09-141 O'Grady Paving IncE. CONTRACT FOlft PUBLIC WORKS ~~ ~ ~6',J'9f`
This CONTRACT made on `~~~-~-vw~-y Z~~ w~l by the CITY OF
CUPERTINO, a municipal corporation of the Mate of California, hereinafter called CITY, and
O'GRADY PAVING INC., hereinafter called CONTRACTOR.
IT IS HEREBY AGREED by CITY and CONTRACTOR as follows:
1. THE CONTRACT DOCUMENTS. The complete contract consists of the following
contract documents:
a. Notice to Contractors, Proposal, Time of Completion, Estimated Quantities, Noncollusion
Affidavit, Bidder Qualification Form, Subco~itractors Form and Signature Form.
b. Standard Specifications, General Provisions ~~nd Special Provisions.
c. Plans and Specifications for 2009 HOMES;i'EAD ROAD REHABILITATION, PROJECT
NO. 2009- p5.
d. Faithful Performance Bond and Payment Borid.
e. Insurance Agreement, Certificate of Insurance, Endorsement of Primary Insurance,
Additional Insured Endorsement, Endorseme-nt of Aggregate Limits of Insurance per Project,
Waiver of Subrogation Endorsement Worker's Compensation Insurance and Notice of Policy
Cancellation Endorsement.
f. This Contract for Public Works.
All of the above documents are intended to cooperate so that any work called for in one and not
mentioned in the other, or vice versa, is to be Esxecuted the same as if mentioned in all of said
documents. The documents comprising the complete contract are sometimes hereinafter referred
to as the Contract Documents. In case of conflict between the Plans and the Specifications on the
one hand, and this Contract on the other, the Plaris and Specifications shall prevail.
2. THE WORK. CONTRACTOR agrees t~~ furnish all of the tools, equipment, apparatus,
facilities, labor, transportation and materials necessary to perform and complete in a good and
working order, the work of overlaying City streets, as called for, and in the manner designated in,
and in strict conformity with, the Plans and Specifications prepared by the Engineer and adopted
by CITY, which Plans and Specifications are entitled, respectively, 2009 HOMESTEAD ROAD
REHABILITATION, PROJECT NO. 2009-02 rind which Plans and Specifications are identified
by the signatures of the parties to this Contract. It is understood and agreed that said tools,
equipment, apparatus, facilities, labor, transportation and materials shall be furnished, and that
said work shall be performed and completed as required in said Plans and Specifications under
the sole direction of CONTRACTOR, but subject to the inspection and approval of CITY, or its
representative.
CITY hereby designates as its representative fo:r the purpose of this Contract the Engineer, Mr.
Ralph A. Qualls, Jr.
l :i 4
3. CONTRACT PRICE. CITY agrees to p~iy, and CONTRACTOR agrees to accept, in full
payment for the work above agreed to be do~1e, the sum of $606,609.10 (Six Hundred Six
Thousand, Six Hundred Nine Dollars and Ten Cents) subject to additions and/or deductions as
provided in the Contract Documents, per Exhibit A attached hereto.
4. DISPUTES PERTAINING TO PAYMENT FOR WORK. Should any dispute arise
respecting the true value of the work done, or any work omitted, or any extra work which
CONTRACTOR may be required to do, or respecting the size of any payment to
CONTRACTOR during the performance of this Contract, said dispute shall be determined either
by reference to the Unit Prices bid, if applicab fie, or in accordance with agreement of prices, if
applicable, or in accordance with the agreement of the parties, or in accordance with Section 6,
paragraph "f ' of the General Provisions.
5. PERMITS, COMPLIANCE WITH LAW,. CONTRACTOR shall obtain and bear all
expense for all necessary permits, licenses and easements for the construction of the project, give
all necessary notices, pay all fees required by law, and comply with the laws, ordinances and
regulations relating to the work and to the preservation of the public health and safety.
6. INSPECTION BY THE CITY. COI`1TRACTOR shall at all .times maintain proper
facilities and provide safe access for inspection ley CITY to all parts of the work, and to the shops
wherein the work is in preparation. Where the Specifications require work to be specially tested
or approved, it shall not be tested or covered up without timely notice to CITY of its readiness
for inspection and without the approval thereo:F or consent thereto by CITY. Should any such
work be covered up without such notice, approval, or consent, it must, if required by CITY, be
uncovered for examination at CONTRACTOR';i expense.
7. EXTRA OR ADDITIONAL WORK ANDS CHANGES. Should CITY at any time
during the progress of the work require any alterations, deviations, additions or omissions from
the Plans and Specifications or the Contract Documents, CITY shall have the right to do so, and
the same shall in no way affect or make void the Contract, but the cost or value thereof will be
added to, or deducted from, the amount of the Contract price, as the case may be, by a fair and
reasonable valuation, which shall be determined either by reference to the Unit Prices bid, if
applicable, the Standard Specifications, or in accordance with the agreement of the parties. No
extra work shall be performed or change be rr~ade except by a written order from CITY, duly
authorized by resolution of the City Council, acid by all agencies whose approval is required by
law, stating that the extra work or change is authorized, and no claim for an addition to the
Contract sum shall be valid unless so ordered.
8. CHANGES TO MEET ENVIRONMENTAL REQUIREMENTS. CITY shall have the
right to make changes in this Contract during the course of construction to bring the completed
improvements into compliance with envirorur~ental requirements or standards established by
State and Federal statutes and regulations after the Contract has been awarded or entered into.
CONTRACTOR shall be paid for such changes either by reference to the Unit Prices bid, if
applicable, or in accordance with the agreement of the parties.
9. TERMINATION, AMENDMENT OR M~~DIFICATION. This Contract may be
terminated, amended or modified, with the m~rtual consent of the parties. The compensation
135
payable, if any, for such termination, amendment or modification, shall be determined either by
reference to the Unit Price bid, if applicable, the Standard Specifications, or in accordance with
the agreement of the parties.
10. TIME FOR COMPLETION. All wort: under this Contract shall be completed in
accordance with the Time for Completion section in the Proposal and the Specifications of this
project. If CONTRACTOR shall be delayed iii the work by the acts or neglect of CITY, or its
employees, or those under it by contract or otherwise, or by changes ordered in the work, or by
strikes, lockouts by others, fire, unusual delay in transportation, unavoidable casualties or any
causes beyond CONTRACTOR'S control, or by delay authorized by CITY, or by any cause
which CITY shall determine justifies the dela}~, then the time of completion shall be extended
accordingly. This paragraph does not exclude the recovery of damages for delay by either party
under other provisions in the Contract Documer.,ts.
11. INSPECTION AND TESTING OF MATERIALS. CONTRACTOR shall notify CITY
a sufficient time in advance of the manufacture, production or testing of materials to be supplied
under this Contract, in order that CITY may arr;~nge for mill, factory or laboratory inspection and
testing of same.
12. TERMINATION FOR BREACH OR INSOLVENCY. If CONTRACTOR should be
adjudged a bankrupt, or should make a gener~il assignment for the benefit of creditors, or if a
receiver should be appointed on account ~~f insolvency, or if CONTRACTOR or any
subcontractor should violate any of the provisions of the Contract, CITY may serve written
notice upon CONTRACTOR and CONTRAC'TOR'S surety of its intention to terminate the
Contract. Such notice shall contain the reasons for CITY'S intention to terminate the Contract,
and unless within ten (10) days after serving of such notice, such violation shall cease and
satisfactory arrangements for corrections thereof be made, the Contract shall, upon the expiration
of said ten (10) days, cease and terminate. Iii the event of any such termination, CITY shall
immediately serve notice thereof upon CONTRACTOR'S surety and CONTRACTOR, and the
surety shall have the right to take over and perform the Contract; provided, however, that, if the
surety within fifteen (15) days after the serving upon it of notice of termination does not give
CITY written notice of its intention to take over and perform the Contract, or does not commence
performance thereof within thirty (30) days fr~~m the date of the serving of such notice, CITY
may take over the work and prosecute the s~une to completion by contract, or by any other
method it may deem advisable, for the account and at the expense of CONTRACTOR, and
CONTRACTOR AND CONTRACTOR'S surety shall be liable to CITY for any excess cost
occasioned by CITY thereby, and in such eve~it CITY may, without liability for so doing, take
possession of, and utilize in completing the work, such materials, appliances, plant and other
property belonging to CONTRACTOR as may be on the site of the work and necessary therefor.
13. THE CITY'S RIGHT TO WITHHOLD CERTAIN AMOUNTS AND MAKE
APPLICATION THEREOF. In addition to amounts which CITY may retain under other
provisions of the Specifications until final completion and acceptance of all work covered by the
Contract, CITY may withhold from payment to CONTRACTOR such an amount or amounts as
in its judgment may be necessary to pay just ~:laims against CONTRACTOR or subcontractors
for labor and services rendered and materials furnished in and about the work.
136
City may apply such withheld amount or amounts to the payment of such claims in its discretion.
In doing so, CITY shall be deemed the agent o:F CONTRACTOR, and any payment so made by
CITY shall be considered as a payment made under the Contract by CITY to CONTRACTOR,
and CITY shall not be liable to CONTRACTOR for any payment made in good faith. Such
payment may be made without prior judicial determination of the claim or claims. With respect
to any retention of payment by CITY to ensure: performance of the Contract, CONTRACTOR
will be entitled to substitute securities as provided in Section 4590 of the California Government
Code as more fully described in CITY' S Notice to Contractors.
14. NOTICE AND SERVICE THEREOF. Any notice from one party to the other under
this Contract shall be in writing, and shall be dated and signed either by the party giving such
notice, or by a duly authorized representative of such party. Any such notice shall not be
effective for any purpose whatsoever unless served in the following manner: (a) if the notice is
given to CITY, either by personal delivery thereof to the Engineer of CITY, or by depositing
same in the United States mails, enclosed in a sealed envelope, addressed to CITY OF
CUPERTINO; 10300 TORRE AVENUE; C'UPERTINO, CA 95014; postage prepaid and
certified; (b) if the notice is given to CONTRACTOR, either by personal delivery thereof to
CONTRACTOR, or to CONTRACTOR'S duly authorized representative at the site of the
project, or by depositing same in the United States mails enclosed in a sealed envelope,
addressed to O'GRADY PAVING, INC., ?513 WYANDOTTE STEER, MOUNTAIN
VIEW, CA 94043-2314, postage prepaid <<nd certified; and (c) if notice is given to
CONTRACTOR'S surety or any other person, either by personal delivery thereof to
CONTRACTOR'S surety or other person, or by depositing same in the United States mails,
enclosed in a sealed envelope, addressed to C01~1TRACTOR'S surety or person, as the case may
be, at the address of CONTRACTOR'S surety or the address of the person last communicated by
such person to the party giving the notice, posta€;e prepaid and certified.
15. ASSIGNMENT OF CONTRACT. Neither the Contract, nor any part thereof, nor
moneys due or to become due thereunder, shall lie assigned by CONTRACTOR without the prior
written approval of CITY.
16. COMPLIANCE WITH SPECIFICATIONS OF MATERIALS. Whenever in the
Specifications, any material or process is indicated or specified by patent or proprietary name, or
by name of manufacturer, such Specifications must be met by CONTRACTOR, unless CITY
agrees in writing to some other material, process or article offered by CONTRACTOR which is
equal in all respects to the one specified. It sh;~ll be CONTRACTOR'S responsibility to prove
equality of any such material, process or article offered as a substitution to the one(s) specified.
17. WORKER'S COMPENSATION INSUURANCE AND EMPLOYER'S LIABILITY
INSURANCE. CONTRACTOR shall take ~~ut and maintain during the life of this Contract
Worker's Compensation Insurance and >=;mployer's Liability Insurance for all of
CONTRACTOR'S employees employed at the site of the project. In case any work is sublet,
CONTRACTOR shall require any and all subcontractors similarly to provide Worker's
Compensation and Employer's Liability Insura~ice for all of the Tatter's employees unless such
employees are covered by the protection afforded to the CONTRACTOR.
In signing this Contract CONTRACTOR maker the following certification, required by Section
1861 of the Labor Code: "I am aware of the provisions of Section 3700 of the Labor Code which
1:37
requires every employer to be insured against liability for worker's compensation or to undertake
self insurance in accordance with the provisions of the Labor Code, and I will comply with such
provisions before commencing the performance ~f the work of this Contract."
18. ACCIDENT PREVENTION. Pre~~aution shall be exercised at all times for the
protection of persons (including employees) and property. The safety provisions of applicable
laws, building codes and construction codes shall be observed. Machinery, equipment and other
hazards shall be guarded or eliminated in ~~ccordance with the safety provisions of the
Construction and Safety Orders issued by the [ndustrial Accident Commission of the State of
California.
19. CONTRACTOR'S RESPONSIBILITY FOR THE WORK. CONTRACTOR shall
not be responsible for the cost of repairing or restoring damage to the work caused by Acts of
God. NEVERTHELESS, CONTRACTOR shall., if the insurance premium is a separate bid item,
obtain the insurance to indemnify CITY for ar~y damage to the work caused by Acts of God.
"Acts of God" shall include only the following occurrences or conditions and effects:
earthquakes and tidal waves, when such occurrences or conditions and effects have been
proclaimed a disaster or state of emergency by the President of the United States or by the
Governor of the State of California, or were of a magnitude at the site of the work sufficient to
have caused a proclamation of disaster or state of emergency having occurred in a populated area.
Subject to the foregoing, CITY shall not, in ar.~y way or manner, be answerable or suffer loss,
damage, expense or liability for any loss or damage that may happen to said building, work, or
equipment or any part thereof, or in, on, or about the same during its construction and before
acceptance.
20. CONTRACTOR'S GUARANTEE. CONTRACTOR unqualifiedly guarantees the
first-class quality of all work and of all materials, apparatus and equipment used or installed by
CONTRACTOR or by any subcontractor or supplier in the project which is the subject of this
Contract, unless a lesser quality is expressly authorized in the Plans and Specifications, in which
event CONTRACTOR unqualifiedly guarantees such lesser quality; and that the work as
performed by CONTRACTOR will conform v~~ith the Plans and Specifications or any written
authorized deviations therefrom. In case of <<ny defect in the work, materials, apparatus or
equipment, whether latent or patent, revealed to CITY within one (1) year of the date of
acceptance of completion of this Contract by CITY, CONTRACTOR will forthwith remedy such
defects without cost to CITY.
138
~~ ~~~'
P.O. No.
21. DEFERRED ALTERNATE SELECTION.
The City reserves the right for the term of
the Contract, the deferred selection of none, any or all alternate bid items at the bid price. The
alternates chosen would be for any sites curren~:ly under construction or to be constructed in the
future.
IN WITNESS WHEREOF, the parties have executed this Contract, in duplicate, the day and
year first hereinabove written.
CITY OF CUPERTINO:
By`7'~ Id.- C~ C~ ~ CSC- GC
Ralph A. Qualls, Jr.
Director of Public works
Attest: 1~
City Cl rk
Date: ~~.pf a ® , 20 6 ~
City Clerk
APPROVED AS TO FORM:
1 !`/\ ' l~
X Q{
City Attorney
CONTRACTOR:
0'C~r P v. Svc .
By: --
Notary acknowledgment is required. If a
corporation, corporate seal and corporate
notary acknowledgment and Federal Tax
I.D. are required. If not a corporation a
Social Security No. is required.
gy-1493(o9Z
Social Security # Federal Tax I.D. #
Contractor's License No. ~<<O~ ~O
Project Name & Number: 2009 HOMESTEAD .ROAD REHABILITATION, PROJECT NO.
2009-02
~~~~~
Contractor's Name & Address: / ° Y_~ l~'~~
O'Grady Paving, Inc. ~ - f~
2513 Wyandotte Street
Mountain View, CA 94043-2314
Contract Amount: $606,609.10
Account Number: 27 -9 0 300
File No: 98,493.86 q
l
~~~o~~~v
,p ~~
l~ ~ ~ ~~~~ S ~ C ~~~~ ~f
~~
1..9
~'
A-
i
~~E~~~~°~a~e ~.~~~aW€~c~~~~~~
State of California
-- s s.
County of ~Y1-{-0~ ~ ~ Ya ,_
.._ ;-:
On ~ ~_ g 2~0~ before m =, ~ t t CD1 ~O(J e Z-~ ~ 0'~"G~ f P l
L
C
~
personally appeared
_~~.1,/~I ...... _
~ . Vr.~ 11n~.. .
_
- -
_,
., .,. .__ ; ....~ .
LJ ~J
who proved to me on the basis of satisfactory evidence to be the person(s) h sw oo e
name(s) is/are subscribed to the within instrument and acknowledged to me that
he/she/they executed the same in his/i~er/their authorized capacity(ies), and that by
his/her/their signature(s) on the instrument the persons}, or the entity upon behalf
of which the person(s) acted, executed the instrument.
~ I certify under PENALTY OF PERJURY under the laws of the State of California
~, the foregoing paragraph is true and correct.
MMNNHNHMN~WN~MI...MIW.
ERICA LOPEZ
COMM. #1814340 =
WITNESS my hand and official seal. "otary Public - carfornia ~
Santa Clara County
M~ Comm. Expires Se~. 21, 2012
x~x uunuauunuwuouanuuuuw unumxin~u~
c
Signature of Notary Public "' '''`~ " `''' ~'~'•I ~•-•~~-•• s~"i
'~~`~'`'o!'~'-~ My commission expires on:
l?~iiG!'~! Phone No.:
\ ~_. (wrill'li ...~~" - ~'1!i r~~Ii!"i~~ r aS~.!'1~
OFFICE OF THE CITY CLERK
CITY HALL
10300 TORRE AVENUE • CI~PERTINO, CA 95014-3255
TELEPHONE: (408) 777-322:3 • FAX: (408) 777-3366
WEBSITE: www.cupertino.orc~
CUPERTINO
October 29, 2009
O'Grady Paving Inc
2513 Wyandotte Street
Mountain View, CA 94043-2314
To Whom It May Concern:
Enclosed for your records is a fully executed copy of the agreement with the City of Cupertino.
If you have any questions or need additional information, please contact the Public Works
department at (408) 777-3354.
Sincerely,
CITY CLERK'S OFFICE
Enclosure
cc: Public Works