07-121, Able Underground E. CONTRACT FOR PUBLIC WORKS ~ ~
This CONTRACT made on August 21, 2007 by the CITY OF CUPERTINO, a municipal
corporation of the State of California, hereinafter called CITY, and
Able Underground Construction Inc. hereinafter called CONTRACTOR.
IT IS HEREBY AGREED by CITY and CONTRACTOR as follows:
1. THE CONTRACT DOCUMENTS. The complete contract consists of this contract and
the following contract documents incorporated herein by reference:
a. Notice to Contractors, Proposal, Time of Completion, Estimated Quantities, Noncollusion
Affidavit, Bidder Qualification Form, Subcontractors Form and Signature Form.
b. Standard Specifications, General Provisions, Special Provisions and Technical Provisions.
c. Specifications for Storm Drain Catch Basin Cleaning, Project No. 2007-OS
d. Faithful Performance Bond.
e. Insurance Agreement, Certificate of Insurance, Endorsement of Primary Insurance,
Additional Insured Endorsement, Endorsement of Aggregate Limits of Insurance per Project,
Waiver of Subrogation Endorsement Worker's Compensation Insurance and Notice of Policy
Cancellation Endorsement.
All of the above documents are incorporated into this contract by reference so that any work
called for in one and not mentioned in another, is to be executed the same as if mentioned in all
of said documents. The documents comprising the complete contract are sometimes hereinafter
referred to as the Contract Documents. In case of conflict between the Plans and the
Specifications on the one hand, and this Contract on the other, the Plans and Specifications shall
prevail.
2. THE WORK. CONTRACTOR agrees to furnish all of the tools, equipment, apparatus,
facilities, labor, transportation and materials necessary to perform and complete in a good and
working order, the work of cleaning storm catch basins, as called for, and in the manner
designated in, and in strict conformity with, the Plans and Specifications prepared by the
Engineer and adopted by CITY, which Specifications are entitled, respectively, Storm Drain
Catch Basin Cleaning, Project No. 2007-OS and which Plans and Specifications are identified
by the signatures of the parties to this Contract. It is understood and agreed that said- tools,
equipment, apparatus, facilities, labor, transportation and materials shall be furnished, and that
said work shall be performed and completed as required in said Plans and Specifications under
the sole direction of CONTRACTOR, but subject to the inspection and approval of CITY, or its
representative.
CITY hereby designates as its representative for the purpose of this Contract the Engineer, Mr.
Ralph A. Qualls, Jr.
1
3. CONTRACT PRICE. CITY agrees to pay, and CONTRACTOR agrees to accept, in full
payment for the work above agreed to be done, the sum of $49,600 (Forty Nine Thousand, Six
Hundred Dollars and No Cents) subject to additions and/or deductions as provided in the
Contract Documents, per Exhibit A attached hereto.
4. DISPUTES PERTAINING TO PAYMENT FOR WORK. Should any dispute arise
respecting the true value of the work done, or any work omitted, or any extra work which
CONTRACTOR may be required to do, or respecting the size of any payment to
CONTRACTOR during the performance of this Contract, said dispute shall be determined either
by reference to the Unit Prices bid, if applicable, or in accordance with agreement of prices, if
applicable, or in accordance with the agreement of the parties, or in accordance with Section 6,
paragraph "f' of the General Provisions.
5. PERMITS, COMPLIANCE WITH LAW. CONTRACTOR shall obtain and bear all
expense for all necessary permits, licenses and easements for the construction of the project, give
all necessary notices, pay all fees required by law, and comply with the laws, ordinances and
regulations relating to the work and to the preservation of the public health and safety.
6. INSPECTION BY THE CITY. CONTRACTOR shall at all times maintain proper
facilities and provide safe access for inspection by CITY to all parts of the work, and to the shops
wherein the work is in preparation. Where the Specifications require work to be specially tested
or approved, it shall not be tested or covered up without timely notice to CITY of its readiness
for inspection and without the approval thereof or consent thereto by CITY. Should any such
work be covered up without such notice, approval, or consent, it must, if required by CITY, be
uncovered for examination at CONTRACTOR'S expense.
7. EXTRA OR ADDITIONAL WORK AND CHANGES. Should CITY at any time
during the progress of the work require any alterations, deviations, additions or omissions from
the Plans and Specifications or the Contract Documents, CITY shall have the right to do so, and
the same shall in no way affect or make void the Contract, but the cost or value thereof will be
added to, or deducted from, the amount of the Contract price, as the case may be, by a fair and
reasonable valuation, which shall be determined either by reference to the Unit Prices bid, if
applicable, the Standard Specifications, or in accordance with the agreement of the parties. No
extra work shall be performed or change be made except by a written order from CITY, duly
authorized by resolution of the City Council, and by all agencies whose approval is required by
law, stating that the extra work or change is authorized, and no claim for an addition to the
Contract sum shall be valid unless so ordered.
8. CHANGES TO MEET ENVIRONMENTAL REQUIREMENTS. CITY shall have the
right to make changes in this Contract during the course of construction to bring the completed
improvements into compliance with environmental requirements or standards established by
State and Federal statutes and regulations after the Contract has been awarded or entered into.
CONTRACTOR shall be paid for such changes either by reference to the Unit Prices bid, if
applicable, or in accordance with the agreement of the parties.
9. TERMINATION, AMENDMENT OR MODIFICATION. This Contract may be
terminated, amended or modified, with the mutual consent of the parties. The compensation
payable, if any, for such termination, amendment or modification, shall be determined either by
2
reference to the Unit Price bid, if applicable, the Standard Specifications, or in accordance with
the agreement of the parties.
10. TIME FOR COMPLETION. All work under this Contract shall be completed in
accordance with the Time for Completion section in the Proposal and the Specifications of this
project. If CONTRACTOR shall be delayed in the work by the acts or neglect of CITY, or its
employees, or those under it by contract or otherwise, or by changes ordered in the work, or by
strikes, lockouts by others, fire, unusual delay in transportation, unavoidable casualties or any
causes beyond CONTRACTOR'S control, or by delay authorized by CITY, or by any cause
which CITY shall determine justifies the delay, then the time of completion shall be extended
accordingly. This paragraph does not exclude the recovery of damages for delay by either party
under other provisions in the Contract Documents.
11. INSPECTION AND TESTING OF MATERIALS. CONTRACTOR shall notify CITY
a sufficient time in advance of the manufacture, production or testing of materials to be supplied
under this Contract, in order that CITY may arrange for mill, factory or laboratory inspection and
testing of same.
12. TERMINATION FOR BREACH OR INSOLVENCY. If CONTRACTOR should be
adjudged a bankrupt, or should make a general assignment for the benefit of creditors, or if a
receiver should be appointed on account of insolvency, or if CONTRACTOR or any
subcontractor should violate any of the provisions of the Contract, CITY may serve written
notice upon CONTRACTOR and CONTRACTOR'S surety of its intention to terminate the
Contract. Such notice shall contain the reasons for CITY'S intention to terminate the Contract,
and unless within ten (10) days after serving of such notice, such violation shall cease and
satisfactory arrangements for corrections thereof be made, the Contract shall, upon the expiration
of said ten (10) days, cease and terminate. In the event of any such termination, CITY shall
immediately serve notice thereof upon CONTRACTOR'S surety and CONTRACTOR, and the
surety shall have the right to take over and perform the Contract; provided, however, that, if the
surety within fifteen (15) days after the serving upon it of notice of termination does not give
CITY written notice of its intention to take over and perform the Contract, or does not
commence performance thereof within thirty (30) days from the date of the serving of such
notice, CITY may take over the work and prosecute the same to completion by contract, or by
any other method it may deem advisable, for the account and at the expense of CONTRACTOR,
and CONTRACTOR AND CONTRACTOR'S surety shall be liable to CITY for any excess cost
occasioned by CITY thereby, and in such event CITY may, without liability for so doing, take
possession of, and utilize in completing the work, such materials, appliances, plant and other
property belonging to CONTRACTOR as may be on the site of the work and necessary therefor.
13. THE CITY'S RIGHT TO WITHHOLD CERTAIN AMOUNTS AND MAKE
APPLICATION THEREOF. In addition to amounts which CITY may retain under other
provisions of the Specifications until final completion and acceptance of all work covered by the
Contract, CITY may withhold from payment to CONTRACTOR such an amount or amounts as
in its judgment may be necessary to pay just claims against CONTRACTOR or subcontractors
for labor and services rendered and materials furnished in and about the work.
City may apply such withheld amount or amounts to the payment of such claims in its discretion.
In doing so, CITY shall be deemed the agent of CONTRACTOR, and any payment so made by
3
self insurance in accordance with the provisions of the Labor Code, and I will comply with such
provisions before commencing the performance of the work of this Contract."
18. ACCIDENT PREVENTION. Precaution shall be exercised at all times for the
protection of persons (including employees) and property. The safety provisions of applicable
laws, building codes and construction codes shall be observed. Machinery, equipment and other
hazards shall be guarded or eliminated in accordance with the safety provisions of the
Construction and Safety Orders issued by the Industrial Accident Commission of the State of
California.
19. CONTRACTOR'S RESPONSIBILITY FOR THE WORK. CONTRACTOR shall
not be responsible for the cost of repairing or restoring damage to the work caused by Acts of
God. NEVERTHELESS, CONTRACTOR shall, if the insurance premium is a separate bid item,
obtain the insurance to indemnify CITY for any damage to the work caused by Acts of God.
"Acts of God" shall include only the following occurrences or conditions and effects:
earthquakes and tidal waves, when such occurrences or conditions and effects have been
proclaimed a disaster or state of emergency by the President of the United States or by the
Governor of the State of California, or were of a magnitude at the site of the work sufficient to
have caused a proclamation of disaster or state of emergency having occurred in a populated area.
Subject to the foregoing, CITY shall not, in any way or manner, be answerable or suffer loss,
damage, expense or liability for any loss or damage that may happen to said building, work, or
equipment or any part thereof, or in; on, or about the same during its construction and before
acceptance.
20. CONTRACTOR'S GUARANTEE. CONTRACTOR unqualifiedly guarantees the
first-class quality of all work and of all materials, apparatus and equipment used or installed by
CONTRACTOR or by any subcontractor or supplier in the project which is the subject of this
Contract, unless a lesser quality is expressly authorized in the Plans and Specifications, in which
event CONTRACTOR unqualifiedly guarantees such lesser quality; and that the work as
performed by CONTRACTOR will conform with the Plans and Specifications or any written
authorized deviations therefrom. In case of any defect in the work, materials, apparatus or
equipment, whether latent or patent, revealed to CITY within the time period specified in the
technical provision from the date of acceptance of completion of this Contract by CITY,
CONTRACTOR will forthwith remedy such defects without cost to CITY.
5
P.O. No.t7~ 67 c; .
21. DEFERRED ALTERNATE SELECTION. The City reserves the right for the term of
the Contract, the deferred selection of none, any or all alternate bid items at the bid price. The
alternates chosen would be for any sites currently 'under construction or to be constructed in the
future.
IN WITNESS WHEREOF, the parties have executed this Contract, in duplicate, the day and
year first hereinabove written.
B CyI~FJ~UPE~J:
,;)W w~ ID.2<.D~
David W. Knapp
City Manager
Attest: . ~
~
Date: () d-o-&.u ;;2/
City Clerk
,20~
CONTRACTOR:
No ary acknowledgment is required. If a
corporation, corporate seal and corporate
notary acknowledgment and Federal Tax
I.D. are required. If not a corporation a
Social Security No. is required.
'
Federal Tax I.D. #
Social Security #
Contractor's License No. ~'11"" 7r;'
Project Name & Number: torm Drain Catch Basin Cleaning, Project No. 2007-05
Contractor's Name & Address:
Able Underground Construction Inc.
P.O. Box 24819
San Jose, CA 95154
Contract Amount: $ 58,500
Account Number: 230-8004-7014
File No: 97,569
6
(,~jl~~t, ~c~~s
State of California } J ~V M' 1 ~ ~ l~1(N 1 I-.XAJ ~ ~
} ss. C~...~a,~,t, rl ~ (La ~ cf
County of ~~l
i'f /,I ~,~~d__} ~ ~
~ \ 266 ~ - o~
On (~W~
Before me, Kimberly A. Delay, Notary Public,
f
personally appeared
personally known to me (or ved t me on the basis of satisfactory evidence) to be the
person~s~-whose name i u scribed to the within instrument and acknowledged to
me th e/sl~i:•hcy executed the same ii is~eir authorized capacity(ies~ and that by
is ~ signatures(sj`on the instrument the person($j-~or the entity upon behalf of
which the persoaf s~j acted, executed the instrument.
WITNESS my hand and official seal.
This area for official notarial seal
K(V13ERLY A. DULAY
.u
a !v?; ~ Commission 1641183 Z
z _ w~i y;; Notary Public -California
~ Z :~~~J" Santa Clara County ~
My Comm. Explres..lc,n 27, 20i uj
Signature
My Commission Expires: 01!27/10 Notary Phone: (408) 315-2698
Notary Name: Kimberly A. Delay County of Principal Place of Business:
Notary Registration Number: 1641183 Santa Clara
D~~CUMENT: 19856345 Pages 3
Fees.... ~ No Fees
RECORDING REQUESTED BY Taxes .
Copies..
City of Cupertino AMT PA I D
vl-'HEN RECORDED MAIL "I'O Rf=G I NA ALCOMENDRAS RDE # 001
S~aNTA CLARA COUNTY RECORDER 5/16/2008
CttV Clerk's Office Recorded at the request of 1 ~ 23 PM
City of Cupertino C i t y
10300 Torre Avenue
Cupertino, CA 95014-3255
(SPACE ABOVE THIS LINE FOR RECORDER'S USE)
1V01~'EE I1V ACCORDANCE
WITH GOV. CODE 6103
CERTIFICATE OF COMPLETION
AND
NOTICE OF ACCEPTANCE OF COMPLETION
STORM DRAIN CATCII BASIN CLEANING
PROJECT N~O.2007-OS
Original
O For Fast Endorsement
City Hall
10300 Torre Avenue
Cupertino, CA 95014-3255
(408) 777-3354
CUPERTINO
PUBLIC WORKS DEPARTMENT
CERTIFICATE OF COMPLETION
AND
NOTICE OF ACCEPTAwCE OF COMPLETION
STORM DRAIN CATCH BASIN CLEANING
PROJECT 1v0.2007-OS
NOTICE IS HEREBY GIVEN THAT I, Ralph A. Qualls, Jr., Director of Public Works
and City Engineer of the City of Cupertino, California, do hereby certify that the work and
improvements in hereinafter described in the contract which was entered into, by, and between
the City of Cupertino and Able Underground Construction Inc., on October 25, 2007, in
accordance with the plans and specifications for said work, have been completed to my
satisfaction and acceptance of completion was ordered on May 12, 2008.
That said work and improvements consisted of furnishing all labor, materials, tools, and
equipment required to complete said project, al',~ as more particularly described in the plans and
specifications for said project.
Director of Public Works and
City Engineer of the City of Cupertino
Date: May 12, 2008
"NO FEE"
VERIFICATION
I have reviewed this Certificate of Completion and Notice of Acceptance of
Completion. To the best of my knowledge, the information contained herein is true and
complete.
I verify under penalty of perjury under the laws of the State of California, that the
foregoing is true and correct.
Executed on the 12th of May 2008 at Cupertino, California.
ca
Mary dwine
City lerk's Offer
City of Cupertino