY THEPOLICIESSELOW
50 Fremont St. , Suite *300
San Francisco, CA 94105 COWANES AFFORDNG COVERAGE
415—543-3140 COMPANY
cow LETTER A Transcontinental In u anee Co
COMPANY
LETTER
Trangportation Insurance Co.
P and F Construction, Inc. COMPANY C
1010 39th Avenue LETTESafoco Insurance COMPaniftS
Oakland �LETTER
CA 94601 COMPAK/
LETTER E
m
...........:::..
THIS IS TO CERTIFY THAT THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED.NOT WITHST AND'NG ANY REOUIREM£NT.TE[>AA OR CONDITION QF ANY CONTRACT OR O THER DOCUMENT WITH RESPECT TC WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERT AIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LMITS SHOWS?'-AY HAVE BEEN REDUCED BY PAID CLAMS.
OO TYMOFINSURANOE POLgYNU&a= POLIOVEMOTWE POLIOVEMPSIATIO14 ALL LIMITS IN THOUSANDS
LTG DATE(MWOD/YV) DATE(MM/DO/YY)
OWMALLIABILITY GENERAL AGGREGATE b 2000
A X COMMERCIAL GENERAL LIABILITY 803398721 1/01/91 1/()1/92 P a miscow7&;iAG3TeGAtE Is 1000
CLAIMS MADE a OCCUR. PERSONAL L AOYERTISlN(]1N,JLAtY : 1000
OWNER'S& WRACT RS PROT EACH OCOJAREtCE b 1000
FIRE DAMAGE (Army am tire) b 50
MEDICAL EXPENSE(Any one Person) b 5
AUTOMOBa.0 LIABLnY StNOLE :
B ANY AUTO BUA704717638 1/01/91 1/01/92 LIMIT 1000
ALL OWNED AUTOS INJURY b
SCHEDULED AUTOS (Per person)
X HIRED AUTOS IN,ARY f
X NOWOWNEO AUTOS (Per aooidm+t
OARA13E LIABILITY PROPERTY
DAMAGE b
EXCESSLIABLITV OC
• b b
OIFER THAN UMBRELLA FORM
WORKER COMPENSATION STATUTORY
'S •If;
MID b 1000 (EACH AMCENT)
C WC2153249 1/01/91 1/01/92 b 1000 (DISEASE-POLICYLIMIT)
EMPLOYERS'LIABLITV : 1000 (0 SEASE-EACHEMPLOYEE)
OTHER
DESCRIPT�N OF O.'+a:.1TtoNS0.AOA110NSItIZ1ilOLLrStSPE01AL t4EAtS
RE: Sidewalk Grinding, Project 91-106
(SEE ATTACHED ADDITIONAL INSURED ENDORSEMENT)
`CER?IFICATEHOLAF.td wC1WC IIOt
.. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF. THE ISSUING COMPANY WILL'ol G�16Aifi
`'• MAIL 30 DAYSWRITTENNOTICETOTHECERTIFICATE HOLDER NAMED TOTHE
City of Cupertino " LEFTIdol-
10300 Torre Ave.
Cupertino. CA 95014 ? � REPaesENrATWE
154550000
A (itI��> `Z3JAAAdOEt(7coRP� IaT( Mt9ea;
POLICY NUMBIZz. 803398721
THIS ENDORSEM---NT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED ® OWNERS, LESSEES OR
CONTRACTORS (FORM B)
This endorsement modifies insurance provided under the folbwing:
COMMERCIAL GENERAL LIABILITY COVERAGE PART.
SCHEDULE
Name of Person or Organization:
CITY OF CUPERTINO, ITS OFFICERS AND EMPLOYEES
(If no entry appears above.information required to Mete this endorsement will be shown in the Declarations
as apolicabie to this endorsement.)
WHO IS AN INSURED (Section It) is amended to include as an insured the person or organization shown in the
Schedule. but only with respect to liability arising out of"your work"for that insured by or for you.
RE: SIDEWALK GRINDING
PROJECT 91-106
THIS INSURANCE IS PRIMARY EXCEPT WHEN EXCESS INSURANCE APPLIES. IF THIS
INSURANCE IS PRIMARY. OUR OBLIGATIONS ARE NOT AFFECTED UNLESS ANY OF THE OTHER
INSURANCE IS ALSO PRIMARY. THEN, WE WILL SHARE WITH ALL THAT OTHER INSURANCE
WITHIN THE TERMS DESCRIBED IN THE POLICY.
=C 20 2 C 1 25 Cooyrign,. tnsurance Services Office. Inc.. 198t
STATE OF CALIFORNIA )
SS.
COUNTY OF CONTRA COSTA )
On FEkkuAgy 25, 199 _ before me,a Notary Public,
personally appeared _ j MIN u_ FTSCHER
personally known to me (or proved to me on the basis of satisfactory evidence), to be the person whose
name is subscribed to this instrument as attorney-in-fact
of ----- _ 11IilT.LT Y AND DEPOS T T MAPANY_aE_.MA$Yj,A1�._ .�
and acknowledged to me that he (she) subscribed the corporation named t reto as Suety and his (her)
own name as attorney-in-fact.
NOTARYBLIC
STATE OF CALIFORNIA On this..... .2ath.......day of........FURUAM...............in the year
Ss. ......n91........... .................before me,
COUNTY OF...... C NT ..CASTA. ...ROSE.V....FRAGOS.0.............a Notary Public,State of California,
duly licensed and sworn,personally appeared..................................
..............................FRANK.SK.SUO...............................
personally known to me(or proved to me on the basis of satisfactory evidence)
to be the person who executed the within instrument as............PRESIDENT
or on behalf of the corporation therein named and acknowledged to me that
such rorporation executed the within instrument pursuant to its by-laws or a
resolution of its board of directors.
IN WITNESS WHEREOF I have�ereunto set my hand and affixed
my official seal in the...........,.....y�.. y Of••CONTRA•CaSTA
r
Tfa d=WMm n arty a g",i tam whch may he prover fa use M evnpte ............................. above in this certificate.
rr8lget ba wW m M way wM,a M Owidea to M.ae a suhsetute for Ow
amp d an aaarroy.The—ft do n04 make my warramy eaher exprees m mpbe0 as to me
-. team vabchty of any Mvnion a the suea0ifay M mesa fame m any spat he traratectan • .
Notary Pu li fate of California
Cowdery's Form No. 28—Acknowledgement to Notary Public—
Corporation(C.C.Seca. 1190-1190.1)--(Rev. 1/83) My commission expires
BOND NO. 30305422
PREMIUM:$424.00
'WMTHFUL PEP.FOR.MANCE BOND
KNOW ALL MEN BY THESE PRESENTS:
THAT WE, P & F CONSTRUCTION, INC.
as Principal and „_g=nat_T AND_nEPO:SIT COMPANY OF MARXI AM
as Surety are held and firmly bound unto the City of Cupertino, State of California,
in the sum of -BD= -FIXE THOTISAwn SEVENTY THRRE Alf 10Qthg ------------- Dollars
($ ) lawful money of the United States, for the payment
of w 3
c11 will and truly to be made, we bind ourselves, our heirs, executors,
successors and assigns, jointly and severally, firmly by these presents.
THE CONDITION of the above obligation is such that,
WHEREAS, the Principal has entered into a contract dated FER jAM 12, 1991 .
with the Obligee
to do and perform the following work to-wit:
SIDEWALK GRINDING
PROJECT 91-106
NOW, THEREFORE, if the said Principal shall well and truly perform the work
contracted to be performed under said contract, then this obligation be
void; otherwise to remain :in full force and effect.
IN WITNESS WHEREOF, this instrument has beer: duly executed by the Principal
and Surety this 25th day of -_-_._.FRRRIIARY 19��•
(To be signed by Principal
and Surety and acknowledgment. )
CONS gCTION fNC.
rinclpal
FIDELITY A COMPANY OF M&ULAND
Surety
--� Lam:---
' By:
_
Attorney-in-Face
JOHN R. FISCHER
The above bond is acce,`.ted and approved this day of 19____
BOND NO. 30305422
PREMIUM INCLUDED IN PERFORI ANCE BOND
LABOR AND MATERIAL BOND
KNOW ALL MEN BY THESE PRESENT:
WHEREAS, the City of Cupertino, State of California, and
P S F CONSTRUCTION, INC.
hereinafter designated as "Principal" have entered into or are about to enter
into a contract providing for the installation, construction, and erection by
Principal of certain improvements more particularly described in said contract;
and incorporated herein by reference.
WHEREAS, said Principal is required to furnish a bond in connection with
said contract, providing that if said Principal, or any of his or its sub-
contractors, shall fail to pay for any materials, provisions, provender or
other supplies or teams used in, upon, for or about the performance of the work
contracted to be done, or for any work or labor done thereon of any kind, the
Surety on said bond shall pay the same to the extent hereinafter set forth;
NOW, THEREFORE, we, the Principal, and
_ FIDELITY AND DEPOSIT COMPANY OF MARYLAND
as Surety, firmly bind ourselves, our executors, administrators, successors
and assigns, jointly and severally, unto the City of Cupertino, and any and
all materialmen, persons, companies, or corporations furnishing materials,
provisions, provender or other supplies used in, upon, for or abut the perfor-
mance of the aforesaid work contracted to be executed or performed under the
contract hereinabove mentioned, and incorporated herein by reference, and all
persons, companies or corporations 'Lending or hiring teams, implements or
machinery, for or contributing to said work to be done, and all persons who
perform work or labor upon the same, and all persons who supply both work and
materials, whose claim has not been paid by Principal or by any other person,
in the just and full sum of _FORTY EIVE THOU2AND 5 .V .NTY THREE AND NO/baths
-------------- ------------------------------------------------------
----------------------------------------------- ($ 45,073.00
THE CONDITION OF THIS OBLIGATION IS SUCH THAT ii said Principal, his or
its subcontractors, heirs, executors, administrators, successors or assigns,
shall fail to pay for any materials, provisions, provender or other supplies
or teams used in, upon, for or about the performance of the work contracted to
be done, or for any work or labor thereon of any kind, or for amounts due under
the unemployment Insurance Act with respect to such work or labor, or any and
all damages arising under the original contract, then said Surety will pay the
same and also will pay in case suit is brought upon this bond, such reasonable
attorney's fee as shall be fixed by the court.
This bond shall inure to the benefit of any and all persons, companies,
and corporations entitled to file claims under Section 1184. 1 of the Code of
Civil Procedure, so as to give a right of action to them or their assigns in
any suit brought upon this bond.
STATE OF CALIFORNIA )
} SS.
COUNTY OF CONTRA COSTA )
On FEBRUARY 25. 1991 4 , before me,a Notary Public,
personally appeared _ _ JQ1i1 R. FISCHER ____..^_ _
personally known to me (or proved to me on the basis of satisfactory evidence), to be the person whose
name is subscribed to this instrument as attorney-in-fact
Of
and acknowledged to me that he(she) subscribed the corporation nagred theretp-a"urety and his (her)
own name as attorney-in-fact.
r
N T RY PUBLIC
STATE OF CALIFORNIA On this....25th.........day of....FRBRMY...................in the year
ss. ..................19.911.......................................before me,
CO OF..CONTRA.�QSTA...... ROSE..V....FRAGOSO................a Notary Public,State of California
duly licensed and sworn,personally appeared..................................
FRAiy1K'SnSETC..................................
personally known to me(or proved to me on the basis of satisfactory evidence)
to be the peson who executed the wit`in instrument as.?RESIDENT
or on behalf of the corporation therein named and acknowledged to me that
_. such corporation executed the within instrument pursuant to its by-laws or a
resolution of its board of directors.
IN WITNESS WHEREOF I have heree}nto set my Land and affixed
m official seal in the...............,.... ) County of
y ,r fi° y RA c(3 s f A
Yha docvmeaf a 04 a VOWd fom,. may be WOW for ase.,wnae ................................., f Ihe,dat eOorth a his certificate.
from OOM end M M W"6C-n.«IS WWW ed to W.M a Ub$bb m f«me
&*m of on abrr y.YM f does net make any w mly enter eWew or w6Aatl m fc ma
"Mvwafy of any proms or ffb%ftW"of mesa forms m any anooft trwnwhon dT
Cowdery's Form No. 28—Acknowledgement to Notary Public-- _ Notary Public,State alifornis
Corporation(C. C. Secs. '190-1190.1)—(Rev. 1/83) My commission expires_—
Labor and Material Bond Page 2
And the said Surety, for value received, hereby stipulates, and agrees
that no change, extension of time, aiteration or addition to the terms of the
contract or to the work to be performed thereunder or the specifications
accompanying the same shall in any wise affect its obligations on this bond,
and it does hereby waive notice of any such change, extension of time, alter-
ation or addition to the terms of the contract or to the work or to the speci-
fications.
IN WITNESS WHEREOF, this instrument has been duly executed by the
Principal and Surety this 25th—day of ITERRUARX 19 93
7
i
P 6 TRUC
B °
(To be signed by Principal ` ncipal
and Surety. Notary
acknowledgments required.)
FIDE .TTY AND D -FUSTY A P NY OF NARYLAND
Surety
r j
Attorney-in-Fact
JOHN R. FISCHER
The above bond is accepted and approved this day of
19
6/17/85
Power of Attori f
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
HOME OFFICE.OAL rusOeE.MO.
KNOW ALL MEN BY THESE PRESENTS:That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND.a corporation of the
State of Maryland, by C. M. PECOT, JR. , Vice-President,and C. W. ROBBINS
Assistant Secretary,in pursuance of authority granted by Article VI.Section 2,of the By-Laws cf said Company,which
reads as follows:
'"The Chairman of the Board,or the President,or any Executive Vice-President,or any of the Senior Vice-Presidents or Vice-Presidents
specially authorised so to do by the Board of Directors or by the Executive Committee,shall have power•by and with the concurrencoof the Secretary
or any one of the Assistant Secretaries,to appoint Resident Vice-Presidents.Assistant Vice-Presidents and Attorneys-in-Fact as the business of the
Company may require,or to authorise any person or persons to execute on behalf of the Company any bonds,undertakings,recognmanees,
stipulations.policies,contracts,agreements,deeds•and releases and assignments ofjudgements,decrees,mortgages and instruments in the nature of
mortgages....and to affix the seal of the Company thereto."
does hereby nominate constitute and appoint John R. Fischer of Walnut Creek, California. . . _
its true and lawful agent and Attorney-in-Fact,to make,execute,seal and deliver,for,and on its behalf as surety,and as
its act and deed: any and all bonds and undertakings. . . . . . . . . . . . . . . . . . . . .
n- the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said
Company,as fully and amply,to all intents and purposes,as if they had been duly executed and acknowledged by the
regularly elected officers of the Company at its office in Baltimore, hid., in their own proper persons.
The said Assistant Secretary does hereby certify that the aforegoing is a true copy of Article Vf.Section 2,of the By-Laws of said Company,snd is
now in force.
IN WITNESS WHEREOF,the said Vice-President and Assistant Secretary have hereunto subscribed their names and
affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this ...........�8th..............day
of..........Fe.�ruAN_Y............................A.D. 19..86...
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
w,moo oc►os r� ATTEST:
n
..........�......................................................... By ....................... ........................................
` •�. Ami.uam Seortory Bice-President
STATE Of MARYLAND ? SS:
CITY Of BALTIMORE J
On this 28 th day of February .A.D.l9 86 ,before the subscriber,a Notary Publi--if the State of Maryland,in
and for the City of Utimore,duly commissioned and qualified,came the above-named Vice-President and Assistant Secretary of the FIDEUTT AND
DEPOSIT COMPANY or MARYLAND.tome Personally known to be the individuals and officers described in end who executed the preceding instrument,
and they each acknowledged the execution of the same,and being by me duly sworn.severally and each f-r himself deposeth and with,that they are
the said officers e`;he Company aforesaid•and that the seal affixed to the preceding instrument is I he Corporate Seal of said Company,and that the
said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the
said Corporation.
IN TESTIMONY WHEREOF,I have hereunto jet my hand and affixed by Official Seal,at the City nf B&itimore.the day and year first above writ en.
.. ....
«i'°_" Notary Public ommission x J.; J.y �.�...1.98.4..t:
�� CERTIFICATE
1,the undersigned.Assistant Secretary of the FIDEUTY AND DEPOSIT COMP.aSY or 1l.%RYLAND,do hereby certify that the original Power of
Attorney of which the foregoing is a full,true and correct copy.is in full force and effect on the date of this certificate:and 1 do further certify that the
Vice-President who executed the said Power of Attorney was one of the suditional Vice-Presidents specially auto orised by the Board of Directors to
appoint any Attorney-in-Fact as provided in Article VI.Section 2 of the By-Laws of the FIDELITY AND DrPosrr COMPANY or MARYLAND.
This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDEUTY AND
DEPosrc COMPANY or MARYtANO at a meeting duly called and held on the 16th day of July.1%9.
RESOLVED:"That the(aeaimile or mechanically reproduced signature of any Assistant Secretary of the Company,whether mado heratofore or
hereafter,wherever appearing upon a certified copy of any Bower o(sitorney issued by the Company,shall be valid end binding upon the Company
with the some force and effect as though manually affixed.' 2 S th
IN TESTIMONY WHEREOF,I have hereunto subscribed my name and affixed the corporate seal of the said Company,this........._......... day
of ._____._.....FEB.RUARY..........19..._91
euiaranr e
016_4 736. _ - --• --- —•--- ._. ._.
I$SUL OA�OiMfOt�11'Y'jn
: .
PRODUCER THIS CERTIFICATE IS ISSUED?»A MATTER OF INFORMATION ONLY AND CONFERS
R. C. Fischer b: C Q. NO RIGHTS UPON THE CERTIFICATF.HOLDER.THIS CERTIFICATE DOES NOT AMEND,
1655 N. Main Street, S U I '•;a 360 EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW
P. O. B O K 8101 COMPANIES AFFORDING COVERAGE
Walnut Cree , Ca. 94516-8101
COMPANY
LETTER
CODE SUB-CODE COMPANY PUBLIC WORKS
INSURED LETTER COMPANY MAR 4 1991
Ambo Engineering, Inc. LETTER 'b
34151 Z+sf i s s i g Way COMPANY
Union City CA 94557 LETTER ® REPUBLIC INDEMN[TY COMPAINY
COMPANY
LETTER
777777T-71197
r , .,., fir# o yQ - x77
. rk 7 -�5 �ssk tJ& t` k u
.< � .. .,.,. ... -.. � y . .: .» ': 'fit...
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED,NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION ALL LIMITS IN THOUSANDS
TR DATE(MM!DD!YY) DATE(MMIDD!YY)
GENERAL LIABILITY GENERAL AGGREGATE S
COMMERCIAL GENERAL LIABILITY PRODUCTS.COMP!OPR AGGREGATE S
CLAIMS MADE OCCUR. PERSONAL&ADVERTISING INJURY S
OWNER'S 8 CONTRACTOR'S PROT. EACH OCCURRENCE $
FIRE DAMAGE(Any one fire) It
MEDICAL EXPENSE{Any one person) S
AUTOMOBILE LIABILITY COMBINED
SINGLE S
ANY AUTO LIMIT
ALL OWNED AUTOS BODILY
INJURY $
SCHEDULED AUTOS (Per person)
HIRED AUTOS BODILY
INJURY $
NON-OWNED AUTOS Per accident)
GARAGE LIABILITY PROPERTY $ {!(
DAMAGE
EXCESS LIABILITY EACH AGGREGATE
OCCURRENCE
OTHER THAN UMBRELLA FORM
WORKER'S COMPENSATION P C`19�?388 1 0/0 i/910 1 0/01/19 1 STATUTORY
S 1 000 (EACH ACCIDENT)
AND $ 1000
EMPLOYERS'LIABILITY (DISEASE—POLICY LIMIT)
$ 1000 (DISEASE—EACH EMPLOYEE)
OTHER
DESCRIPTION OF OPERATIONS!LOCATIONSNENICLESIRESTRICTIONS!SPECML ITEMS
4w. Handicap Ramp Ins't$1I$tion,
Proj$+ct*?1-9401r File No. 9e, S25
_xN WE i4 a
, _
, 777,
d -k
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRAj1DN DATE THEREOF, THE ISSUING COMPANY WILL
City of Cupertino MAIL - DAYS WRITTEN NOTICE i O THE CERTIFICATE HOLDER NAMED TO THE
10300 Torres Avenue LEFT,
Cupertino, CA 95014
UPON M15U1w_F#"1q1!3.,
AUT14ORI
Eastman
r
BIDDERS PF40POSAL PAGE
SIDEWALK GRMING
PRd7Ex,'T 91-106
The below named and undersigned bidder hereby proposes to do all work
required to acmplete the said work in accordance with the specifications
and/or plans for the amounts set forth herein on the incorporated
schedule.
All necessary preparation as well as cleanup is included in the prices bid
and no extra c upensation will be allowed. All work will be done in a
workmanlike manner and will meet or exceed the embodied requirements
and/or the standards stipulated by the City Engineer
The undersigned also understands that the quantities shown below are
estimates only, being given as a basis for the extension of the unit
prig bid. The extension will be the basis for coaparison of bids by the
Director of Public Works.
The work to be done consists of furnishing all labor, methods, or process,
tools, machinery and material required to complete the sidewalk grinding
as described in the Special Provisions.
BID EST. QFI'Y.
ITEM UNIT UNIT PRICE 'DOTAL
1. 959 Ea Provide for grinding of P.C.C. $ t'O(D /Ea 9 L4 .o=
sidewalk where displacement is
greater than O" and less than
or equal to Zee
FaRT-i -SLVt:-w LL-ate_
H 5 do
TOTAL BID: - 013 , -
BID PROPOSAL PAGE 1 OF 6
I, the ignEd agree that if this proposal is accepted, I will
enter into a contract, with the City of Q4x tiro to provide all necessary
machinery, tools, apparatus, and other means of oanstructitm and to do all
the work sp�—ified in the contract in the manner and time specified.
I, the undersigned declare that this bid is made without connection
with any person, firm, or corporation making a bid for the same work, and
is in all respects fair, and without collusion or fraud.
I, the undersigned recognize that the Director of Public Works of
the City of Cupertino will reserve the right to establish the priority of
one job over another and each starting date where conflict of construction
schedules occur.
Attached hereto is the required certified check or bid bond in the
amount of $ /(:) !% , as required by law and the Notice to Bidders
(10% of bid amount)
BID PROPOSAL PAGE 2 OF 6
A. BID DOOMS, Continued
BIDDER QUALIFICATION FXM
In further compliance with the specifications furnished, the
undersigned submits the following statements as to his experienm and to
his qualifications as a part of this proposal, and the truthfulness and
utterance of the information is hereby guaranteed.
(1) How many years has your organization been in
business under its present name? 19
(2) How many years experience in work tearable with
that required under the proposed contract has your
organization had by this or any other nacre? 3 o -t--
(3) Contractor's License No. 3,7 Co O O a ,
State of California, Classification /a+ �C�
Expiration Date IT -3 l -cf 1
(4) List work similar in character to that required in the
proposed contract which your organization or personnel in
your organization has completed within the past 3 years.
Year Class, Location of Work and for Whom Performed Contract Amount
`1� � _ ,L <C � 7 ,
`DA 0-,� FRC-cvloNT,�Svnc CUAC( REF)F1►R a&6211 12.
'3%j 1. "rrg C-S TBLRKELL-i Z�n�-LvRu:i<-PAt(Z �B3U.
0 C(T,, 0� CQPCRTI NU AeA Q)ICFW AMPS 25,Sa 3,
�— rn�C�LLLFN RO�i7 ��
b�'1 0-1 TL, �S �'U�l�. l�� STc l -k w G RU�� �c� t Lt -
BID PROPOSAL PAGE 3 OF 6
A. BID DOCLMM, Continued
Nam of PSed , if any
(Section 4104, Gcvm: att Code)
1. w0mff
2.
3.
4.
5.
6.
Address if Shop cr Office of Sub-Contractors
(Section 4104, Government Code)
1.
2.
3.
4.
5.
6.
Work to be Ferfa med by Sib-Contractors
(Section 4104, Government Code)
1.
2.
3.
4.
5.
6.
BID PROPOSAL PAGE 4 OF 6
A. ID •:•• fz' C.r
37 YOUr M INDIVIDML, -• STATE. YOU -E A FIRM OR
SME MW FIM ME
1D IMT THE L 1: OF 1• D ! CO-PARTNERS
AISO NOW •. FHWMW, SEI1Y-MRMMM AND NANAGM. THE OMWORATE
SEAL MW BE AMM. THE M=CN CMADW IN MIS BID IS BEING MADE
MER PENALTY 1. • - I•Z
TYPE OF BMINESS: Indivictial:
r•1 .rwation
Joint - r 1 -
other
Dr •-
_F.
Name and Signature of Bidder:
(Sic : 1
Address (Both mailiM. 'and location ad&wses) :
C)•
- }. • Number:
r
Date: _L
Ad&-Txbs ..
BID PROPOSAL PAGE
N+ NOOLLUSIC3 AFFMAVIT TO BE EXECUrED BY
BIDDER AND SUHMMW WrM BID
State of California ss.
County Of ALAAILDA
FR to K. SE Q. C—i� being first duly swam, deposes
and says that he or she is �.�c,Dca ar of P�; r r'6NSTRycxryw.Lluc,
the party making the foregoing bid that the bid is not made in the
interest of, or on behalf of, any undisclosed person, partnership,
many, association, organization, or corporation; that the bid is
genuine and not collusive or sham; that the bidder has not directly or
indirectly induced or solicited any other bidder to put in a false or sham
bid, and has not directly or indirectly colludxi, conspired, connived, or
agreed with any bidder or anyone else to put in a sham bid, or that anyone
shall refrain from bidding; that the bidder has not in awry manner,
directly or indirectly, sought by agreement, eoammniicaticn, or conference
with anyone to fix the bid price of the bidder or any other bidder, or to
fix any overhead, profit, or cost element of the bid price, or of that of
any other bidder, or to secure any advantage against the public body
awarding the contract of anyone interest in the proposed contract; that
all statements contained in the bid are true; and, further, that the
bidder has not, directly or indirectly, submitted his or her bid price or
any breakdown thereof, or the contents thereof, or divulged information or
data relative thereto, or paid, and will not pay, any fee to any
corporation, partnership, company association, organization, bid
depository, or to any member or agent thereof to effectuate a collusive or
sham bid.
Name and Signature of Bidder:
(Print)
_ fir
(Signature)
Date: FL-ayaizc) t
BID PROPOSAL PAGE 6 OF 6
li, 0-1
RundNo...............................
Fid-litv and Deposit CompanYJ
HOME OFFICE OF MARYLAND DAL TLMORE, AID. 21203
BID BOND
KNOW ALL INIEN BY THESE PRESENTS-.
That we.................. ...........2..&...F—00NSX-RlJZT1QN.,...1b1C....................... ......................................................................
(A CALIFORNIA CORPORATION)
....................................... ........................................................................................................................................................
........................-.....................................................I..............I as Principal. (hereinafter called the "Principal"), and
the kIDELITY AND DEV051T COMPANY OF IMARYLAND, of Baltimore, Maryland, a corporation duly organized
under the laws of the State of Maryland, as Surety, (hereinafter called the"Surety"),are held and firmly bound
unto.............................-CITY OF CUPERTINO
.....................I......................I...........................................................................................................
..................................................................... ....................................................... ................................................................
...............................................................................................................as Obligee, (hereinafter called the "Obligee"),
in the sum of...TEN PER CENT OF THE AIMOUNT BID ----------- Dollars
...-i------I *-----------------------**................... .........-for the payment 0 which sum well and truly to be made, the said Principal and the said Surety, bind ourselves,
our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these pr,-sentg.
WHEREAS, the Principal has submitted a bid for- ...P.R.O.J-E.C.T...91-.1.06......I.......................................................... .....
.................................................................................... ....... ..1J1D.E14ALI'..GH.1NDJ-NC.........................................................
............................................ .................. .................................................................................................................................
........I.....................................I.....I.......... ................................................................................................................................
.........................................—........... .......--.............................................................................................................................
NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into
a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be
specified in the bidding or contract documents with good and sufficient surety for the faithful performance of
such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the
event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal
shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said
bid and such larger amount for which the Obligee may in good faith contract with another party to perform
the work covered by said bid, then this obligation shall be null and vaid,otherwise to remain in full force and effect.
Signed and scaled this..................A.2.th......-.........................day of...................UBUARY..............A.D. 19....91..
STATE OF CALIFORNIA
COUNTY OF CONTRA COSTA SS.
On before me,a Notary Public,
personally appeared ALAN XAM2BELL___
personally known to me (or proved to me on the basis of satisfactory evidence), to be the person whose
name is subscribed to this instrument as attorney-in-fact
01,
-l2EFDS1T-jWMFANy-QF--MARY1AND
and acknowledged;tc, me that he (she) subscribed the corporation named thereto as Sjvrqty and his (her)
own name as attorney-in-fact,
NOTARY PUBLIC
Power of Attorney
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
NO►AE OFHCE.RAULMOQE.MO.
KNOt<'ALL Ali Ill•THESE PRESENTS:Thal the FIDELITY AND UE11C)SIT CONIVANY OF MAItYLAND,a corporation of the
State of Maryland,by C. M. PECQT, JR. , Vice-President,and C. W. ROBBINS
Assistant Secretary,in pursuance of culhor:ly granted by Article Vf,Section 2,of the By•Laws of said Company,which
reads Its follows:
"7he Chairmas of lisp Bnad,or the President,or Guy Executive. Vice-president•ter any of lite Senior Vice-Presidents or V.-;e-Presidents
speridty autbori:cd v+to du by the Board of Directors or by the Executive Committee,shall have power•by end with lite concurrenrp of the Secretary
or any one of the A.•istanr Secretaries.to appoint Resident Vice-Presrdeuts•Assistant Vice-presidents sad Attorneys-in-fact as ilia business of the
Company may require,at to eullwrixe any Irerseen or protons to execute nit behalf of the Company an, hoods,Undertakings,rrcognitanees,
stipulations,pulicirs•cnuuarts•agreements.Jeeds,and releases anti assignments of judgements,decrees,mortgages and instruments in the nalure of
mortgages....send to affix the seat of the Compaq thereto."
does hereby notninalt:constitute arid appoint J. Alan Campbell of Walnut Creek, California
1 s rue all lawful agctrt arid Altorney•in•Fact,to make,execute,seal and deliver,for,and on its behalfas surety,and as
its act and dccd:atty and all bonds and undertakings.. . . . . . . . . . . . > . . . . . . . . . . .
lTitiThe exccufiun of such bonds or undertakings in pursuance of these present.. +l he "ng upon said
Company,as fully and amply,to all intents and purposes,as if they hnd been duly evecaveai ar..•i acl:r.cwlcdged by the
regularly elcocd officers of the Company at its office in Uallimore, Aid.,in their or.. .:.oprr nerscit-
The said Assisunt Secretory does hereby certify that the+foregoing is s true copy of Article VI,Section 2,of the By-Laws of said Company,one-.',is
now in force.
IN WITNESS 1V►MIEf1F,the said Vice-President and Assistant Secretary have hereunto subscribed their names and
affixed file Corporale Seal of life said FIDELITY AND UEPOSI•r COMPANY OF MARYLAND, this ..........7$t! day
of..................January....................., A.U. 19.55....
• + A•e FIDELITY AND DEPOSIT COAII'ANY OF.AIAIII'LAND
t►JPyotrnr.i4 ATIF.ST: ,
FA
.a
' ' SEAL
"' r co U (�4
r
y
Secrets D'nce•Preudent
SrATEOrPIAP.YLtND ? SS:
CITY OF BALTIMORE l
On this 7 t h day of January A.U. 1135 .before flee sultecrlher,a Notary public of Ibe Sin 1e OtI filaryland,in
slid for the Cily of Ilnitintore,duly commissioned and qualified.canoe Ilse shove-named Vice-President and Assistant Secretory of lite FLDrUTT AND
DrrosiT COMt'ANY OF MARYLAND,to me-perennelty known to be the inJividunts and officers described in an I who exrculed the precedi•.p instrument,
and they each acknetwiedged the executson of the.same,and I;eing he-Otte.ihtly sworn,severally and each for himself deposeth end snits,that they are
file said offierrs of the Co+npany aforesaid.sod Chia ttte seal affixed 10 the preceding inslroment is the Corporate Sent of said Company,and that tilt
as id Corporate Seal and their signal ores as such officers wets duly affixed and subscribed to the said instrument by die author icy and direction of the
laid Corpoution.
IN TESTIMONY W111.11LUr,I leave ltercuselle set my land and affixed by Officia)Seal,At Ibe Gty oo e,t e day slid car Brat above written.
r_
�:Moises:\ ..................................t. .............Ju.......2......1...8.....
!Votary Public Comallssion Expires..Y. Y.............F...4....
CERTIFICATE
1,the ta side rsignrtl,Aisisfatel Secretary of flee FIDELITY AND DFTUS1T COMPANT or 11IARYl.AND,do hereby certify that the original Polite, ,
Allce•otney of which lite foregoing is a full,true and correct copy,is in full force.and effect on the date of this cep lificnte;end I do strther certify that n..a
Vi President who eseculed ilia said Power of o Attorney was clue of Ibe additional Vice-Presidenls aperiallie authorised by the Ilonrd of Directors to
appoint any Allorney-in•1'4ct as provided in Article Vt.Section 2 of he By.Laws of flee FIDELITY AND DFTUSIT COMPANY Or MARYLAND.
This Certificate may br signed by facsimile utnler end by authority of the following resolution of 16e Board of Directors of lite FIDEUTT AND
Urrostr COMPANY nr MARTIAND al a meeting duly called and held on the lGth day of July,1969.
Rrso1 vED:'"Thal ilia facsimile or mechanically reproduced signature of any Asaislartf Secretary of Ilse Company,whelher made hetelofore or
hereafter,wherever appearing upon a certified copy of any rower of senorney issued by Ilse Company,anal)be valid sold binding upon Ilse Company
with die soma force aced effect as though manually affixed.' 12th
IN TESTIMONY WilALUr.I have hereunto►ubecrileed my name slid seUixed lire corporate seat of the said Company,this...................... day
of............FEBRUARY ................19...91
...........:........................ .. .. ............................. .........
u4nit_or016-4 736 efssirfmt Sr
t
%'t 11 io, Jill ,
BondNo.................................
r
Fidelity and Deposit Company
HOME OFFICE OF MARY.LAND BALTI,4IORE•, AID. 21203
BID BOND
KNOW ALL MEN B Y THESE PRESENTS:
Thatwe..............................P..&... ..CD.NSTRU.GTIIIN.,...1XC_.............................................................................................
(A CALIFORNIA CORPORATION)
............................................................................................................................................................................................
............................................................................................... as Principal, (hereinafter called the "Principal"), and
the FIDELITY AND Di.-POSIT COMPANY OF A'IARYLAND, of Baltimore, INIarvland, a co.-poration duly organized
under the laws of the State of 'Maryland, as Surety, (hereinafter called the "Surety"),are held and firmly bound
unto.................................CITY OF CUPERTINO
.........................................................................................................................................................
...........................................................................................................................................•----•----.............................................
...............................................................................•-------•---.......................as Obligee, (hereinafter called the "Obligee"),
in the sum of...TEN PER CENT OF THE AMOUNT BID ----------------------Dollars (S....107- ----- ),
................
for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves,
our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
WHEREAS; the Principal has submitted a bid for.....Uq-11 CT 9.1,-106
.................................................................................................5IU EWALL..GILND.LNG................._....................._..................
................................................................................................................................................... ..............................................
..................................................................................................................................................................................................
--------••-•............................................................................................................................................•.............._.._...-........-.........
NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into
a contract with the Obligee in accordance with the terms of such bid and give such Jond or bonds as may be
specified in the bidding or contract documents with good and sufficient surety for the faithful performance of
such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the
event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal
shall pay to the Obligee the difference not to exceed the penalty hereof t7etu,een the amount specified in said
bid and such larger amount for which the Obligee may in good faith contract with another party to perform
the work covered by said bid,then this obligation shall be null and !oid,othenYise to remain in full force and effect.
Signed and scaled this ..... 1'......................................day of...................F.l~ RUARY..............A.D. 19....91..
P -& F CONSTRUCTION, INC. (SEAL
Principal
Witness BY �
,. ...... ii Title
FIDELITY AND DEPOSIT COMPANY-OF INIARYLAND
Sufcl y
.............................................................................................. By.......... !.-.........................(SEAL)
I'Vih7css J. ALAN CAMPBELL Tillc
ATTORNEY-IN-FACT
C323d--150At.
Approved by The American Institute of Architects.
A.I.A. Document No.A-310 February 1970 Edition.
CITY OF CUPERTINO
DEPARn4W OF PUBLIC WOM
CALM, FOR BIDS
SPBQFIc�TIONS FM SIDE NUX tRINDDiG
PF47EX.'I' 91-106
BID OPENING
DEPAR'IPIF3JP OF PUBLIC WMS
3UESDAY
FEB 12, 1991
2:00 P.M.
Bert J. Viskovich
Director of Public Works
City of Cupp..rti.no - Department of Public Works
10300 Torre Pvenie
Cupertino, CA 95014
File: 50,321
TABLE OF OQNZEtM
OMRY1ACr DOCLZgItTiS
A. BID DOC %WM
1. Notioe to Contractors
2. Proposal
B. GENERAL PROVISIONS
1. Definition of Terms
2. Prosecution and Progress
3. Control of Work
4. Control of Materials
5. Legal Relations and Responsibilities to the Public
6. Proposal Requirements and Award of Contract
C. SPECIAL PROjTISIONS
1. Location
2. Soope of Work
3. Estimated Quantities
4. Explanation of Bid Items
5. Limits of Work
6. Time of deletion/Liquidated Damages
7. Payment
8. Protection of Property
t D
NariC1E TO C10NTi2A=WSS
City of Cupertino
10300 Torre Avenue
04->artino, California 95014
SIDEWALK GRINDING
PRCI7DGT 91-106
The City of Cupertino, Santa Clara County, California invites sealed
proposals for the construction of the work delineated on the Plans or in
the Specifications, entitled, SIDERAIIC CLING PRO► = 91-106.
Said sealed proposals will be received at the office of the City Clerk,
Room 205, City Hall, City of Cupertino. California, until 2:00 P.M.
ZUESDAY, Feb. 12, 1991 at which time they will be publicly opened and the
comparative totals read.
All bids received will be reported to the City Council of 0.4)extino within
thirty (30) days of receipt, at which time the Council will review and act
upon the bids submitted. Award, if any, will be to the lowest responsible
bidder.
Payment will be made in cash by said City upon submission by the
Contractor and approval by the Engineer of a progress billing which
reflects the value of the work L.s pleted. The progress payments made as
work progresses will be payments on account and will not be considered as
an acceptance of any part of the materials or workmanship required by the
Contract. Pursuant to Section 4590 of the California Government Code, the
Contractor will be permitted, at its request and sole expense, to
substitute securities for any monies withheld by the City to ensure
performance under the contract. Said securities will be deposited either
with the City or with a State or Federally chartered bank as escrow
agent. Securities eligible for this substitution are those listed in
Section 16430 of the California Government Code or bank or savings and
loan certificates of deposit, interest bearing demand deposit accounts,
standby letters of credit, or any other security mutually agreed to by the
Contractor and the City. The Contractor shall be the beneficial owner of
any securities substituted for monies withheld and shall receive any
interest thereon.
All proposals or bids shall be accapanied by a cashier's or certified
check payable to the order of the City of Cupertino, amounting to ten (10)
percent of the bid, or by a bond in said amount and payable to the City,
signed by the bidder and a corporate surety, or by the bidder and two
sureties who shall justify before any officer competent to administer an
oath, in double said amount and over and above all statutory exemptions.
Said check shall be forfeited or said bond shall became payable to the
City in case the bidder depositing the sane does not, within ten (10) days
after written notice that the contract has been awarded to him, enter into
a contract with the City.
i r
Notice to Contractors Page #2
CIMItractor shall furnish to City a faithful performance bond and a labor
and raterial bond as required in said specifications.
It shall be mandatory upon the Contractor to whom the contract is awarded,
and upon subcontractors under him to pay not less than said general
prevailing rates of per diem wages to all laborers, workmen, and mechanics
employed in the execution of the Contract.
All bias shall be oompared using the estimate of quantities prepared by
the Engineer of Work and the unit prices submitted. No Mete nor
Interlineated proposal or bid will be accepted. Bidders are required to
bid on all items of the proposal.
No bid will be accepted from a contractor who has not been lid in
a000rdance with the provisions of Chapter 9 of Division 3 of the Business
and Professions Code of the State of California.
The contract shall not be awarded to any bidder who does not possess the
Proper Classification of license.
Special attention of bidders is directed to Section 6 for full directions
as to bidding.
Plans, Specifications and Contract Documents may be reviewed and copies of
sane may be obtained at the office of. the City Engineer, City Hall,
Cupertino, California, upon deposit tr!.refore of $5.00 per set, none of
which deposit will be refunded.
The City of 04)ertino reserves the right to reject any or all bids, and
further reserves the riot to delete any item or items from tree proposal
or to increase or decrease the quantity of any item thereof.
CITY OF CTJPUCM
'1
l r
Date: t�, ;.c. c y Y / By: � � �►/�.�_ l �e,1
City Clerk
Publish: Cupertino Courier
Jan. 30, 1991
Feb 6, 1991
� 6
BMDERS PROPOSAL PAGE
SIDE49" GRINDING
PROTECT 91-106
GENTLEMEN:
The below named and undersigned bidder hereby pies to do all work
required to complete the said work in accordance with the specifications
and/or plans for the amounts set forth, herein on the incorporated
schedule.
All necessary preparation as well as clearer is included in the prices bid
and no extra compensation will be allowed. All work will be done in a
workmanlike manner and will meet or exceed the tmftdied requirements
and/or the standards stipulated by the City Engineer
The undersigned also understands that the quantities Ehcwn below are
estimates only, bein5 given as a basis for the extension of the unit
prices bid. The extension will be the basis for comparison of bids by the
Director of Public works.
The work to be done consists of furnishing all labor, methods, or process,
tools, machinery and material required to ccmplete the sidewalk grinding
as described in the special Provisions.
BID PST. QTY.
ITEM UNTT UNIT PRICE TOTAL
1. 959 Ea Provide for grinding of. P.C.C. $ 50,oy /Ea $ 4 14
sidewalk where displacement is
greater than 011 and less than
or equal to 211
Flr-T-r -,P, S A Uu Ucl �
y 71 `150 .�c7
TEAL BID: $-
BID PRopOSAL PAGE 1 OF 6
U
r �
I, the undersigned agree that if this proposal is accepted, I will
enter into a oortact with the City of CLqxwtino to provide all necessary
maehir .1, tools, appamtus, and other means of constructicn and to do all
the work specified in the contract in the manner and time specified.
I, the undersigned declare that this bid is made without connection
with any person, firm, or corporation making a bid for the same work, and
is in all respects fair, and without collusion or fraud.
I, the undersigned recognize that the Director of Public Works of
the city of Cupertino will reserve the right to establish the priority of
one job over another and each starting date where conflict of construction
schedules occur.
Attached hereto is the required certified check or Qid band in the
amount of $ 4,� 3xd , as required by law and the Notice to Bidders
(10% of bid amount)
BID PROPOSAL PAGE 2 OF 6
� D
A. DLL LdK.iA•iGL`lLJ, 011ti11 ed
BIDDER FM;K
In further maj;lianae With the specifications furnished, the
undersigned submts the following statem %ts as to his experience and to
his qualifications as a part of this proposal, and the truthfulness and
utterance of the information is hereby guaranteed.
(1) How many years has your organization been in
business under its present rkme?
(2) How many years experience in work comparable with
that required under the proposed contract has your
organization had by this or any other name?
(3) c'mY ractor's Lioense No. 1 C,,- i�--C
State of California, Classification Tj �_.
Expiration Date "_ `t -;,,
(4) Dist work similar in cd1aractex to that required in the
poop d contract which your organization or persmiel in
Your organization has completed within the past 3 years.
Year Class, Location of Work and for v&= Perfanned Contract Amount
LP
BID PROPOSAL PAGE 3 OF 6
F"JOB10: JOB(OWNER) : CONT. DAT17-:
JOB DESCs MONEY: `
JOB#:- 0885 JOB(OWNER) : CITY OF UNION CITY CONT. DATE: 9-19-90
108 DESC: TRANSIT 'SYSTEM BUS SHELTERS PROD. 68-19 MONEY: $78, 065. 0.7
"s 0886 JOB(OWNER) s COUNTY OF SANTA CLARA CONT. DATE: 10-10-90
JOB DESC s BUS STOP RESTORATION, VICTORIA DR. M'9�i-•48 MONEY: $10, 100. 88
JOB#s 0867 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 10-16-90
JOB DESC: DRAINAGE MODIFICATION CERONE COACH DIV. M90-49 MONEY: $6, 441. 00
JOB#: 0888 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 10-22-90
JOB DESC: EROISION CONTROL/ALDERCROFT HEIGHTS M90-50 MONEY: $13, 000. 00
JOB#: 0889 JOB(OWNER) : IBM CORPORATION CONT. DATE: i1/1/90
JOB DESCs BLDG 26 DOCK REPAIR P. O. K4718 --D.3 MONEY : $20, 74.3. 00
JOB#: 0890 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 11-2-90
JOB DESCs INSTALLATION OF FACILITIES tt 3 PARK & RIDE LOTS TD90-17 MONEY: $334, 1
JOB#: 0891 JOB(OWNER) : CITY OF SUNNYVAI_E: CONT. DATE: 11-9-90
JOB DESC: CURBS, GUTTERS, & SIDEWALKS "P." ST90-1 MONEY: $38, 44(_,. 00
JOB#: 0892 JOB(OWNER) : COUNTY OF SANTA CLLARA C;ON'T. DATE: 11-9-90
JOB DESC: WORK AT JUVENILE HALL MONEY: $1 C)(..), 1.25. 00
JOB#s 0893 JOB(OWNER) : COUNTY OF SANTA G'L.ARA CONT. DATE: 11-14-90
JOB DESC: BUS STOP IMPROVEMENTS (3) M90-51, 52,, & 53 MONEY: $24, 602. 03
F
Jn9#s 0894 JOB(OWNER) : IBM CORPORATION F: 1. 1-21—90
DESC s REMODEL OFFICES AT BLDG. (J88 MC)Nt_.\': y,�;:;, 7 3i i, 00
JOB#: 0895 JOB(OWNER) : IBM CORPORAT 1OIL i O'NT, Dwm: 1 1-27-`- 0
JOB DESC: MISC. CONCRETE REPAIRS/SK 495E5D4 MONEY:
JOB#: 0896 JOF(OWNER) : THOMAS BURKE CONT , DATE: 12-7-90
JOB DESC: GABIANS/MT EDEN ESTATES IhL7nIi: Y: s 5o. (',(_,
JOB#: 0897 J'J'B(OWPIER) : HEWLETT PACKARD CONT. DATE: 1E-11-90
JIB DESC: POOL HOUSE PROJECT/SANTA CLARA MONEY- $I2:', 287. 00
JOB#: 0898 JOB(OWNER) : BLACKWEL L HOMES CONT. DATE: 1 -17-9(?
JOB DESC: INSTALL PRE-FABRICATED BRIDGE: MONEY: $28, 728. 00
JOB#: 0899 JOB(OWNER) : CITY OF SAN ,fOSE CONT. DATE: 12-20-9c',
JOB DESC: B-3 EXTRUDED CURBING MONEY.
JOB#: 0900 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE:
JOB DESC: WALL COATING AT VALLEY MEDICAL PO (12604 5 MONEY: $6, 7'71. 0C-)
JOB#: 0901 JOB(OWNER) : CITY OF SAN ,POSE CONT. DATE_: 1-30-91
JOB DESC s SJ/SC WPCP STRUCTURAL REHAB, CONCRETE. & GRATING MONEY: $.156; 895. 0i i
JOB#: 0902 JOB(OWNER) s IBM CORPORATION CONT. DATE: 2-4-91
JOB DESC: TIME AND MATERIAL JOBS MONEY:
j7k+
D9N8 -0864 JOB(OWNER) s CITY OF CUPERTINO CONT. DATES 4-10-90
%TOB ESCs CURBS' GUTTERS & SIDEWALKS, PROJECT 90-102 MONEY: $164,975. 34
"JOBNsr0865 JOB(OWNER) s VALLEY MEDICAL CENTER CONT. DATEe 4-19-90
w .Tl"ql DESCs INTERIUM EMERGENCY ROOM WORK P.O. 025519 MONEY: $51,526.00
:JO®8t. 0866 JOB(OWNER) s GRANITEROCK CONT. DATEe 4-20-90
®8'DESCa REMODEL REDWOOD CITY OFFICE MONEYS $15, 722. 00
t.
JOBBs 0867 JOB(OWNER) s IBM CORPORATION CONT. DATEs 4-24-90
j JOB DESCs MISC. CONCRETE WORK AT COTTLE FACILITIES MONEY: $50,000.00
JOB*x 0868 JOB(OWNER) : UNITED TECHNOLOGY SYSTEMS CONT. DATE: 4-26-90
JOB DESCs SEISMAC REPAIRS TO BLDG 0650 MONEY: $18, 611. 00
JOBBs 0869 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 5-15-90
JOB DESC: PARKING GARAGE REPAIRS MONEY: $9, 361. 00
JOB#is 0870 JOB(OWNER) s COUNTY OF SANTA CLARA CONT. DATE: 5-17-90
JOB DESC: GUADALUPE CORRIDOR PHgSE III, TD 90-13 MONEY: $412, 795. 22
s JOB#s 0871 JOB(OWNER) : SANTA CLARA VALLEY WATER DIST CONT. DATEe 5-23-90
r:
JOB �DESC: CARBON SLURRY SYSTEM AT PENITENCIA WATER PLANT MONEY: $138,317. 00
'; JOB##s 0872 JOB(OWNER) s COUNTY OF SANTA CLARA CONT. DATE: 5-31-90
JOB DESCs VALLEY MEDICAL CENTER/SEISMIC BRACING MONEYS $25, 000. 00
JOB#ts 0873 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 6-8-90
JOB DESCs BUS STOP IMPROtIEMrr-NT M90-35 MONEY: $8, 113. 40
�#is 0874 JOB(OWNER) s CITY OF SAN JOSE CONT. DATE: 6-11-90
DESC: MEDIAN ISLAND CONSTRUCTION MONEY: $5, 895. 00
t '`'JOB#3s 0875 JOB(OWNER) : WEST VALLEY CONSTRUCTION CONT. DATE: 6—IS-90
JOB DESC: TIME AND MATERIAL JOBS MONEY: $50, 000. 00
JOB# i 0876 JOB(OWNER) : BLACKWELL HOMES CONT. DATE: 6-19-90
JOB DESC: BOX CULVERTS — WEST OF GRAND MEADOWS LANE MONEY: $202,205. 53
JOB#to 0877 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 7-2--90
JOB DESCt INSTALL TYPE 50 CONCRETE BARRIERS M 90-36 MONEY: $34, 093.' 50
JOB#t: 0878 JOB(OWNER) : GRANITEROCK CONT. DATE: 7-9-90
JOB DESC: CAPITOL ASPHALT PLANT/WALLS MONEY: $102,835. 00
JOB#1s 0879 JOB(OWNER) : CITY OF SAN JOSE CONT. DATE: 7-24-90
JOB DESC: PC BERM/4C SIDEWALK/CHENOWETH MONEY: $5, 500. 00
JOB# $ 0880 JOB(OWNER) a COUNTY OF SANTA CLARA CON—. DATES 8-6-90
JOB DESC: EARTHQUAKE REPAIRS TO RUNDELL CREEK BRIDGE MONEY: $121,890. 00
JOB##: 0881 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 8-6-90
JOB DESCs BRIDGE GUARD RAIL REPLACEMENT\MCKEAN ROAD M90-39 140NEYs $23j019. S0
'JOB##: 0882 JOB(OWNER) a NEW UNITED MOTORS CONT. DATE: 8-6-90
JOB DESCs CONCRETE REPAIR WORK MONEY: $7, 901. 26
8tm-008 0883 JOB(OWNER) s COUNTY OF SANTA CLARA CONT. DATE: 8-30—90
JOB DESC: BUS STOP IMPROVEMENTS M90--44 & M90-45 MONEY: t17,071. 10
JOB#es 0884 JOB(OWNER) s CITY OF SAN JOSE CONT. DATE: 9-12-90
JOB DESCs SIDEWALK WORK AT COPELAND -* ^nIVALIER MONEY: $9, 433. 00
91-007 SIDEWALK GRINDING 2 of 2
PROJ. 91-106
JOB#: JOB(OWNER) : CONT. DATE:
JOB DESC: MONEY:
:"^n#: 0844 JOB(OWNER) : THERMA CORPORTION CONT. DATE: 12-18-89
DESC a WORK AT IBM BLDG. 110 MONEY: $3, 000. 00
JOB#6: 0845 JOB(OWNER) : COUNTY- OF SANTA CLARA CONT. DATE: 12-28-89
JOB DESC: SCHALLENBERGER ROAD YARD MOD. MONEY: $22, 150.00
JOB#is 0846 JOB(OWNER) : MASS ELECTRIC CONT. DATE: 1-4-90
JOB DESC: P. O. WORK MONEY: $30, 000. 00
JOB#5s 0847 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 1-4-90
JOB DESC: BUS STOP IMPROVEMENTS M89-61 MONEY: $7, 594. 00
JOB#: 0848 JOB(OWNER) : IBM CORPORATION CONT. DATE: 1-4-90
JOB DESC: MISC. CONCRETE WORK P. O. #SJ30375D4 MONEY: $21, 477. 00
JOB#: 0849 JOB(OWNER) : UTC/CHEMICAL SYSTEMS CONT. DATE: 1-4-90
JOB DESC: STRUCTURAL REPAIRS STA 0050 MONEY: $64, 674. 00
JOB##: 0850 JOB(OWNER) : WEST VALLEY CONSTRUCTION CONT. DATE: 1-4•-90
JOB DESC: PALO ALTO TANK REPAIR MONEY: $20. 246. 00
JOB#: 0851 JOB(OWNER) : TMERMA CORPORATION CONT. DP,TE: 01-16-90
JOB DESC: IBM E:OX CAB I NFT "7NEY: $7, 1.30. 00
JOB#: 0852 JOB(OWNER) : IBM CORPORATION CONT. DP:TE: 01-19-90
JOB DESC: BLDG. 067 P. C. 2548664 MONEY: $2, 055. 00
J`,,.i4l: 0853 JOB(OWNER) : IBM CORPORATION CONT. DATE: 2-2-90
JOB DESC: FLOOR DRAINS P.O. MFI9PH MONEY: $8, 800. 00
JOB#: 0854 JOB(OWNER) : SCOTT COMPANY CONT. DATE: 2-2-90
JOB DESC: PIPE SUPPORTS BLDG 4 AT IBM 4*097251-40019 MONEY: $4. 447. 0Ci
JOB#: 0855 JOB(OWNER) : COUNTY OF SANTA CLARA CUNT. DATE: 2-20-90
JOB DESC: EARTHQUAKE DAMAGE REPAIRS TO BRIDGES M90-8 MONEY: $11, 981. 70
JOB#: 0656 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 2-21-90
JOB DESC: SCHALLENBERG YARD MONEY: $11, 560. 00
JOB#: 0857 JOB(OWNER) : IBM CORPORATION CONT. DATE: 2-21-90
JOB DESC: BLDG. 090 ELEVATOR PC 2548671 MONEY: $104, 787. 00
JOB#: 0858 JOB(OWNER) : VALLEY MEDICAL CENTER CUNT. DATE: 2-21-90
JOB DESC: REFIT NURSES STATION MONEY: $20, 354. 40
JOB#: 0859 JOB(OWNER) : IBM CORPORATION CONT. DATE: 2-26-90
JOB DESC: TILE WORK IN VARIOUS LOCATIONS—P. O. K12467-82 MONEY: $9, 500. 00
JOB4s 0860 JOB(OWNER) : IBM CORPORATION CONT. DATE: 3-8-90
JOB DESCs FIRE DOORS AT BLDG 50 SK 12849D4 & SK 13102D4 MONEY: $70, 529. 00
JO"a 0861 JOB(OWNER) : GRADEWAY CONSTRUCTION CONT. DATE: 3-8-90
,DESC: LIGHT RAIL BUS SWELTERS/SCC MONEY: $27, 600. 00
JOB#s 0862 JOB(OWNER) : STATE OF CA/DMV IN LOS GATOS CONT. DATE: 4-2-90
JOB L SSC: REMOVE AND REPLACE SIDEWALK MONEY: $14, 370. 00
JOB# # 0863 JOB(OWNER) : CITY OF SAN JO SE CONT. DATE: 4-4-90
JOB DESCs CURB AND GUTTER WORK MONEY: $20, 00o. Oo
JOB#: JOB(OWNER) : CANT. DATE:
.J[OB -DESC: MONEY:
JOB#: 0824 JOB(OWNER) : COUNTY OF SANTA CLARA CONT, DATE: 10-08-89
JOB DESC: NORTH COACH EMERGENCY REPAIRS MONEY: $5, 000. 00
'.#: 0825 JOB(OWNER) : IBM CORPORATION CONT. DATE: 10-18-89
DESC: EMERGENCY REPAIRS MONEY: $25, 000. 00
JOB#: 0826 JOB(OWNER) : STATE OF CALIFORNIA CONT. DATE: 10-25-69
JOB DESC: EARTHQUAKE REPAIR WORK MONEY: $4, 962. 00
JOB#: 0827 JOB(OWNER) ., GRANITEROCK CONT. DATE: 10-26-89
JOB DESC: EARTHt2UAKE REPAIR WORK MONEY: $2C>. 600. 00
JOB#: 0828 JOB(OWNER) : SAN JOSE WATER WORKS CONT. DPTE: 10-26-89
JOB VESC: EARTHQUAKE REPAIR WORK MONEY: $21. 000. 00
JOB#: 0829 JOB(OWNER) : STATE OF CALIFORNIA CONT. DATE: 10-27-89
JOB DESC: SAN CARLOS TRAIN STATION MONEY: $13, 645. 00
JOB#: 0830 JOB(OWNER) : STATE OF CALIFORNIA CONT. DATE: 1 i_►— 7—89
,JOB DESC: TIME AND MATERIAL JOBS MONEY. R '►:►, c,►i�i►, �1c1
JOB#: 0831 JOB(OWNER) : IBM CORPORATION CONT. DATE: 11 /l /89
JOB DESC: REMODEL BLDG 94) 2548624 MONEY: $ 3. 1 44. ��0
JOB#: 0832 JOB(OWNER) : GEORGE &I ANC;H I CONSTRUCT I ON CONT. DATE: 11110189
JOB DESC: BIANCHI PUMP JOLT MONEY: $2►:►, �:>c_i►';. t';4>
JOB#0: 0833 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 11/15/89
JOB DESC: FAIRGROUND EARTH REMOVAL_ MOl\lEY: �E "a. <►0�►. C,c7
#: 0834 JOB(OWNER) : SAN JOSE WATER WORKS CONT. DATE: 11/15/89
JOB DESC: EARTHEN TANK JOB MONEY: $.310, i(71. (7)0
JOB#: 0835 JOB(OWNER) : CITY OF SUNNYVALE CONT. DATE: 1.1/15/89
JOB DESC: CONCRETE SERVICES FOR PARKS MONEY: 49, O(-)0. 0G
JOB#: 0836 JOB(OWNER) : IBM CORPORATION CONT. DATE: 11— c7-89
JOB DESC: BLDG 100 'STRIP OUT P&C �254865i� MONEY: $33. 708. i 0
JOB#: 01837 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE:
JOB DESC: I NSTALAT I ON OF CURB R GuTTE.R M89-53 MONEY- $27, 21 i�. 00
JOB#: 0838 JOB(OWNER) : VALLEY MEDICAL CENTER CONT. DATE: 11-28-89
JOB DESC: CONCRETE BASE MONEY., $6, 02.7. 96
JOB#: 0839 JOB(OWNER) : SCV MEDICAL CENTER CONT. DATE: 11--3 ►-89
JOB DESC: SIDEWALK CONSTRUCTION MONEY: $8, 202. 00
JOB#: 0840 JOB(OWNER) : CITY OF PAL.O ALTO CONT. DATE: 12-06-89
JOB DESC: TRANSFORMER TIE DOWN AT SUBSTATION MONEY: $44, 445. 18
JOB#: 0841 JOB(OWNER) : COUNTY OF SANTA CLARA CONT. DATE: 12-14-89 '
JOB DESC 3 BUS STOP IMPROVEMENTS MONEY: $6, '264. 00
0842 JOB(OWNER) -. STATE OF CALIFORNIA CONT. DATE.- 12-14-89
DESC: HR. RATE ALAMEDA COUNTY Mt_►NEY: $13, ►:►c.►c_►. tua
JOB#: 0843 JOB(OWNER) : COUNTY OF SANTA t:":..faF2i1 C:C7Nl'. l:)OTE: 12--18-89
.JOLT DESC: SHEAR WALL AT JUVENILE CENTER t+if�W _Y': '!n�'`. , 195. 00
t
A. BID DOC HWM, Cont.iMled
Name of ftqxx;ed If WT
(Section 41 Gavexrmkent Cade)
1.
2.
3.
4.
5.
6.
Address if Shop or Office of Sub�ntractors
(Section 4104, Goverment Code)
1.
2.
3.
4.
5.
6. i
Work to be Perfc by Sub-Contractors
(Section 4104, - t Code)
1.
2.
3.
4.
5.
6.
BID PROPOSAL PAGE 4 OF 6
A. BM DOaMWM, Continued
IF YOU ARE AN IMIV=UAL, SO SVUE. IF YOU ARE A F7M OR CD AFMMLqH3:P,
2 THE f'i. NAM 1R 1JM 7HE NMESIMXVIDURL CD-PARTNERS
SEAL MUSr
AFFIXED. iE INFCMMON ••N: v t 2r IN MS1 IS :Etr. r r
UNDER PEVAIM OF •y• M
TME OF BUSIMSS: Individual:
r•.
Joint - r -
other
(Dwc
• Signature of •,. _
• � � fit..
(Signature)
Address (Both mailing and location addresses) :
0-
TelephoneI' •
Cj
Addendas Received:
BM PROPOSAL PAGEOF
r
NONaOLdIISICK AFFIDAVIT TO BE E}BCE1PID BY
BIMER AND SUMETIM Wrri BID
State of California ss.
County of
n u r� being first duly sworn, deposes
and says that he or she is _ —T ;z,,` ofCCagow d. 2�&A&jszk-c_ b:s-; �L-,-�
the party making the foregoing bid that the bid is not made in the
interest of, or on behalf of, any undisclosed person, partnership,
aampany, association, arganization, or corporation; that the bid is
gentane and not collusive or sham; that the bidder has not directly or
indirectly intaced or solicited any other bidder to put in a false or sham
bid, and has not directly or indirectly colluded, cormpired, connived, or
agreed with any bidder or anyone else to put in a sham bid, or that anyone
shall refrain from bidding; that the bidder has not in any manner,
directly or indirectly, sought by agreement, co tunication, or conference-
with anyone to fix the bid price of the bidder or any other bidder, or to
fix any overhead, profit, or cost element of the bid price, or of that of
any other bidder, or to secure any advantage against the public body
awarding the contract of anyone interest in the proposed contract; that
all statements contained in the bid are true; and, further, that the
bidder has not, directly or indirectly, submitted his or her bid price or
any breakdown thereof, or the contents thereof, or divulged information or
data relative thereto, or paid, and will not pay, any fee to any
corporation, partnership, ca-pany association, organization, bid
depository, or to any member yr agent thereof to effectuate a collusive or
sham bid.
Name and Signature of Bidder:
Lckc
(Print�j—
(Signature)
Date: �,' OC'Lt
BID PROPOSAL PAGE 6 OF 6
A,, GENERA 9ENERA PROVISIONS
3 ADOPTION QE STANDARD SPECIFICATIONS
By this reference, the Standard Specifications of the State of
California, Department of Transportation dated January, 198! (hey.'ein referred
to as "Standard Specifications") is incorporated and adopted as the Standard
Specifications and shall apply together with the modifications contained
herein.
HEADINGS �QI CITATIONS
The section and other headings and citations to the State Standard
Specifications are inserted solely as a matter of convenience and 'are not a
part of the City's Standard Specifications.
3 DEFINITIONS
The definitions and terms outlined in Section 1 of the State Standard
Specifications shall apply with the following modifications:
1-1.:3: "Department" means the City of Cupertino (hereinafter referred to
as "City") .
1-1.15: "Director" means the Director of Public Works/City Engineer, City
of Cupertino (hereinafter referred to as "Engineer") .
1-1.18: "Engineer" means the Director of Public Works/City Engineer, City
of Cupertino, or appointed agent(s) (hereinafter referred to as "Engineer") .
1-1.25: "Laboratory" means the City's approved testing laboratory.
1-1. 32: "Proposal Form" means the form(s) provided by the City and
provided in the Special Provisions of the Project Specifications and upon
which the City requires formal bids be prepared and submitted for the work.
1-1.39: "State" means the City of Cupertino.
4 PROSECUTION &I PROGRESS OF ME WORK
a. Noise Control
Grading, - construction and demolition activities shall be allowed to
exceed the noise limits of Section 10.48.040 of the Cupertino Municipal Code
during daytime hours provided that the equipment utilized has high quality
noise muffler and abatement devices installed and in good condition and the
activity meets one of the following criteria:
1. No individual device produces a noise level more than eighty-nine(39) dBA
at a distance of twenty-five(25) feet from said device.
2. A noise level on any nearby property does not exceed seventy(70) dBA.
General Provisions page 1 of 11
T
L, T+1. oise Contrgl((ont'd)
It is a violation of this chapter to engage in any grading, street
construction or underground utility work within seven hundrea fifty(750) feet
of a residential area on Saturdays, Sundays, Holidays and during the nighttime
period except as provided in Section 10.48.030, emergency exception. Grading,
construction or demolition occuring during nighttime periods shall not be
allowed unless they meet the nighttime standards of Section 10.48.040, daytime
and nighttime maximum noise levels.
b Zrogress of the Work
The contractor shall begin work within fifteen(15) days after recieving
notice that the contract has Seen approved, or upon reciept of notice to
proceed, and shall diligently and continuously prosecute the same to
completion within the number of working or calender days as shown in the
Special Provisions.
of &qcoXd Dras�ings
The Contractor, upon completion of this project, shall furnish and submit
a set of accurate "Record Drawing" plans to the Department of Public Works.
Five(5) sets of "Electrical Schematics" of the traffic signal cabinet and
service equipment enclosure shall be provided by the Contractor on projects
where traffic signals are constructed or modified in any way. These plans
shall show all contract change order work amd all variations in the
construction from the plans provided to the Contractor by the City.
d,. Right of Ha
The right of way for the work to be constructed will be provided by the
City. The Contractor shall make arrangements and pay all expenses fo:
additional area required outside of the limits of right of way.
e,. Suspension of trig Contract
If, at any time, the City determines that the Contractor has failed to
supply an adequate working force or material of proper quality, has failed in
anT other respect to prosecute the work with the diligence and force specified
and intended in and by the terms of the contract, or has failed to comply with
any of the terms of the State Public Contract Code, written notice to correct
any such deficiencies shall be served to the Contractor. Should the Contractor
net,lect or refuse to provide means for a satisfactory compliance with the
contract as directed by the Engineer, within the time specified in such
notice, the City shall have the power to suspend the operation of the
Contractor. Upon recieving notice of such suspension, the Contractor shall
discontinue said work, or such parts of it as the City may designate. Upon
such suspension, the Contractor's control shall terminate, and thereupon the
City of its duly authorized representative may take possession of all or any
part of the Contractor's materials, tools, equipment and appliances upon the
premises, and use the same for the purpose of completing said contract. The
City may employ other parties to carry the contract to completion, employ the
necessary works, hire equipment, substitute other machinery and materials,
General Provisions page 2 of 11
9— Susaenaion oq t1m Contract(Cont'd)
purchase the materials for, and buy such additional materials and supplies at
the Contractor's expense as may be necessary for the proper conduct of the
work and for the completion of the contract.
The City may annul and cancel the contract and relet the work or any part
thereof. _ny excess of cost arising therefrom over and above the contract
price will be charged against the Contractor and the Contractor's sureties,
who will be liable therefore. In the event of such suspension, all money due
the Contractor or retained under terms of this contract shall be forfeited to
the City. Such forfeiture will nbt release the Contractor or sureties from
liability for failure to fulfill the contract. The Contractor and the
Contractor's sureties will be credited with the amount of money so forfeited
toward any excess of cost over and above the contract price, arising from the
suspension of the operations of the contract and the completion of the work by
the City as above provided, and the Contractor will be so credited with any
surplus remaining after all just claims for such completion have been paid.
In the determination of the question whether there has been any such non-
compliance with the contract as to warrant suspension or annulment thereof,
the decision of the City Council of the City of Cupertino shall be binding on
all parties to the contract.
f. Time of Completion ATLd Liquidated Damages
The. work to be performed under this contract shall be completed in
accordance with Section B, paragraph 4b, above. It is agreed by the parties to
the contract that in case all the work called for under the contract, in all
parts and requirements, is not fir..ished or completed within the number of days
as set forth in the Special Provisions, damage will be sustained by the City.
It is further agreed that it is and will be impracticable and extremely
difficult to ascertain and determine the actual damage which the City will
sustain in the event of or by reason of such delay. It Is therefore agreed
that the Contractor will pay to the City, the sum set forth in the Special
Provisions, per day for each and every day of delay in finishing the work in
excess of the number of days prescribed. The Contractor agrees to pay said
liquidated damages herein provided for, and further agrees that the City may
deduct the amount thereof from any monies due or that may become due to the
Contractor under the contract.
It is further agreed that in case the work called for under the contract
is not finished and completed in all parts and requirements within the number
of days specified, the Engineer shall have the right to increase the number of
days or not, as may be deemed in the beat interest of the City. If the
Engineer decides to increase the said number of days, they City shall further
have the right to charge to the Contractor, the Contractor's heirs, assigns or
sureties* the actual cost of engineering, inspection, superintendence, and
other overhead expenses which are directly chargeable to the contract, and
which accrue during the period of such extension. The cost of final surveys
and preparation of final estimate shall not be included in such charges.
The contractor will be granted an extension of time and will not be
assessed with liquidated damages or the cost of engineering and inspection for
any portion of the delay in completion of the work beyond the time named in
General Provisions page 3 of 11
,L 11M 21 Completion and Liquidated Aarna es(Cont'd)
the Special Provisions for the completion of the work caused by acts of God or
of the public enemy, fire, floods, tidal waves, ecrthquakes, epidemics,
quarantine restrictions, strikes, labor disputes, shortages of materials and
freight embargoes, provided, that the Contractor shall notify the Engineer in
writing of the causes of delay within fifteen(15) days from the begining of
any such delay. The Engineer shall ascertain the facts and the extent of the
delay. T'.ie Engineer's findings thereon shall be final and conclusive.
No extension of time will be granted for a delay caused by a shortage of
materials unless the Contractor furnishes to the Engineer documentary proof
that every effort has been made to obtain such materials from all known
sources within reasonable reach of the work in a diligent and timely manner.
Further proof in the form of supplementary progress schedules, as required in
Section 8-1.04 of the State Standard Specifications ("Progress Schedule") ,
that the inability to obtain such materials when originally planned did in
fact cause a delay in the final completion of the entice work, which could not
be compensated for by revising the sequence of the Contractor's operations,
shall be required. The term "shortage of materials," as used ir. this section.
shall aoply only to materials, articles, parts or equipment which are standard
items and are to be incorporat%d in the work. The term "shortage of
materials," shall not apply to materials, parts, articles or equipment which
are processed, made, constructed, fabricated or manufactured to meet the
specific requirements of the contract. Only the physical shortage of material
will be considered under these provisions as a cause for extension of time.
Delays in obtaining materials due to priority in filling orders will not
constitute a shortage of materials.
If the contractor is delayed in completion of the work by reason of
changes made under Section 4-1.0? of the State Standard Specifications
("Changes") , or by failure of the City to acquire or clear right of way, or by
any act of the City, not contemplated by the contract, an extension of time
commensurate with the delay in completion of the work thus caused will be
granted and the Contractor shall be relieved from any claim for liquidated
damages, or engineering and inspection charges or other penalties for the
period covered by such extension of time. The Contractor shall notify the
Engineer in writing of the causes of delay within fifteen(15) days from the
begining of any such delay in order to be releived of said liquidated damages
or other penalties. The Engineer shall ascertain the facts and make findings
regarding the extent of delay. The Engineer's findings shall be final and
conclusive.
Except for additional compensation provided for in Section 8-1.09 of the
State Standard Specifications ("Right of Way Delays") , and except as provided
in Public Contract Code Section 7102, the Contractor shall have no claim for
damage or compensation for any delay or hindrance.
It is the intention of the above provisions that the Contractor shall not
be relieved of liability for liquidated damages or engineering and inspection
charges for any period of delay in completion of the work in excess of that
expressly provided fir in this section. (See State Standard Specifications
Section 8-1.07. 1
General Provisions page 4 of 11
IL C =OZ. QETIZ �Lom
A. AU02KISa LQ Deviate Iron the_ Agproved Plans
In addition to the provisions of Section 5-1.03 of the State Standard
Specifications, deviations from the approved plans or specifications for the
project must be authorized in writing by the Engineer.
b Dust Co t o
The Contractor shall, at all times during construction and until final
completion and acceptance, prevent the formation of an air-borne nuisance by
oiling, watering with non-potable water, or by other satisfactory method, as
required by the Engineer. The Contractor shall treat the site of the work in
such a manner that will confine dust particles to the immediate surface of the
work. The Contractor shall perform such dust control measure within two(2)
hours after notification that the Engineer has determined that an air-borne
dust nuisance exists. If the Contractor fails to abate the nuisance within
two(2) hours, the City of Cupertino may order that dust control measures at
the site be done by City personnel and equipment or by others, and all
expenses incurred in the performance of ais work shall be charged to the
Contractor and paid for by the Contractor.
,c, Inspection
In addition to the provisions of Section 5-1.08 of the State Standard
Specifications, the Contractor shall provide, to the Engineer, all information
respecting the progress of the project. The Contractor shall also furnish
telephone service at all facilities servicing the project.
All work done by the Contractor shall be accomplished between the hours
of 8:00 a.m. and 5:00 p.m. , Monday through Friday, or as specified in the
Special Provisions, unless authorized in writing by the Engineer. Whenever the
Contractor varies the period within the authorized hoi-,rs during which work is
carried on each day, the Contractor shall give due notice to the Engineer, so
that proper inspection may be provided. Any work done in the absence of the
Engineer will be subject to rejection.
Inspection costs for any work done before 8:00 a.m. or after 5:00 p.m. on
a regular work day or on Saturdays, Sundays, or Holidays, shall be paid for by
the Contractor at a rate of thirty-five dollars($35.00) per hour, or latest
rate approved by the City Council, except where such work is specifically
required by the Special Provisions.
Projects financed in whole or in part with state funds shall be subject
to inspection at all times by the State Director of Public Works or the State
Agency involved. (See State Standard Specifications Section 5-1.08. ]
d,, Mo umentation
The Contractor shall properly guard, protect and preserve all street and ,
highway monuments, all property corner and property line monuments and all
U.S.C. & G. S. monuments in their proper places until their removal is
authorized by the Engineer. Any monuments that have been rig°moved without
proper authority shall be replaced at the Contractor's expense.
General Provisions page 5 of 11
2, SaM21as gMd Tests
The source-of supply of each of the materials to be used on the project
shall be approved by the Engineer before delivery is started and before such
material is used in the work. Representative preliminary samples of the
character and quality prescribed shall be submitted by the Contractor or
producer of all materials to be used in the work for testing or examination as
desired by the Engineer.
The Contractor shall furnish such samples of materials as are requested
by the Engineer, without charge. No materials shall be used until it has been
approved by- the Engineer. Additional sampiss may be secured and tested
whenever necessary to determine quality of materials.
All tests of the materials furnished by the Contractor shall be made 'in
accordance with commonly recognized standards of national organizations, and
such special methods and tests as are prescribed in the Special Provisions.
,L Utilities
It is the Contractor's responsibility to verify the location of all
existing utilities . The Contractor shall have all of the utilities,
underground mains, and services that may conflict with the project field
located. The Contractor shall contact Underground Services Alert (USA) forty-
eight(48) hours in advance of any work at (800) 642-2444.
Due caution shall be exercized to insure that underground irrigation
systems, electrical systems, and other utilities on private property are not
damaged during construction of the project. During excavation, appropriate
techniques shall be employed which safeguard all existing utilities and
underground facilities. Damage to such utilities and underground facilities
shall be repaired at the Contractor's expense.
g,. Water fgl Construction
Water used in any way for the construction of the oroject shall be
imported by the Contractor and shall be non-potable water in tanks clearly
marked as such unless specific authorization to deviate has been granted by
the Engineer.
A. LR,G®j, REUTIONS AD RESPONSIBILITIES ZQ MZ PUBLIC
ay,, Contractor's PaXMents
Upon request by the City, the Contractor shall submit reasonable evidence
that all payrolls, materials, bills and other indebtedness connected with the
work have been paid. If any liens against the Contractor for labor or
materials furnished hereunder remain unsatisfied after., final payment by the
City, the Contractor agrees to pay the City all monies that the City may be
compelled to pay in discharging such lien, including all costs and a
reasonable attorney's fee.
General Provisions page 6 of 11
b Insurance ; Putl is Liability eMA Prooerty Damage
Prior to entering into the contract respecting this project, the bidder
to whom the contract is awarded shall furnish to the City Council of the City
of Cupertino satisfactory proof that the bidder has public liability and
property damage insurance in effect for the entire period covered by the
proposed contract. The insurance carrier and forms of insurance shall be
satisfactory to the City.
Said insurance shall name as additional insureds, the City, it's officers
and it's em-ployees and shall protect the City against loss or liability for
damages resulting from (1) bodily injuries, including death resulting
therefrom, accidentally suffered or alleged to have been suffered by any
person or persons not employed by the Contractor, that may be caused directly
or indirectly by the performance of the contract, and (2) on account of injury
to or destruction of property, including the resultant loss or use thereof,
resulting from any act of the City or omission by the Contractor, or otherwise
resulting directly or indirectly from the operations of the Contractor in the
performance of the contract. The policy shall not contain the so-called "x"
"c" "u" exclusions.
The minimum limits of liability for this insurance shall be as indicated
in (a) and (b) as follows:
JFa,,_ch Pe sM ch Occurance AsLregate
a) Bodily Injury Liability $500,000.00 $1,000,000.00
Property Damage Liability $250,000.00 $500,000.00
b) A single limit for Bodily
Injury Liability and Property
Damage Liability Combined of $500,000.00 $500,000.00
Insurance coverage in the minimum amounts set forth herein shall not be
construed to relieve the Contractor from liability in excess of such coverage,
nor shall it preclude the City from taking such other actions as are available
under any other provision of the contract, or otherwise by law, except for the
retainage of monies due the Contractor.
If the Contractor fails to maintain such insurance, the City may take out
such insurance to cover any damages of the above-mentioned types for which the
City might be held liable on account of the Contractor's failure to pay ,,rh
damages, and deduct and retain the amount of the premiums from any sums aue
the Contractor under the contract.
Nothing in the contract i, intended to create the public or any member
thereof a third party beneficiary hereunder, nor is any term and condition or
other provision of the contract intended to establish a standard of care owed
to the public or any member thereof. (See State Standard Specifications
Section 7-1. 12. 1
General Provisions page 7 of 11
c, Labor Nondiscrimination
Attention is directed to the provisions of Section 7-1.O1A(4) of the
State Standard Specifications, which apply. In addition, tha Contractor shall
comply with the recommended minority and female employment practices of the
Office of Federal Contract Compliance of the United States Department of Labor
as established for Santa Clara County.
d,. Responsibility Lo-r Damages
The City of Cupertino, the City Council, the Engineer or the Engineer's
agents shall not be answerable or accountable in any manner for any loss or
damage that may happen to the work, or any part thereof, any material or
equipment used in performing the work, or for injury or damage to any person
or persons, either workers or the public, or for damage to adjoining property
from any cause whatsoever during the progress of the work or at any time
before final acceptance.
The Contractor shall be responsible for any liability imposed by any law
and for injuries to or death of any person including but not limited to
workers and the public, or damage to property resulting from defects or
obstructions or from any cause whatsoever during the progress of the work or
at any time before its completion and final acceptance.
The Contractor shall indemnify and save harmless the City and all
officers and employees thereof from all suits, claims or actions of any name,
kind and ftscription, brought forth, or on account of, injuries to or death of
any person including but not limited to workers and the public, or damage to
property resulting from the performance of a contract, except as otherwise
provided by statute. The duty of the Contractor to indemnify and save harmless
includes the duties to defend as set forth in Section 2778 of the Civil Code.
With respect to third party claims against the Contractor, the Contractor
waives any and all rights to any type of express or implied indemnity against
the City, its officers or employees.
It is the intent of the parties that the Contractor will indemnify and
hold harmless the City, its officers and employees from any and all claims,
suits or actions as set forth above regardless of the existence or degree of
fault or negligence on the part of the City, the Contractor, the subcontractor
or employee of any of these, other than the active negligence of the City, its
officers and employees.
In addition to any remedy authorized by law, so much of the money due the
Contractor under and by virtue of the contract as shall be considered
necessary by the City may be retained by the City until disposition has been
made of such suits or claims for damages as aforesaid. The retention of money
due the Contractor shall be subject to the following:
1. The City will give the Contractor thirty(30) days notice of its
intention to retain funds from any partial payment which may become due to the
Contractor prior to acceptance of the contract. Retention of funds from any
payment made after acceptance of the contract may be made without such prior
notice to the Contractor.
General Provisions page 8 of 11
d. Re oonsibility f-om pamazaeicont'd)
2. No retention of additional amounts out of partial payments will be
made if the mount to be retained does not exceed the amount being withheld
from partial payments pursuant to Section 9-1.06 of the State Standard
Specifications ("Partial Payments") .
3. If the City has retained funds and it is subsequently determined that
the City is not entitled to be indemnified and saved harmless by the
Contractor in connection with the matter for which such retention was made,
the City shall be liable for interest on the amount retained at the legal rate
of interest for the period of such retention.
The City will consider proposals by the Contractor to enter into special
arrangements, such as posting securities or bonds acceptable to the City, in
lieu of the retention of funds. Such special arrangements shall be in writing,
and approved by the surety on the performance bond and by the surety on the
payment bond.
No funds shall be retained where the Contractor establishes, to the
satisfaction of the City that at the time of the accident or occurance giving
rise to a claim or lawsuit against the City or its officers or employees, that
the Contractor had in effect public liability and property damage insurance of
the type, form, and amount as provided in Section B. paragraph 6b, above
("Insurance - Public Liability and Property Damage") . (See State Standard
Specifications Section 7-1.12. )
7 PROPOSAL NOD BARD OF C9MACT
a,, Competency & Bidders
All bidders are required to complete the "Bidder Qualification Form" as
provided in the proposal. Incomplete forms or lack of experience in the field
of work being bid may be cause for rejection of the proposal.
b. Contragg Bonds
The Contractor shall furnish two(2) good and sufficient bonds. Each of
the Bonds shall be executed in a sum equal to the contract price. The first
bond shall guarantee the faithful performance of the contract by the
Contractor. The second bond shall be furnished as required by the terms of
Sections 3247 to 3252 , inclusive, of the Civil Code of the State of
California. The Labor and materials bond will be released six(6) months after
the Notice of Completion, and the Faithful Performance shall be reduced by
ninety percent(90%) at the Notice of Completion. The remaining ten
percent(10%) will be released at the end of one(;) year from acceptance of the
project provided any deficiencies in the work have been corrected. (See State
Standard Specifications Section 3-1.02. 1
General Provisions page 9 of 11
Si Execution -of Contract
.he successful bidder, as Contractor, shall execute the Agreement set
forth in the contract documents and provide the contract bonds and insurance
certificates required therein within ten(10) days of notification of award of
contract. Failure to do so may result in annulment of award and forfeiture of
the proposal guarantee. No proposal shall be considered binding upon the City
of Cupertino. [See State Standard Specifications Section 3-1.03. ]
A, PgyMent
The Cit.f will make partial payments to the Contractor on the basis of a
duly certified estimate of the work performed and the materials incorporated
in the project during the preceding reporting period. The City utilizes a bi-
weekly accounts payable cycle and issues checks on Fridays. The actual dates
of the payment schedule are available through the City' s Accounting
Department. The City will retain ten percent(10%) of the amount of each of
said estimates until the expiration of thirty-five(35) days from the date of
recording by the City of the Notice of Completion. At this time, and not
before, Lne City shall pay the Contractor the whole of the remaining ten
parcent(10%) of said contract p-.,ice. The payment of progress payments by the
City shall not be construed as an absolute acceptance of the work done up to
the time of such payments, but the entire wo: k is to be subjected to the
inspection and approval of the City, and subject to whatever inspection and
approval may be required by law.
Proposal Forms
The City will furnish to each bidder a standard proposal form, which,
when filled out and executed may be submitted as the Contractor's bid. Bids
not presented on forms so furnished will be disregarded.
The proposal form is bound together with the Notice to Contractors,
General Provisions , Special Provisions, Bidder Qualification Form, Sub-
Contractors Form and Signature Form. The Contractor shall submit as a minimum,
the Notice to Contractors, Proposal, Bidder Qualification Form, Sub-
contractors Form and Signature Form. Bids containing less than this or bids
containing incomplete forms will be disregarded.
All proposals shall state the dates for completion, if required, the
prices proposed, both in writing and in figures and shall show a total, and
shall be signed by the bidder, with the bidders address. If proposals are made
by an individual, name and post office address shall be shown. If made by a
firm or partnership, the name and post office address of each member of the
firm or partnership shall be shown. If made by a corporation, the proposal
shall show the names, titles and business address of the president, secretary
and treasurer and the proposal shall show the corporate seal.
General Provisions page 10 of 11
gb Proposal Forms(Cont'd)
The proposal shall be submitted as directed in the 'Notice to
Contractors' under sealed cover plainly markeu as a proposal, and identifying
the project to which the proposal relates and the date of the bid opening
therefor. Proposals not properly submitted may be disregarded. Proposal forms
Ray be obtained from the Office of the City Clerk, City of Cupertino, 10300
Torre Avenue, Cupertino, CA, 95015-3255 or by calling (408) 252-4505.
f. Proposal Lroposal Cuaranty
All proposals or bids shall be accompanied by cash, cashier' s check,
certified check, bid bond made payable, in the amount of ten percent(10%) of
the bid amount, z:o the City of Cupertino as gaurantee that the bidder, if
awarded the contract, will within ten(10) days after notice of award, enter
into a contract with the City for the work.
g,i Rejection of Proposals
Proposals may be rejected if they show aixy alterations of form, additions
not called for, conditional or alternative bids not called for, incomplete
bids or erasures, or for irregularities of any kind. Only the proposal forms
prepared by the City shall be used. (See State Standard Specifications Section
2-1.06. )
h, Subcontractors
The proposal shall contain the name and location of the place of business
of each subcontractor who will perform work or labor or render service to the
prime contractor in or ,about the construction of the work or improvement, or a
subcontractor licensed by the State of California who, under subcontract to
the prime contractor, specially fabricates and installs a portion of the work
or improvement according to detailed drawings contained in the plans and
specifications, in an amount in excess of one-half of one percent(0.58) of the
prime contractor's bid or, in case of bids or offers for the construction of
streets or highways, including bridges, in excess of one-half of one percent
(0.58) of the prime contractor's total bid or ten thousand dollars($10,000.00)
whichever is the greater.
The proposal shall list the portion of the work which will be done by
each subcontractor for this project. The prime contractor shall list only
one(1) subcontractor for each portion as is defined by the prime contractor in
the prime contractor's bid.
General Provisions page ll b f 11
SPECIAL PRDVISIONS
1. LOCATION
This work is located within the City of Cupertino, Canty of Santa
Clara, State of California, at various locatiam.
2. SCOPE OF MRK:
The work shall consist of furnishing all labor, equipment and
materials neoesssary for the grinding of the P.C.C. sidewalk in
aC :e with these specifications, Standard Details and Cal Trans
Standard Specifications.
3. E MATED WAN TES:
Item Description Unit Q�yt
1. P.C.C. sidewalk, greater than 0" and less than or Each 959
equal to 2t1 uplift; (4 1/2 ft. X 611 to 12") ,
Detail A & B.
4. E3GIANATION OF BID ITEMS;
The unit price bid per unit measure of work shall include all costs of
labor, equipment and materials necessary for the grinding dam of
Portland Cement concrete sidewalk, including move in costs for each
location, in accordance with the special provisions. Any item shown
on the details or described in these special provisions and not
specifically listed as a bid item shall be considered as included in
the various bid items and no special motion will be allowed.
Bid Items No. 1 Sidecealk Grinding (Each) :
These items shall be bid per each and shall include all costs for:
a) Grinding of P.C.C. sidewalk and removing and disposing of residue
from grinding. Debris cannot be disposed of in the sanitary
sewer or storm drain. Debris shall be disposed of outside of
City Limits.
b) Grinding shall be performed so that the sidewalk surface has
essentially the same texture adjacent to either side of the joint
or crack.
C) Sanples of sidewalk that have been leveled by a grinder can be
seen in front of 10060 and 10090 Pharlap Dr. and 22156 and 22157
Clear Creek Ct.
d) See Details A & B
SPECIAL PRMSICNS PAGE 1 OF 2
SPECIAL PROVISIONS (CONrINuED)
5. LIMITS OF WMW:
A representative of the City shall paint the limits of grinding
required at each sidewalk location.
6. TIME OF O IMKJLIQUIDIATED DAMAGES:
The contractor shall diligently prosecute the work and said work shall
be cOMPleted before the expiration of forty five (45) working days
from the notice to proceed. No work on Saturdays, Sundays, or
Holidays, or before 8:00 A.M or after 5:00 P.M. will be allowed.
the contractor shall pay to the City of Cupertino the stun of one
hundred and fifty dollars ($150.00) per day for each and every
calendar day's delay beyond the completion date.
7. PAYMERI':
Payment shall be made on only those addresses the City has approved
for grinding. No other compensation will be allowed. A payment
schedule is available in the Public Works Department.
Change orders will not be considered or accepted after the project has
been accepted by the City cot=il.
8. PROTECTION OF PROPERTY:
The contractor shall maintain the work site as clean and as free of
debris as is feasible. Ttie contractor shall not pile debris or
equipment or otherwise trespass, on private praperLy, unless he has
obtained specific permission frcan the property owner. The contractor
shall take reasonable precautions to cause the least damage possible
to existing i provements and landscaping in the work area on both
public and private property.
SPECIAL PROVISIONS PAGE 2 OF 3
SPECIFICATIONS FOR SIDEWALK GRINDING
Project 91-106
Reviewed by:
(z cr� r
Bob BOtelho
Public Wcrks Superintwdent
Reviewed by: Approved by:
Travice WiftftfjH lch
Assistant City FYqineer =ector' O Public Wcmim
SPB ALA PWaSICKS PAGE 3 OF 3
CZ/im
'® GRIND OUT
EXISTIA16 PC.C. WALK
®ETAI L A
GRIND CHAT
EXISTING PC-C. WALK
DETAIL
l
I
21DEWALK GRINDING DETAILS
N.T.S.
SIDEWALK GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO. STPHT NUMBER OF GRINDS COMPLETED
2 AINSWORTH DR 10470 1
585 AIDERBROOK tN. 803 2
587 ALDERBROOK IN. 887 1
586 AIDERBROOK LN. X-FROM 857 1
453 AMHERST DR 19776 1
319 APPLE TREE IN. 20157 2
320 APPLE 'TREE IN. 20189 1
318 APPLE TREE LN. - SIDE 20075 1
334 APPIETREE IN. X-FROM 20111 1
583 ATHERWOOD AVE 801 1
582 ATHERWOOD AVE 6329 2
584 ATHERWOOD AVE. X-FROM 6363 1
430 AUBURN Cr. 19721 2
429 AUBURN DR 19745 1
467 AVACADO Pl. 10215 2
301 BARNHART Pt. 7420 1
302 BARNHART Pl. 7450 1
295 BARNHART Pl. @ PRIMROSE WY. - N WEST CORNER 3
409 BAYWOOD DR 10481 1
412 BAYWOOD DR 19854 3
410 BAYWOOD DR 19855 2
411 BAYWOOD DR 19866 2
441 BAYWOOD DR - SIDE 10480 4
142 BEARDON DR 60'S. OF VALLEY GREEN DR 1
84 BEAVEN AVE 21739 1
57 BELKNAP DR X-FROM 7939 1
530 BMIN AVE 877 1
533 BFM AVE 852 3
534 BFM AVE 858 1
531 BFM AVE 861 1
547 BETTE AVE. - SIDE 10550 2
468 BIXBY DR 10752 1
474 BIXBY DR 19741 1
469 BIXBY DR 19742 1
475 BIXBY DR 19751 1
340 BLANEY AVE 10295 2
418 BIANEY AVE 10390 1
338 BIANEY AVE. 10460 1
402 BLANEY AVE 10619 1
403 BLANEY AVE. 10633 2
404 BIANEY AVE 10683 2
405 BLANEY AVE 10715 1
406 BLANEY AVE 10743 1
345 BLANEY AVE. 10140 2
316 BLANEY AVE - SIDE 10521 3
347 BLANEY AVE @ FLORIST SHOP t
312 IBIANEY AVE ® HOMESTEAD RD. - S W CORNER 1
313 JBIhNEY AVE HWY 280 OVERPASS - S/E SIDE 2
SIDEWALK GRINDING PROJECT 91-106
LD. NUMBER DATE
NO. SIPM NUMBER OF GRM COMPIM ED
588 BLAZWGWOOD AVE. 928 2
589 BLAZINCWOOD AVE. X-FROM 937 3
232 BOLINGER RD. 7445 2
407 IBQLLINGER RD. X-FROM 6834 1
408 BDLIINGER RD. X-FIRM 6956 1
160 BONNY DR 10194 2
161 BONNY DR 10208 1
162 BONNY DR 10313 1
532 IBRENT DR - SIDE 889 1
361 BRMANY Cr. 10299 1
359 BRrM4NY CT..- SIDE 10289 3
360 BRfMAY Cr. 10308 2
32 BUBB RD. 1001 1
47 BUBB RD. 11247 1
48 BUBB RD. X-FROM 1222 2
8 CAUFORNLA OAK WY. X-FROM 10072 1
227 CANDLELIGHT WY. 1161 2
226 CANDLELIGHT WY. 1191 1
125 CAMINE AVE. 10390 1
120 CAMINE AVR 10520 3
121 CASPWE AVE. 10550 2
122 CAS TINE AM 10590 2
124 CASTWE AVE. 10591 2
123 CASPINE AVE 10610 1
135 CAMINE AVE. 10731 1
44 CAS' MN ST. 21594 3
45 CASfLMN Sr. 21603 2
37 CAS'IEMN ST. 21753 1
315 CEDARTREE C. 10552 2
178 CHERYL DR 20663 2
181 CHERYL DR 20781 3
166 CHERYL DR - SIDE 20781 1
370 CLAY ST. 20327 2
371 CLAY ST. 20337 2
373 CLAY S. _ 20348 2
372 CLAY S'f. 20368 1
374 CUFDEN WY. 20321 1
375 CUFDEN WY. 20345 2
376 CUFDEN WY. 20351 1 1
384 CIIFDEN WY. 20374 1
378 CUFDEN WY. 20388 2
377 CIMEY WY. 20396 1
536 CLIFFORD DR 6559 2
537 CLIFFORD DR 6685 2
538 CLIFFORD DR 6707 1 1
539 CLIFF0RD DR 6743 3
540 CUFFORD DR 6751 2
535 C[IFFOPO DR X-FROM 6675 1
SIDEWALK GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO. SFREET NUMBER OF GRID COMPLETED
454 COLBY AVE. 10225 2
452 COLBY AVE 10299 1
451 COLBY AVE 10368 1
450 ICOIBY AVE 10384 1
449 COLBY AVE 10449 1
470 COLD HARBOR AVE 10327 1
473 COLD HARBOR AS 10328 1
472 COLD HARBOR AVE. 10338 1
471 COU, HARBOR AVE. 10338 1
464 COLD HARBOUR AVE - SIDE 10257 4
46 CQUJNGSWORTH DR 21756 1
238 COIDNYHIUS I.N. 1047 1
I 239 C01ONYHHlS IN. 1053 4
241 COLONYHI LS IN. 1066 2
240 COIDNYHUIS IN. 1070 2
237 COIDNYHIIIS IN. - SIDE 1035 1
33 COLUMBUS AVE 21541 1
34 COLUMBUS AVE. 21561 1
35 COLUMBUS AVE 21591 1
36 COLUMBUS AVE. 21661 1
592 COTTONWOOD CT. 6377 1
175 CRAIG Cr. 20627 1
176 CRAIG CT. 20687 3
61 CRANBURY CIRCLE 7945 1
62 CRANBURY DR 988 1
60 CRANBURY DR 1025 4
228 CRESTLINE DR 1180 t
t26 CYPRESS Cr. - SIDE 10571 1
428 CYPRESS DR 10491 1 1
425 CYPRESS DR 10510 1
427 CYPRESS DR 10511 2
557 DAVIDSON AVE. 10460 1
558 DAVIDSON AVE_ 10471 2
559 DAVIDSON AVE 10491 1
560 DAVIDSON AVE. 10501 1
561 DAVIDSON AVE 10511 2
233 DE FOE DR 7539 1
234 DE FOE DR 7547 1
235 DE FOE DR X-FROM 7565 t
353 DEANZA BL 10420 1
461 DEEPROSE PE 10151 2
460 DEEPROSE Pl. 10152 4
447 DOWN AVE 102172 1
446 DENNISON AVE. 10349 1
445 DENNISON AVE 10377 2
423 DEODARA DR 10490 3
424 DEDDARA DR 10511 2
422 DEODARA DR - SIDE 10484 2
SIDEWALK GRINDING PROJECT 91-106
NIJNIBER DATE
N0. NUMBER OF GRUGS COMPLEM
208 DERBYSHIRE DR 1137 1
209 DERBYSHIRE DR 1141 1
119 DEXTER DR 21384 1
305 DONEGAL DR 7511 2
431 DRAKE DR 19705 1
432 DRAKE DR - SIDE 19750 L
236 DUMAS DR 7454 2
512 EESTATES DR 845 2
513 EESTATES DR 854 2
514 EESTATES DR 858 1
515 EESPATES DR 862 1
516 EESTATES DR 866 1
517 EESTATES DR 883 1
491 EESTATES DR 10159 1
492 EESTATES DR 10253 1
493 EESTATES DR 10265 1
506 EESCATES DR IG400 1
508 EESTATES DR 10465 2
507 EESTATES DR 10466 1
511 EESTATES DR 10611 1
510 EESPATES DR 10620 1
509 EESfATES DR - SIDE 10481 5
63 ELM Cr. 21444 1
55 EIMSFORD Cr. 1181 1
56 ELMSFORD DR 1108 1
53 ELMSFORD DR 1154 2
54 EIMSFORD DR 1155 1
185 ERIN WY. 7565 2
186 ERIN WY. 7571 2
187 ERIN WY. 7580 2
188 EPX4 WY. 7583 1
190 ERIN WY. 7584 2
189 ERIN WY. 7590 L
191 IERIN WY. 7596 1 2
192 ERIN WY. 7613 �.
193 ERIN WY. 7616 1
194 ERIN WY. 7649 2
195 ERIN WY. 7675 4
243 FALLENtEAF IN. 7373 1
242 FAIIENLEAF IN. 7464 2
245 FAIIENIEAF IN. @ WE MYNN WY. N CORNER 1
354 FARAUDNE DR 10275 1
355 FARALLDNE DR 1 G285 2
356 FARALLDNE DR 10295 1
357 FARALIDNE DR 10425 1
386 FARAUONE DR 10619 3
358 FARAU.ONE DR - SIDE 10441 2
387 FkR-AIlONE DR - SIDE 10711 2
SIDEWALK GRINDING PR ECT 91-106
I.D. NUMBER DATE
NO. STREET NUMBER OF GRINDS COMPLETED
100 FESTIVAL DR 7830 2
414 FIG M CT 19907 3
599 FINCH AVE 10451 2
598 FINCH AVE 10465 1
66 FLTGERDID DR 0 DEMPSTER AVE -- S E CORNER 2
68 FTIZGEROID DR 21601 1
67 FPIZGEROLD DR 21611 1
298 FIDWER Cr. - SIDE 1330 2
52 IFOIXMNE DR 7951 1
5 FOO HU BL 0 SALEM - N E CORNER 1
6 FQ0ML BL 0 SALEM - S CORNER 1
13 FOOTH U BL X-FROM 10406 2
4 FWMU BL X-FROM SILVER OAK WY. 1
324 FOREST AVE 20190 1 2
323 FOREST AVE 20206 2
134 GARDENA DR 21156 3
132 GARDENA DR 21180 1
131 GARDENA DR 21192 1
130 IGARDENA DR 21251 2
129 GARDENA DR 21261 1
379 GI111CK WY. 20324 1
382 GII11CK WY. 20353 2
383 QUICK WY. 20387 2
541 GLENVIEW AVE 10377 1 2
542 GLENVIEW AVE 10395 2
543 GtEN`VIEW AVE 10412 4
544 GLENVIEW AVE 10465 2
545 GLENVIEW AVE 10511 1
548 GLENVIEW AVE 1055� 3
549 GLENVIEW AVE 10559 1 2
551 GLENVIEW AVE 10580 2
552 GLENVIEW AVE 10583 2
553 GLENVIEW AVE 10615 1
500 GLENVIEW DR - SIDE 10340 1
128 GRAPNEL Pl. 10665 1
577 GREENWOOD Cr. 10323 2
578 GREENWOOD CT. 10362 1
576 GREENWOOD Cr. 91515 1
579 GREENWOOD Cr. - SIDE 10337 1
615 GREENWOOD DR 19385 2
613 GREENWOOD DR X-FROM 9425 2
1 HAR19ti M DR 0 CHACE - Sa CORNER 1
217 HOILYHEAD IN. 1107 1
218 HOLLYHEAD LN. 1127 1
605 HOMESTEAD RD. 0 WOLF SHELL STATION 1
212 HUN+`MWN Pl. 1082 2
596 HYDE AVE 6148 1
299 JAM15MWN DR - SIDE 1463 1
SIDEWAUc GRINDING PROJECT 91-106
LD. NUMBER DATE
NO. STREET NUM EP OF GRINDS COMPIEM
300 JAMESTOWN DR — SIDE 1641 2
529 JOHN DR 6721 2
528 JOHN DR _ 6724 1
527 IJOHN DR 6`56 1
395 JOHN DR 20153 1
101 IENMOORE CT. — SIDE '002 2
257 KENTWOOD DR 1075 1
266 IENTWOOD DR 1115 1
269 KMOOD DR 1123 2
270 KENTWOOD DR 1128 2
271 KENTWOOD DR 1143 2
277 KENTWOOD DR 1151 3
278 KENTWOOD DR 1152 3
268 KENTWOOD DR X—FROM 1119 1
204 104 ST. 0 CREEK BRIDGE 1
224 IlaNGSBURY DR 7491 2
225 KIN(SBURY DR X—FROM 7538 1
201 EMWININ. 7556 1
200 KTRWININ. 7556 1 1
199 IMWININ. 7586 2
198 KIRWIN IN. 7598 1
197 MRWIN LN. — SIDE 7629 1
495 IA MAR CT. 19621 1
496 LA MAR Cr. 19631 2
497 IA MAP. Cr. 19745 1
498 IA MAR Cr. 19759 2
499 ILA MAR Cr. 19787 1
503 IIA MAR DR 19778 1
502 IIA MAR DR 19828 1
504 'LA MAR DR — SIDE 19764 3
389 LA RODA DR 10576 1
390 LA RODA DR 10577 1
391 LA RODA DR 10605
392 TA RODA DR 10619 2
393 LA RODA DR 10647 1
394 LA RODA DR 10659 1
388 LA RODA DR 10762 1
363 LAS ONDAS Cr. 20129 1
364 LAS ONDAS CT. — SIDE 20088 1
362 LAS ONDAS WY. 20088 3
614 LBOLA Cr. 10331 1
23 UNDA VISTA DR 10996 1
24 UNDA VGS"I'A DR 11087 1
526 UNDENBROOK IN. 19863 3
575 UNDSAY AVE 10369 1
574 UNDSAY AM 10370 1
573 UNDSAY ADZ 10381 2
571 UNDSAY AVE 10420 5
SIDEWALK GRINDING PROJECP 91-106
I.D. NUMBER DATE
NO. STREET NUMBER OF GRINDS COMPLETED
572 L INDSAY AVE 10451 2
501 LINDSAY AVE. — SIDE 10361 3
219 LOCKFORD Cr. 7525 1
222 ROCKFORD Cr. 7534 1
220 LOCKFORD CT. 7557 1
221 LOCKFORD Cr. 7572 2
203 LONNAIR 861 1
202 IONNA IR — SIDE 7515 1
7 MAdESP1C OAK WY. 22754 1
30 MARIA ROSA WY. 11010 1
380 MARTINWOOD WY. 10751 2
381 MAR INWOOD WY. 10765 8
114 MARY AVE X—FROM MEMORIAL PARK ENTRANCE 1
113 MARY AVE. 0 OAKS THEATRE W SIDE 1
116 MARY AVE BETWEEN 2 ND GLENBFOOK APT. & LUBEC E SIDE 1
115 MARY AVE. NEAR 2 ND GLENBROOK APT. ENTR E SIDE i
III MARY AVE X—FROM LEBEC Cr. !.ME 1
117 MARY AVE.150'S OF LUBE C ST. E SIDE 1
112 MARY A'✓ O OAKS PARKING LOT W SIDE 2
437 MCCLAREN PL 10146 2
182 MCCLEIILN RD. 20651 3
183 MCCLEIL AN RD. 20661 3
22 MCCL ELLAN RD. X—FROM 21737 1
463 IMELLO PL. 10119 2
402 MELLD Pl. — SIDE 10170 1
12 MERRIMAN RD. 10413 1
442 MERRIT DR 19665 2
443 MERRIT DR 19707 1
444 MERRIT DR 19710 1
421 MERRIT DR 19850 1
420 MERRIT DR 19872 3
419 MERRIT DR 19888 1
317 MERRITT DR 20046 1
126 METEOR DR 21327 1
127 METEOR PL. 10555 1
385 MICHAEL Cr. — SIDE 20328 1
205 MILKY WY. 1081 1
206 MIL XX WY. 1089 1
207 MUhr' KY. 1093 1
593 MIILEI AVE. 849 1
595 MILLER AVE 868 3
594 MILLER AVE. 973 2
580 MILLER AVE. W SIDE 10381 1
581 MILLER AVE W SIDE 10505 1
49 MONROVIA ST 21526 1
50 MONROVIA ST. 21546 1
591 MYRrLP0OD DR 6367 3
590 MYRTIEIVOOD DR — SIDE 6390 2
SIDEWALK GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO. STREET NUMBER OF GRM COMPLETED
177 NANCY Cr. _ 20645 1
31 NEW HAVEN Cr. 931 1
79 NOEL DR 10293 1
83 INOEL DR 10343 1
80 NOEL DR 10392 1
81 NOEL DR 10393 1
82 NOEL DR 10413 1
307 NORMANDY WY. 7551 1
308 NORMANDY WY. 7575 1
309 NORMANDY WY. 7641 _ 2
310 NORMANDY WY. 7680 3
439 NORWICH AVE. 10332 1
440 NORWICH AVE. 10346 1
92 INOVEMBER DR 903 1
93 NOVEMBER DR 1021 2
94 NOVEMBER DR 1035 1
95 NOVEMBER DR 1039 1
96 NOVEMBER DR 1040 1
97 NOVEMBER DR 1077 1 1
98 NOVEMBER DR 1081 1
99 NOVEMBER DR 1087 3
21 OAKLEAF PL 10109 l
570 OAKVIEW AVE 10441 2
546 OAKVIEW AVE - SIDE 10510 1
566 OAKVIIIE AVE 10390 3
567 OAKV111E AVE 10401 1
568 OAKVILIE AVE 10420 2
569 OAKVIIIE AVE 10431 2
505 OAKVIIIE DR 10380 1
89 OCTOBER WY. 7902 1
90 OCTOBER WY. 7918 1
91 OCTOBER WY. 7941 1
290 ORANGEBLOSSOM DR - SIDE 7695 3
314 ORANGETREE IN. 10555 1
401 PACIFICA DR 20031 2
400 NCIFICA DR 20184 1
399 PACIFICA DR 20198 2
40 PALOS VERDES DR 11106 2
41 PALOS VERDES DR 11126 1
42 PALOS VERDES DR 11136 2
292 PEACHBLOSSOM DR 7678 2
291 PEACHBLOSSOM DR - SIDE 7689 1
331 PEACHTREE IN. 20106 2
330 PEACHTREE LN. 20120 1
415 PEARTREE IN. 19936 1
416 PEAMM IN. 19955 1 2
417 JPEARTREE IN. 19967 1
339 1PEARTREE LN. - SIDE 19990 2
SIDEWALK GRINDING PROJECT 91-106
ID, NUMBER DATE
NO. NUMBER OF GRINDS MPLETED
413 PEAMM IN. X-FROM '9866 1
158 PEPPERTREE IN. 20870 I
157 PEPPERTREE LK 2089E i
156 PEPPERTREE Lrl. 20940 1
20 PHARIAP DR 10120 1
565 PINEVILIF AVE. 10420 2
564 PINEVIIUE AVE, 10450 1
563 IPIlVZ!,'VIIIE AVE 10460 1
562 'r.PINEVIL E AVE 10520 i
550 PINEVIIIE AVE - SIDE 10530 2
337 PLUFinW IN. 10401 2
336 PUJMTREE LN. 10439 1
335 PLUMTREE IN. X-FROM 10462 1 __
303 POPPY WY. - SIDE 1640 1
455 PORTAL AVE 10128 1
436 ,PORTAL AVE 10137 1
456 PORTAL AVE. 10142 1
457 PORTAL AVE 10154 3
466 PORTAL AVE. 10204 2
448 PORTAL AVE 10384 1
435 PORTAL AVE. 10551 2
434 PORTAL AVE 10601 2
433 PORTAL AVE 10602 4
458 PORTAL AVE 100S. OF STEVEN CRK BL E SIDE 2
459 PRICE AVE. 19831 1
293 PRIMROSE WY. 1343 1
294 PRIMROSE WY. 1449 1
304 PRIMROSE WY. - SIDE 1648 3
286 RAINBOW DR 7424 1
287 RAINBOW DR 7553 1
288 RAINBOW DR 7595 1
289 RAINBOW DR 7669 1
556 RAMPART AVE. 10475 1
555 RAMPART AVE 10489 1
554 RAMPART AVE 10531 3
333 RANDY IN. 10094 2
332 RANDY IN. 10208 2
609 RICHWOOD Cr. 19460 2
610 RICHWOOD Cr. 19470 4
611 JCHWOOD CT. 19480 1
477 RICHWOOD DR 10119 2
478 RICHWOOD DR 10143 3
479 RICHWOOD DR 10184 1
480 RICHWOOD DR 10265 1
481 RICHWOOD DR 10277 2
482 RICHWOOD DR 10301 2
483 IRICHWOOD DR 10325 2
476 IRICHWOOD DR 19618 1
SIDEW" GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO NUMBER OF GPM COMPLETED
15 RIVERSIDE DR 22413 1
14 RIVERSIDE DR 22414 1
16 RIVERSIDE OR ® DREA RD. - N/E CORNER 2
210 ROBINDEIL WY. 7818 1
211 ROBINDEIL WY. @ STEUJNG RD. - S CORNER 1
350 RODREGUES AVE, 20370 2
349 RDDREGUES AVE, 20380 1
348 RODREGUES AVE. 20410 1
149 RODREGUES AVE. 50'W. OF DEANZA BLS SIDE 1
261 ROILLNGDEIL DR 7409 1
262 ROLLINGDELL DR 7480 2
264 ROWNGDELL DR 7489 2
263 ROIIJIGDELL DR 7497 1
265 ROLLINGDELL. DR 7497 1
612 ROSE MARIE PL 19472 1
110 ROSEBI,0S9DM DR 820 2
106 ROSEBIDSSOM DR 841 2
109 ROSFBLOSSOM DR 872 l
107 RtMLOSSOM DR 931 1
306 ROSEGARDEN IN. 1496 1
118 RUMFORD DR 21386 t
108 SAGE Cr. 914 1
25 SANTA TERESA DR 11091 1
150 SCOFLELD DR 20610 2
151 SCOFTU DR 20686 1
152 SCOFIEID DR 20720 1
155 &DFLEID DR 20851 2
148 ISCOFnD DR ® MCWORTERS DRIVEWAY I
15tSiEVrEMBER
FIELD DR X-FROM 20745 1
224ND DR - SLUE 1123 1
10MBER DR 826 1
10MBER DR 850 1
10M ER DR 912 0
10 DR 932 2
88 SEPTEMBER DR 899 1
87 SEPTEMBER DR - SIDE 84" 1
229 SHABOWHIll W 7631 2
230 SHADOWHIIL IN. 7643 1
231 SHADOWIHM IN. 7653 1
65 JSHANNON Cr. 21423 l
64 NON Cr. 21443 t
174 Y DR 20618173 Y DR 20638 4
172Y DR 20679 4
170Y DR 20729 2
169 Y DR 2.751 1
143 WY. W SIDE FROM 7-11 S ORE TO STEVEN CRK. BL 4
369ADO AVE. 20294 1
SIDEWAIX GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO. MEET NUMBER OF GRINT S COMPLETED
365 SILVFT" AVE. 20295 4
366 SILVERADO AVE. 20309 1
368 SILVERADO AVE 20337 1
367 SPLVERADQ AVE 20351 2
51 STAFFORD DR 1211 1
260 STAFORD PL - SIDE 7408 1
259 STANFORD PL 7478 2
258 STANFIDRD PL 7498 1
267 STANFORD PL - SIDE 7495 2
282 STEPLECIIACE IN. 1110 2
283 SfEEPLDCHACE IN. 1113 1
285 STEEPLECRACEIN. 1114 2
284 STEEPLEMCE IN. 1117 1 _
276 STEEPIBMCE IN. 1122 9-
275 SPEEPLECHACE IN. 1126 1
274 SPEEPLECHACE IN. 1134 2
272 SPEEPIECHACE IN. 1137 1
281 SfEEPLECHACE I.N. 1137 2
280 SI'EEPLEMCE IN. 1138 2
273 STEEPLECHACE IN. 1138 2
279 91'EEPLMCE IN. 1142 1
196 ST'EWNG RD. 848 2
214 SlMMG RD. 1348 1
213 STELIING RD. - SIDE 1083 2
600 STEVEN CREEK BL Y-FROM N SIDE 19444 2
144 STEVEN CRK BL ® UNION CIIURCH S SIDE
!46 STEVENS CRK BL 4 MARIE CAII ENDERS
147 STEVENS CRK BL 1-4 MERVWS S SIDE 1
145 STEVENS CRK BI. 0 POST OFFICE DRIVEWAYS SIDE 1
86 STOKES AVE 10330
85 STOKES AVE. 10430 l
69 SIDKES AVE. 10441 1
70 STOKES AVE. 10471 2
71 STOKES AVE 10481
73 STOKES AVE. 10531 2
76 STOKES AVE 10591 1
74 MIS AVE 10620 1
75 STOFM AVE 10630 1
77 STOKES AVE. 10631 1
78 STOKES AVE. 10641 1
72 STOKES AVE - SIDE _ 10521 1
396 SUISUN DR 20071 1
397 SUISUN DR 20087 1
398 SUISUN DR 20171 1
597 TANTAU AVE. 923 1
601 TANTAU AVE. 50' N OF STEVENS CRK BL E SIDE 1
43 TERRACE DR - SIDE 21643 2
246 TIPTOE LN. 7407 2
SIDEWALK GRINDING PROJECT 91-106
A224
NI MER DATE
N MBER OF GRINMS MPLETED
iE
LN. 7414LN. 7421 2
LN. 7442
IN. 7463 i
255 TFTOE 1N. 7477 I
251 TWTOE 1N. 7484 2
254 TIME IN. 7496 2
252 TIPTOE IN. 7539 1
256 TWME IN. 7565 1
171 TONITA WY. — SIDE 10316 3
180 IDNITA WY. — SIDE 10439 2
352 TORRE AVE. 10393 1
351 TORRE AVE X—FROM 10300 3
341 TWILIGHT Cr. 19938 1
342 TWILIGHT Cr. — SIDE 19997 3
604 VALLCO PARKWAY 1OO'E OF WOLF RD. N SIDE 1
603 VALLCO PARKWAY 50'El OF CREEK N SIDE 1
602 VALLCO PARKWAY N SIDE 19191 1
139 VAt1EY GREEEN DR E SIDE 4
140 VALLEY GREEN DR 0 APT.# 295 N SNE 1
141 VALIEY GREEN DR 0 BEARDON DR S W CORNER 1
137 VALLEY GREEN DR S SIDE 2
138 VALLEY GREEN DR X—FROM APT. 435 N SIDE 3
136 VALLEY GREEN DRIVE 0 APART'aLENT 437 1
484 VICKSBUR DR 19711 3
490 VICKSBURG DR 10311 1
494 VICKSBURG DR 19660 3
489 VICKSBURG DR 19688 1
488 VICKSBURG DR 19702 2
487 VTCKSBURG DR 19 718 4
486 ViCKSBURG DR 19736 1
485 VI':4{SBURG DR 19756 2
325 VISTA DR 10304—A 3
326 IVISTA DR 10334—A I
327 VISTA DR 10344—Al 2
328 VISTA DR 10384—A 2
329 VISTA DR 10438 1
322 VISTA DR X—FROM 10184 1
321 VISTA DR X—FROM 10424 1
3 VISTA KNOLL 10288 2
It VOSS AVE 22674 1
9 VOSS AVE 22716 2
10 VOSS AVE 0 LOCKWOOD DR — S E CORNER l
522 W.ESTATES DR 10784 1
521 W.ESTATES DR 10809 1
520 W.ESTATES DR 10825 2
5l8 W.ESTATES DR 10880 1
519 W.ESTATES DR — SIDE 1O832 I
SIDEWALK GRINDING PRWECT 91-106
!.D. NUMBER DATE
NO. STREET NUMBER OF GRINDS COMPIMU
19 WALNUT CIRCLE NO. 22480 1
18 WALNUT CIRCLE SD. 22481 1
17 WALNUT CIRCLE SO. 22482 1
311 WATERFORD DR 7574 2
215 IWEST HILL Cr. 1076 1
216 !VEST HIM Cr. 1082 2
163 WESTACERS DR 10281 2
179 WESTACERS DR 10326 2
165 WESTAM DR 10445 1
168 IWESTACERS DR - SIDE 10290 1
167 WESTACERS DR - SIDE 10312 1
164 WESTACRES DR 10354 1
184 WESTACRES DR - SIDE 10486 3
154 WESTERN DR 10195 1
153 WESI'ERir1 DR 10209 1
253 WES!'LYNN WY. 990 2
244 WESTLYNN WY. 1044 1
346 WHEATON DR 20094 1
438 WHEATON DR X-FROM 19884 1
297 WHDFLOWER WY. - SIDE 7447 1
296 iWUDFWWER WY. - SIDE 7448 1
26 WUXENSDN AVE 10813 2
27 WQIENSON AVE 10873 1
28 WHIMCON AVE 10893 1
29 WQIEL4ON AVE. 10973 1
38 WHIMMN AVE I1153 2
39 WILEEWN AVE 11163 2
523 WR OWBROOK WY. 10775 2
525 WIIIDWBROOK WY. 108 i 0 1
524 WIIIDWBIMK WY. 10822 1
465 WINTERGREEN DR 19733 2
608 WOLF RD. 200'N OF STEVENS CREEK BL W SIDE 3
607 WOLF RD. @ HWY 280 OVER PASS W SIDE 1
606 WOLF RD. BEFORE FREEWAY ® PARKNG LOT W SIDE 2
617 WOLF RD. BETWEEN HOMESTEAMHWY280 W SIDE i 1
616 WOLF RD. BETWEEN PRUNRiDGE&HOMESPEAD E SIDE 4
59 IYORK3M Cr - SIDE 1181 2
58 IYORKSHRE DR ® YORKW HRE Cr. I
T O T A L 959
SIU£W." GRINDING PROJECT 91-106
L U. NUMBER DATE
fit). STREET NUMBER OF GRINDS ICOMPLFTED
1 HARTMAN DR 0 CHACE - S E CORNER � 1
AINSWORTH DR 10470 1
3 VISTA KNOLL _ 10288 2
4 EOOTHU BL X-FROM SILVER OAK WY. l
5 FOOTHIIL BL 4 SALEM - WE CORNER 1
6 FW MIIL BL ® SAIEM - S E CORNER 1
7 MAJESTIC OAK WY. 22754 1
$ CAIMPM OAK WY. X-FROM 10072 1
9 VOSS AVE 22716 2
10 VOSS AVE @ LO;KWOOD DR - S E CORNER 1
11 VOSS AVE. 22674 L 1
12 MERRIMAN RD. 10413 1
13 FOOTHILL BL X-FROM 10406 2
14 RIVEME DR 22414 1
15 RIVERSIDE DR 22413 1
t 6 RIVERSIDE DR 0 DREA RD. - N E CORNER 2
17 WALNUT CIRCLE SO. 22482 1
I B WALNUT CIRCLE SO. 22481 1
19 WALNUT CIRCLE NO. 22480 1
20 PHARIAP DR 10120 1
21 OAK" PL 10109 1
22 MCCGEL AN RD. X-FROM 21737 1
23 LINDA VISTA DR 10996 1
24 L INDA VISTA DR 1 11087 1
25 SANTA TERESA DR 11091 1 _
26 WHJINSON AVE 10813 2
27 WUXENSON AVE 10873 1
28 WLXENSON AVE 10893 1
29 WIUO;NSON AVE, 10973 1
30 MARIA ROSA WY. 11010 1
31 NEW HAVEN Cr._ 931 1
32 BUBB RD. 100; 1
33 COLUMBUS AVM 21541 1
34 COLUMBUS AVE. 21561 1
35 COLUMBUS AVE 21591 1
36 COLUMBUS AVE 21661 1
37 CASfL E'tON ST. 21753 1
38 WI1I(ENSON AVE 11153 2
39 WUHNSON AVE, 11163 2
40 PAM VERDES DR 11106 2
41 PALOS VERDES DR 11126 I
42 PALOS VERDES DR 11136 2
43 TERRACE DR - SIDE 21643 2
44 CAS LETON ST. 21594 3
45 CASTLE MN SP. 21603 2
46 COLLINGSWORTH DR 21756 1
47 BUBB RD. 11247 1
48 BUBB RD. X-FROM 1222 2
SIDEW.41X GRINDING PROJECT 91-106
LD NUMBER DATE
NO. NUMBER OF GRINDS COMPIEM
49 PMON;RovlA ST. 21526 1
50 MONROVIA S7. 21546 1
51 STAFFORD DR 1211 1
52 FOLKS ONE DR 7951 1
53 EIISFORD DR. 1154 2
54 ELMSFORD DR 1155 1
55 ELMSFORD CT. 1181 1
56 EDWORD DR 1108 1
57 IBELKNAP DR X-FROM 7939 1
58 YORKSM DR ® YORWiIIRE Cr. 1
59 YORKSHM Cr. - SIDE 1181 2
60 CRANBURY DR 1025 4
61 CRANBURY CIRCLE 7 945 1
62 CRANBURY DR 988 1
63 ELM Cr. 21444 1
64 SHANNON Cr. 21443 1
65 SHANNON Cr. 21423 1
66 F1rGEIK)ID DR @ DEM139M AVE - S E CORNER 2
67 FIMEROLD DR 21611 1
68 FPiZGEROID DR 21601 1
69 SMOKES AVE. 10441 1
70 SMM AVE 10471 2
71 SDOKES AVE 10481 2
72 SDOKES AVE - SIDE 10521 1
73 SMM AVE. 10531 2
74 SIbKES AVE 10620 1
75 SMM AVE 10630 1
76 SlbM AVE. 10591 1
77 S70KES AVE. 10631 1
78 STOKES AVE. 10641 1
79 NOEL DR 10293 1
80 NOEL DR 10392 _ 1 _
81 NOEL DR 10393 1 _
82 NOEL DR 10413 1
83 NOEL DR 10343 1
84 BEAVEN AVE 21739 1
85 SIi M AVE 10430 1
86 STOKES AVE 10330 2
87 SEPTLg3ER DR - SIDE 847 1
88 SEPTEMB�--R DR 899 1
89 OCInBER WY. 7902 1
90 OCTOBER WY. 7918 1
91 OCr0BER WY. 7941 1
92 NOVEMBER DR 903 1
93 NOVEMBER DR 1021 2
94 NOVEMBER DR 1035 1
95 NOVEMBER DR 1039 1
96 NOVEMBER DR 1040 1
SIDEWALK GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO. SIREI✓"f NUMBER OF GRINDS MPLEIED
97 NOVEMBER DR 1077 _1
98 NOVEMBER DR 1081 1
99 NOVEMBER DR 1087 3
100 IFMITVAL DR 7830 1 2
101 KENMOORE Cr. - SIDE 1002 2
102 SEPrEMBER DR 932 2 _
103 SEVITMBER DR 912 2
104 SEPTEMBER DR 850 1
105 SEMMER DR 826 1
106 ROSEBLOSSOM DR 841 2
107 ROSEBL0SSDM DR 931 1
108 SAGE CT. 914 1
109 ROSEBLOSSOM DR 872 l
11O ROSEBLOMM DR 820 2
III MARY AVE X-FROM LEBEC Cr. W SIDE 1
112 MARY AVE® OAKS PARKING IDT W SIDE 2
113 MARY AVE. @ OAKS THEATRE W SIDE 1
114 MARY AVE X-FROM MEMORIAL PARK ENTRANCE 1
115 MARY AVE. NEAR 2 ND GLENBROOK APT. WM E SIDE 1
116 MARY AVE BETWEEN 2 ND GLENBROOK APT. & LUBEC E SIDE 1
117 MARY AVE 150'S. OF LUBEC ST. E SIDE i
118 RUMFORD DR 21386 1
119 DEXTER DR 21384 1
120 CASTINE AVE. 10520 3
121 CASfINE AVE 10550 2
122 CAMM AVE. 10590 2
123 CASnNE AVE 10610 1
124 CASPINE AVE. 10591 2
125 CASTINE AVE. 10390 1
126 METEOR DR 21227 1
127 METEOR Pl. 10555 1
128 GRAPNEL PL 10655 1
129 GARDENA DR 21261 1
130 GARDENA DR 21251 9
131 C;ARDENA DR 21192 1
132 GARDENA DR 21180 1
134 GARDENA DR 21156 3
135 CAMM AVE 10731 1
136 VALLEY GREEN DRIVE ® APARTMENT # 437 1
137 VALLEY GREEN DR S SIDE 2
138 VALLEY GREEN DR X-FROM APT. 435 N SIDE 3
139 VALLEY GREEEN DR E SIDE 4
140 VALLEY GREEN DR ® APT. 295 N'SIDE 1
141 VALLEY GREEN DR It BEARDON DR S CORNER
142 BEARDON DR 60'S OF VALLEY GREEN DR 1
143 ACH WY. W SIDE FROM 7-11 STORE TO STEVEN CRK BL 4
144 STEVEN CRK BL @ UNION CHURCH S IDE 1
145 STEVEN4 CRK Bl. 0 POST OFFICE DRIVEWAY S/SIDE I
SIDEWALK GRINDING PRDJECf 91-106
I.D. NLWER DATE
NO. NUMBER OF GRINDS COMPLETED
146 'ENS CRK BL 0 MARtE CAILENDERS 2
147 CRK BL ® MERVYNS S SIDE 1
148 FIELD DR ® MCWORPERS DRIVEWAY _ 1
149 RODREGUFS AVE. 50T. OF DEANZA BL S/SIDE 1
150 900FULD DR 20610 2
151 SCOFIELD DR 20686 1
152 SDOFIELD DR 20720 1
153 WES`W DR 10209 1
154 IWEMN DR 10195 1
155 SODFMD DR 20851 2
156 PEPPERIVE IN. 20940 1
157 PEPPERM IN. 20896 1
158 PEPPERIREE LN. 20870 1
159 SCOFIELD DR X-FLi 20745 1 1
160 BONNY DR 10194 2
161 BONNY DR 10208 1
162 BONNY DR 10313 1
163 WESTACERS DR 10281 2
164 WESTACRES DR 10354 1
165 WESTACERS DR 10445 1
166 CHERYL DR - SIDE 20781 1
167 WE 3TACE RS DR - SIDE 10312 1
168 WESTACERS DR - SIDE 10290 1
169 SHELLY DR 20751 1 _
170 SHELLY DR 20729 2
171 TONMA WY. - SIDE 10316 3
172 SHELLY DR 20679 4
173 SHELLY DR 20638 4
174 SHELLY DR 20618 1
175 CRAIG Cr. 20627 1
176 CRAIG Cr. 20687 3
177 NANCY Cr. 20645 1
178 CHERYL DR 20663 `'
179 WESTACERS DR 10326 2
180 TONITA WY. - SIDE 10439 2
181 CHERYL DR 20781 3
182 MCCIEIIAN RD. 20651 3
183 MCCLEILAN RD. 20661 3
184 WESTACRES DR - SIDE 10486 3
185 IERIN WY. 7565 2
186 ERIN WY. 7571 2
187 ERIN WY. 7580 2
188 ERIN WY. 7583 1
189 ERIN WY. 7590 1
190 ERIN WY. 7584 2
191 ERIN WY. 7596 2
192 ERIN WY_ 7613 1
193 ERIN WY. 7616 1 1
S1DEWA1X GRINDM PROJECT 91-106
O. NUMBER DATE
\0. SIREET NUMM OF GRLND6 COMPIEM
194 ERIN WY. 7649 2
195 ERIN WY. 7675 4
196 STEUJNG RD. 848 2
197 IE3RWIN UV. - SIDE 7629 1 1
198 IOI?WIN IN. 7598 1
199 KIRWIN IX 7586 2
200 KRWIN I.N. 7556 1
201 KIRWLN IN. 7556 1
202 LONNA IN. - SIDE 7515 1
203 IDNNA LN. 861 1
204 MM ST. 0 CREEK BRIDGE 1
205 MILKY WY. 1081 1
206 MM WY. 1089 1
207 MIIXY WY. 1093 1
208 DERBYSHIRE DR 1137 1
209 DERBYSHN DR 1141 1
210 ROBINDELL WY. 7818 1
211 ROBINDEIL WY. 0 STEUJNG RD. - S W CORNER 1
212 HUNTERSON PL 1082 2
213 STEWIG RD. - SIDE 1083 2
214 STEUJNG RD. 1348 1
215 WEST HILL Cr. 1076 1
216 WEST H1U.Cr. 1 u82 2
217 HOILYHEAD IN. 1107 1
218 HOILYHEAD IN. 1127 1
219 1DCUI DRD Cr. 7525 1
220 TDCIFORD Cr. 7557 1
221 LOCKFORD Cr, 7572 2
222 LOCIQORD Cr. 7534 1
223 SCOTLAND DR - SIDE 1123 1
224 IQNGSBURY DR 7491 2
225 IQNGSBURY DR X-FROM 7538 1
226 CANDLELIGHT WY. 1191 1
227 CANDLEUGHT WY. 1161 2
228 CRFSPIINE DR 1180 1
229 SHADOWHILL IN. 7631
230 SHADOWHTTL LN. 7643 1
231 SHADOWHRL IN. 7653 1
232 BOLUNGER RD. 7445 2
233 DE FOE DR 7539 1
234 DE FOE DR 7547 1
235 DE FOE DR X-FROM 7565 1
236 DUMAS DR 7454 2
237 COLONYHIILS IN. - SIDE 1035 1
238 COIDNYHOS LN. 1047 1
239 COIDNYHW IX 1053 4
240 COIDNYHIUS LN. 1070 2 _
241 COIDNYMS IN. 1066 2
SIDEWAIR GRINDING PROJECT 91-106
LD. NUMBER DATE
NO• S7REEr NUMBER OF GRID COMPLETED
242 FAIIlN" IN. 7464 2
43 FAIIENIEAF LN. 7373 1
244 WESTLYNN WY. 1044 !
245 FAILENIEAF LN. 0 WWMYNN WY. N WEST CORNER !
246 TPME IN. 7407 2
247 TFIDE IN. 7421 2
248 TFfOE IN. 7414 1
249 TFFOE IX 7442 2
250 WME LN. 7463 1
251 TIPME IN. 7484 2
252 TWME LN. 7539 1
253 WESTLYNN WY. 990 2
254 TIPME IN. 7496 2
255 ITIPME IN. 7477 1
256 T TOE IN. 7565 1
257 KENTWOOD DR 1075 1
258 STANFURD PL 7498 1
259 STANFORD PL 7478 2
260 STAFORD PL - SIDE 7408 1
261 ROLLINGDELL DR 7409 1
262 ROLLINGDELL DR 7480 2
263 ROLLINGDELL DR 7497 1
264 RDLLINGDELL DR 7489 2
265 ROWNGDEIL DR 7497 1
266 KENTWOOD DR 1115 1
267 STANFORD PL - SIDE 7495 2
268 KENTWOOD DR X-FROM 1119 1
269 KENTWOOD DR 1123 2
270 KENTWOOD DR 1128 2
271 KENTWOOD DR 1143 2
272 STEEPLECHACE I.N. 1137 1
273 SCEEEPLECHACE LN. 1138 2 _
274 STEEPLECHACE LN. 1134 2
275 STEEPLECHA.CE IN. 1126 !
276 ST U. UrHACE IN. 1122 2
277 KENTWOOD DR 1151 3
278 KENTWOOD DR 1152 3
279sTEEPI&HACE IN. 1142 1
280 SlUTIEMCE IN. 1138 2
281 STEEPLECHACE IN. 1137 2
282 Sl IEMCE IN. 1110 2
283 STEEPLECHACE IN. 1113 1
284 S=IEMCE IN. 1117 1
285 STEEPIECHACE IN. 1114 2
286 RAMW DR 7424 1
287 RAUGOW DR 7553 1
288 RAINBOW DR 7595 1
289 RAINBOW DR 7669 1
SIDEWALK GRINDING PROJECT 91-106
LD. NUMBER DATE
NO. STREET NUMBER OF GRNMS COMPLETED
290 ORANGEBLMM DR — SIDE 7695 3
291 PEACHBLOSSOM DR — SIDE 7689 1
292 PEACHBLOS90M DR 7678 2
293 PRIMIM WY. 1343 1
294 PR94M WY. 1449 1
295 BARNHART PL 0 PRIMROSE WY. — N CORNER 3
296 WI DFIDWER WY. — SIDE 7448 1
297 WHDFLOWER WY. — SIDE 7447 1
298 FIDWER Cr. — SIDE 1330 2
299 JAMEMWN DR — SIDE 1463 1
300 JAMESTOWN DR — SIDE 1641 2
301 BARNHART PL 7420 1
302 BARNHART PL 7450 1
303 POPPY WY. — SIDE 1640 1
304 PRIMROBE WY. — SIDE 1648 3
305 DONEGAL DR 7511 2
306 ROSEGARDEN IN. 1496 1
307 NORMANDY WY, 7551 1
308 NORMANDY WY. 7575 1
309 NORMANDY WY. 7641 2
310 NORMANDY WY. 7680 3
311 WATERFDRD DR 7574 2
312 BWTY AVE. ® HOMESTEAD RD. — S W CORNER i
313 BLANEY AVE HWY 280 OVERPASS — S E SIDE 2
314 ORANGE M IN. 10555 1
315 CEDARTREE CT. 10552 2 _
316 BLINEY AVE — SIDE 10521 3
.317 MERRITT DR 20046 1
318 APPLE TREE IN. — SIDE 20075 1
319 APPLE TREE LN. 20157
320 APPLE TREE LN. 20189 i
321 VISTA DR X—FROM 10424 1
322 VISTA DR X—FROM 10184 !
323 FORE.T AVE 20206 2
324 FOREST AVE 20190 2
325 VISTA DR 10304—A 3
326 VISTA DR 10334—A 1
327 VISTA DR 10344—A 2
328 VISTA DR 10384—A 2
329 VISTA DR 10438 i
330 PEACHTREE IN. 20120 1
331 PEACHTREE LN. 20106 2
332 RANDY IN. 10208 2
333 RANDY IN. 10094 2
334 APPLETREE IN. X—FROM 20111 1
335 PUJMTREE IN. X—FROM 10462 1
336 PLUMTREE IN. _ 10439 1
337 PLLJbTTREE IN. 10401 1 2
SIDEWALK GRL%I)M PRWE T 91-106
I.D. NUMBER DATE
NO. gREEI' _ NUMBER OF GRINDS COMPLETM
338 BLANEY AVE. 10460 1
339 PEARIM IN. - SIDE 19990 2
340 BIANEY AVE _ 10295 2
341 TWIUGHT Cr, 19938 1
342 TWfllGHT Cr. - SIDE 19997 3
345 BLANEY AVE. 10140 2
346 WHEATON DR 20094 1
347 BLANEY AVE. ® FLORIST SHOP I
348 RODRDGUES AVE 20410 1
349 RDDREGUES AVE 20380 1
350 RDDREGUES AVE 20370 2
351 TORRE AVE X-F OM 10300 3
352 TORRE AVE 10393 1
353 IDEAN7A BL 10420 1
354 IFARAUDNE DR 10275 1
355 FARAUONE DR 10285 2
356 FARAUONE DR 10295 1
357 FARAUONE DR 10425 1
358 FARAUDNE DR - SIDE 10441 2
359 BRMANY Cr. - SIDE 10289 3
360 BRfMAY Cr. 10308 2
361 BRMANY Cr. 10299 1
362 [AS ONDAS WY. 20088 3
363 IAS ONDAS Cr. 20129 1
364 !IAS ONDAS Cr. - SIDE 20088 1
365 SILVERADO AVE. 20295 4
366 SILVERADO AVE 20309 1
367 SILVERADO AVE. 20351 2
368 SILVERADO AVE 20337 i
369 SILVERADO AVE 20294 1
370 CLAY ST. 20327 2
371 CLAY ST. 20337 2
372 CLAY ST. 20368 1
373 CLAY ST. 20348 2
374 CUFDEN WY. 20321 1
375 CUFDEN WY. 20345 2
376 CLIFDEN WY. 20351 1
377 CUFDEN WY. 20396 1
378 CUFDEN WY. 20388 2
379 GIWCK WY. 20324 1
380 MARTINWOOD WY. 10751 2
381 MARTINWOOD WY. 10765 8
382 GDSICK WY. 20353 2
383 GIUICK WY. 20387 2
384 CUFDEN WY. 20374 1
385 MICHAEL Cr SWE 20328 1
386 FARAD DNE DR 1 10619 3
387 FARAUONE DR - SIDE 10711 2
SIDEWALK GRINDING PROJECT 91-106
LD. NUMBER DATE
NO. SIPM NUMBER OF GRINDS COMPLETED
388 LA RODA DR 10762 1
389 LA RODA DR 10576 1
390 IA RODA DR 10577 1
391 ILA RODA DR 10605 2
392 LA RODA DR 10619 2
393 IA RODA DR 10647 1
394 IA RODA DR 10659 1
395 JOHN DR 20153 1
396 ISUISUN DR 20071 1
397 SULSUN DR 20087 1 _
398 SURN DR 20171 1
399 PACIFICA DR 20198
400 PACIFICA DR 20184
401 PACIFICA DR 20031 2
402 BLANEY AVE 10619 1
403 BLANEY AVE 10633 2
404 BLANEY AVE 10683 2
405 BLANEY AVE 10715 1
406 BLANEY AVE 10743 1
407 BOUJNGER RD. X-FROM 6834 1
408 BOUJNGER RD. X-FROM 6956 1
409 BAYWOOD DR 10481 1
410 BAYWOOD DR 19855 2
411 BAYWOOD DR 19866 2
412 BAYWOOD DR 19854 3
413 PEARTREE LN. X-FROM 19866 1
414 FIGTREE Cr. 19907 3
415 PEARTREE IN. 19936 1
416 PEARTREE IN. 19955 2
417 PEARTREE IN. 19967 1
418 BLANEY AVE 10390 1
4:3 MERRIT DR 19888 1
420 MERRIT DR 19872 3
421 MERRIT DR 19850 1
422 DEODARA DR - SIDE 10484 2
423 DEODARA DR 10490 3
424 DEODARA DR 10511 2
425 CYPRESS DR 10510 1
426 CYPRESS Cr. - SIDE 10571 1
427 CYPRESS DR 10511 2
428 CYPRESS DR 10491 1
429 AUBURN DR 19745 1
430 AUBURN CT. 19721 2
431 DRAKE DR 19705 1
432 DRAM DR - SIDE 19750 1
433 PORTAL AVE 10602 4
434 PORTAL AVE 10601 2
435 PORTAL AVE 10551 2
SIDEWALK GRINDING PROJECT 91-106
I.D. NUMBER DATE
N0, STREETNUMBER OF GRM COMPLETED
436 PORTAL AVE 101.37 1
437 MC'C1AREN Pi. 10146 2
438 WHEA'!ON DR li-FROM 19884 1
439 NORWICH AVE. 10332 1 1
440 NORWICH AVE 10346 1
441 BAYWOOD DR - ME 10480 4
442 MERRIT DR 19665 2
443 MERRIT DR 19707 1
444 MERRIT DR 19710 1
445 DENNISON AVE 10377 2
446 DENNISON AVE 10349 1
447 DENNISON AVE 10272 1
448 PORTAL AVE 10384 1
449 COLBY AVE 10449 1
450 COLBY AVE. 10384 1
451 COLBY AVE 0368 1
452 COLBY AVE 10299 1
453 AMHERSI' DR 19776 1
454 COLBY AVE. 10225 2
455 PORTAL AVE 10128 1
456 PORTAL AVE 10142 1
457 PORTAL AVE 10154 3
458 PORTAL AVE 100°S. OF STEVEN CRK BL E SIDE 2
459 PRICE AVE 19831 1
460 DEEPROSE Pl. 10152 4
461 DEEPROSE Pl. 10151 2
462 MELID PL - SIDE 10170 1
463 MELLO Pl. 10119 2
464 COLD HARBOUR AVE - SIDE 10257 4
465 WINTERGREEN DR 19733 2
466 PORTAL AVE 10204 2
467 AVACADO Pl. 10215 2
468 BI?®Y DR 10752 1
469 BVMY DR 19742 1
470 COLD HARBOR AVE 10327 1
471 COLD HARBOR AVE 10338 1
472 COLD HARBOR AVE 10338 1
473 COLD HARBOR AVE 10328 1
474 BIXBY DR 19741 1
475 BD(BY DR 19751 1
476 RICHWOOD DR 19618 1
477 RICHWOOD DR 10119 2
478 RICHWOOD DR 10143 3
479 RICHWOOD DR 10184 1
480 RICHWOOD DR 10265 1
481 RICHWOOD DR 1 10277 2
482 RICHWOOD DR 10301 2
483 RICHWOOD DR 10325 2
SIDEWAIX GRINDING PROJECT 91-106
I.D. NUMBER DATE
NO NUMBER OF GRINDS COMPLETED
484 VICKSBUR DR 19711 3
485 VICKSBURG DR 19756 2
486 VICKSBURG DR 19736 1
487 VICKSBURG DR 19718 4
488 VICKSBURG DR 19702 2
489 VICKSBURG DR 19688 1
490 VICKSBURG DR 10311 1
491 RESTATES DR 10159 1
492 IRESrATES DR 10253 1
493 EESTATES DR l0265 1
494 VICKSBURG DR 19660 3
495 IA MAR CT. 19621 1
496 IA MAR Cr. 19631 2
497 LA MAR CT. 19745 1
498 1?, MAR CT. 19759 2
499 IA MAR CT. 19787 1
500 GUNAEW DR - SIDE 10340 1
501 IJN SAY AVE - SIDE _ _ 10361 3
502 IA MAR DR 19828 1
503 IA MAR DR 19778 1
504 IA MAR DR - SIDE 19764 3
505 OAKVUlE DR 10380 1
506 RESTATES DR _ 10400 1
507 EESTATES DR 10466 1
508 RESTATES DR 10465 2
509 RESTATES DR - SIDE 10481 5
510 EESTATES DR 10620 1 _
511 RESTATES DR 10611 1
512 E.ESE'ATES DR 845 2 _
513 IEESTATES DR 854 2
514 RESTATES DR 858 1
515 i?ESTATES DR 862 1
516 EESTATES DR 866 i
517 RESTATES DR 883 1
518 W.ESTATES DR 10880 1
519 W.ESTATES DR - SIDE 10832 1
520 W.ESTATES DR 10825 2
521 W.ESTATES DR 10809 1
522 W.ESTATtS DR 10784 1
523 WUDWBROOK WY. 10775 2
524 WIIIDWBRDOK WY. 10822 1
525 IWWWBROOK WY. 10810 1
526 UNDENBROOK IN. 19863 3
527 JOHN DR 6756 1
528 JOHN DR 6724 1
529 JOHN DR 6721 2
530 IBETLIN AVE 877 1
531 JBETTE AVE. 861 1
a
SIDEWALK GRINDING PROJECT 91-106
LR NUMBER DATE
NO. STREET NW-dER OF GRINDS COMPLETED
532 BRENT DR - SIDE 889 1
533 BETTE AVE 852 3
534 BETTE AVE. 858 1
535 CUFFORD DR X-FROM 6675 1
536 CUFFORD DR 8559 2
537 CUFFORD DR 6685 2
538 CUMRD DR 6707 1
539 CUFFORD DR 6743 3
540 CLIFFORD DP. 6751 2
541 GIENV[EW AVE _ TT 10377 2
542 GLENVIEW AVE -rn_ 10395 2
543 G AVE -� 10412 4
544 GLENVIEW AVE .__-.._ _ 104E5 2
545 GLENVIEW AVE �_ 10511 1
546 AKV[EW AVE - SIDE 10510 1
547 BETTE AVE. - SIDE 10550 2
548 GLENVIEW AVE 10551 3
549 GLEN'VIEW AVE 10559 2
550 PINEVIL E AVE - SIDE 10530 2
551 GIENM AVE. 10580 2
552 GLENVIEW AVE. 10583 2
553 GLENVIEW AVE. 10615 1
554 RAMPART' AVE I Ir,31 3
555 RAMPART 01 10489 1
556 RAMPART AVE 10475 1
557 DAVMS0N AVE 10460 1
558 DAVHWN AVE 10471 2
559 DAVIDSON AVE i 10491 1
560 DAVIDSON AVE 10501 1
561 DAVIDSON AVE 10511 2
562 PINEVIIII AVE 10520 1
563 PINEVUE AVE. 10460 1
564 PINEVIUE AVE. 10450 1
565 PINE UZ AVE. 10420 2
566 OAKVW AVE 10390 3
567 OAKVM AVE 10401 1
568 OAKVW AVE 10420 2
569 OAKV U AVE 10431 1 2
570 OAKVIEW AVE 10441 2
571 UNDSAY AVE 10420 5
572 UNDSAY AVE 10451 2
573 UNDSAY AVE. 10381 2
574 UNDSAY AVE 10370 1
575 UNDSAY AVE. 10369 1
576 GREENWOOD CT. 91515 1
577 GREENWOOD Cr. 10323 2
578 GREENWOOD CT. 10362 1
579 GREENWOOD Cr. - SIDE 10337 1
SIDEWAU( GRINDING PROJECT 91-106
LD, NUMBER DATE
INO. STREET NUMBER OF GRINDS COMPLETED
580 MINER AVE W/SIDE 10381 1
581 MUM AVE ! SIDE 10505 1
582 ATHERWOOD AVE 6329 2
583 ATHERWOOD AVE 801 1
584 ATHERWOOD AVE X—FROM 6363 1
585 AIDERBROOK LN. 803 2
586 UDERBROOK LN. X—FROM 857 1
587 ALDERBROOK IN. 887 1
588 BLAZINGWOOD AVE 928 2
589 BLAZINGWOOD AVE. X—FROM 937 3
590 MYRTIEW00D DR — SIDE 6390 2
591 MYR71EWOOD DR _ 6367 3
592 COTTONWOOD CT. 6377 1
593 MI11.ER AVE 849 1
594 MILDER AVE 973 1 2
595 MIII.ER AVE 868 3
596 Hn7)E AVE 6148 1
597 TANTAU AVE 923 1
598 FINCH AVE 10465 1
599 FINCH AVE 10451 2
600 STEVEN CRWK BL X—FROM N SIDE 19444 2
601 TANTAU AVE 50' N OF STEVENS LRK. BL E SIDE 1
602 VALLCO PARKWAY N SIDE 19191 1
603 VAIWO PARKWAY 50'F. OF CREEK N SIDE 1
604 VALLCO PARKWAY 100'E OF WOLF RD. N SIDE I
605 HOMESTEAD RD. 0 WOLF SHELL STATION 1
606 WOLF RD. BEFORE FFiTWAY 4 PARKING UYT W SIDE 2
607 WOLF RD. 0 HWY 280 OVER PASS W/SIDE 1
608 WOLF RD. 200'N OF STEVENS CREEK BI. W SIDE 3
609 RICHWOOD CT. 19460 2
610 RICHWOOD Cr. 19470 4
611 RICHWOOD CT. 19480 1
612 ROSE MARIE PL 19472 1
613 GREENWOOD DR X—FROM 9425 2
614 LEOLA Cr. 10331 1
615 GREENWOOD DR 19385 2
616 W01-F RD, BETWEEN PRUNRQDGE&HOMESTEAD E SIDE 4
fi 17 WOLF RD. 7 WEEN HOMFSTEAD&HWY280 W SIDE 11
T 0 T AL 959
BIDDERS PROPOSAL PAGE
SIDEfr LK MINDING
PRWECT 91-106
GEI lITIMEN:
The below named and undersigned bidder hereby pry to do all work
required to conplete the said work in accordance with the specifications
and/or plans for the amounts set forth herein on the incorporated
schedule.
All necessary preparation as well as cleanup is included in the prices bid
and no extra cwnpensation will be allowed. All work will be done in a
workmanlike manner and will meet or exceed the embodied requirements
and/or the standards stipulated by the City Engineer
The undersigned also understands that the quantities shown below are
estimates only, being given as a basis for the extension of the unit
prices bid. The extension will be the basis for ccararison of bids by the
Director of Public Works.
The work to be donne consists of furnishing all labor, methods, or process,
tools, Machinery and material required to coWlete the sidewalk grinding
as described in the ,special Provisions.
BID EST. QTY.
IT'Fri UNIT UNIT PRICE TOTAL
1. 959 Ea Provide for grinding of P.C.C. $ c2. /Ea $
sidewalk where displacement is
greater than 010 and less than
or equal to 211
Svc L,A,�.5 A 0 D °J,t, OTS
s 6. r
TOTAL BID:
I-h
BID PROPOSALr PAGE 1 OF' 6 12
I, the undersigned agree that if this prcporal is accepted, I will
enter irta a cmitract with the city of Cupertino to provide all neoemgaxy
maduner}, tools, apparatus, and other means of construction and to do all
the work specified in the om-itract, in the manger and time specified.
I, the signed declare that this bid is made without connection
with any person, firm, or corporation makuq a bid for the salve work, and
is in all respect fair, and without collusion or fraud.
I, the undersigned recognize that the Director of Public Works of
the City of 043extino will reserve the right to establish the priority of
one job over another and each startiiq date where ,conflict of construction
schedules occur.
Attached hereto is the required certified deck or bid bond in the
amount of $ 1U To , as required by lva and the Notice to Bidders
(10% of bid amount)
BID PROPOSAL PAGE 2 OF 6
A. BID DOCK+'MM, 0antinued
BIDDER QUALMCATION FCM
In further conplianoe with the specifications furnished, the
undersigned submits the following statements as to his experience and to
his qualifications as a part of this proposal, and the and
utterance of the information is hereby guaranteed.
(1) How many years has your organization been in
lousiness under its present name? 15 Y C A k S
(2) How many years experience in dark cagarable with
that required under the pied contract has your
organization had by this or any other name> S y C Ap--s
(3) Contractor's License No. ---�10.29 2 ,
State of California Classification A c g
Expiration Date 3i 9
(4) List work similar in character to that required in the
proposed contract which your organization or personnel in
your organization has coupleted within the past 3 years.
Year Class, Location of Work and for Mm Performed Contract Amount
BID PROPOSAL PAGE 3 OF 6
Q d E L E IED--CQ tJ.1 R-()G'l
6QEKYZQQNIACI QLS Q R I E I IQ N 0 M-Q UNi T
U.S.P.S, S.F. I ri-t-ri L i) i r p o'r is J. 1) 0 G.151
Byron Wl* L 1. i -a Load i n 9 E)c)c 1. M(3(1 i
876-9414
U n i v. Ca L i f 11 av i L a-4-1 d H i.-I 1. 1. 5().. 0 0 00
Car I ton `-.'t Nand i c.a r--, rt o c I i -f i c-t:(-t j (3 r,
Berketey
Vic Taylor
642-0489
Un i V. Ca L i f S, i to J.,ift p-I.-o-v m E--:.1-1 t 1:- 1") 0 0 0
(5ame as ---ibc--ve)
K a i s e r C-o n 5u c:a" i c,r, V a r j (-j Lt s y.is
101 0
17 8 0--2n al
Berkel.c.,!v ,
R o n Me 1. 1.c)
428-6475'
City of Unior, 4'> 0 0 0 0
AL, a r a d o N i 1. F"d IMP,
Union City , CA Decolc- ic.t
J i (11 G 1-1 c.?(11 c,-I.
4-1,J.--3,:,:X
F,Or A- c)-f 1" I
66 JacJ-1- LcaMd S k 1. o
OakLa-rid , C ]
R u f i I-I C) 0 La
4 Al.1 J.C3 0
%J
Mad i .t:l'ov-1 c:i I fil(.i(1 d Y) i it I i c!"i
0 a k L a)i cl J C A C c-.-,-I--) t c,1,
4,
Int-avid (.*,c.,-,,il-a V i ne v id o u kJ I I ,
37333-Ceclar D 1.vcl c"!)-ICI 1 1-1 C-?C1 1 4"i(.), 000 .00
Newark , C a i ng , a a 1. .l. , c c)n c:v e I e
Fred I ars d s-b e r g
7 9 7--2)0 2 1
County of Alameda Yf-cec---!t 2 D 0 00
399 Etinhurs-1- St , F-*,ob i vi./F' i r
Hayward , CA
Pau I Char Les
670--54cN,
L
U P.9 Improvements to 2296, 000.0
Payhill Drive Evans Ave. lli i I
San F(runa, CA Fa c i L i t y
Byron WILliamE
S76-9414
C i t y C)f 9(1 rul-i-Yva Le Math i L d C-3- Pi 4 0 0
456 West Ol. ive Ave M e d i art--t :1:s- 1,a d
gunnyvaLe, CA
Ernie Y o s h i z u k a
(408) 730--7429
Co. of Santa Ctara Va Y. i a(I s Con t Y.a C.t s 360, 000.00
Tr a n5p or t a t ion Efus Stop Pavement
1555 Berger Drive
San Jose, CA
Hugh Hancock
(406) '291721!59i
City of Sunrly-val.e M u r p h.v a t i C)1- 8 19L kl)0 0 1")
456 Uert OLi %.fe Ave
S U-1-1 r-I Y,,a
R L)9 e Y- J e n 1, i -ris
Wash incitcrri k1tDc.-Pital. Park i L 6 0 , 00 0
2000 M o w-r y v e B o x C,ki I (,,"r t r tj t i o n
Frett.ont , CA
Vern
?65 0
L i u i d i WO If Y cl Yl 57-f i I. L
is to I—g e 11 u I:j 1,
I I S.
Tr i..i n',: I yj r')')
PY , I
J.5.5`5 f.:c.,r(:1 1.)-r i t:i B U i L d i vi a e I"
H u 9 I's a.1.) c'
4 0 8
C i t y c,f 41 a Lrtut Cf-(-..? k N c)t.-t h Ma i rl S t e e A, 205. 500 .00
1666 1\1(.-.,r 1.f I I'l a i n 9 t 1(11 p r(:.,"I(-.?(11 e n
W a L u 1 C"-f- k A
Vic .�N.e i 1.
94351:300
C i t Y of W a L r,u-1 e C a I i fiarn i a N e w e 1. L/ J.92, i00.00
:same as a b(:)v e :7 G ki'(h M t-) i '0 't V C?C!t
i t Y f W a L ri u t k C)- (:.?c.k P e a u f i c:a t i L)Y) 483, 6." 0.00
r
A. BID DOCLHNM, Cm*Arnled
NaMS Of PZRpo , if any
(Section 4104, Goverrmlent Code)
2.
3.
4.
5.
6.
Address if Shop or Office of Sub-Contractcrs
(Section 4104, Govenment Code)
1.
2.
3.
4.
5.
6.
Work to be Performed by Sob-Contractors
(Section 4104, Goverrmient Code)
1.
2.
3.
4.
5.
6.
BID PROPOSAL PAGE 4 OF 6
A. BID Doamm, continued
IF YOU AIM AN INDIVIIR AL, 90 STATE. IF YOU AIM A FIM4 OR CD-PAMMSHIP,
STATE THE FERMI NAIL AND LIST THE IMM OF ALL INDIVIDUAL OD•-PAR31ERS
cctq osiNG 7M FITdMi. IF A 0ORPORATICUP STATE LEGAL NAIL OF MWORMON,
ALSO NAM OF PMMERr, SBCFMMM AND Rom. TIM ORATE
SEAL MUST BE AFFI)CED. ZIE YNFCROMC N C OMUNED IN THIS BID IS BEING MADE
UJMER PENALTY OF PERJURY.
TYPE OF BUSINESS: Individual.:
Oo-Fartr�x'ship .
corporation A M �3r, ENL�In>EEiti/n)C, �IyC -
Joint Venture
Other
(Describe)
Name and sicaSETO
I RILSWENT
(Si tug
Address (Both mailing and 1 on ate) :
Telephone: NLmter:
Date..
Addendas Rived:
1 2 3 4 5
BID PROPOSAL PAGE 5 OF 6
NONODYUBION AFF=Vn TO BE EKEC= BY
BIDDER AM SLR%U= WITH BID
State of California ss.
County of L n 6 !r-D/I
r'O:.r Fr-) being first duly sworn, deposes
and says that he or she is -- k ;.�Lnrr" of /\nA r ,) L IV(-I I/0 C C A)
the party making the foregoing bid that the bid is not made in the
interest of, or on behalf of, any undisclosed person, partnership,
company, association, organization, or corporation; that the bid is
genuine and not collusive or sham; that the bidder has not directly or
indirectly induced or solicited any other bidder to put in a false or sham
bid, and has not directly or indirectly colluded, cm spired, connived, or
agreed with any bidder or anyone else to put in a sham bid, or that anyone
shall refrain from bidding; that the bidder has not in any manner,
directly or inairectly, sought by agreement, communication, or conference
with anyone to fix the bid price of the bidder or any other bidder, or to
fix any overhead, profit, or cost element of the bid price, or of that of
any other bidder, ot• to secure any advantage against the public body
awarding the contract cif anyone interest in the proposed contract; that
all statements contained in the bid are true; and, further, that the
bidder has not, directly or indirectly, submitted his or her bid price or
any breakdown thereof, or the contents thereof, or divulged information or
data relative thereto, or paid, and will not pay, any fee to any
corporation, partnership, company association, organization, bid
depository, or to any member or agent thereof to effectuate a collusive or
sham bid.
Name and Signature of Bidder:
MMV
(Print)
(Sicilia e)
Date: ` '
BID PROPOSAL PAGE 6 OF 6