15070164M
a
CITY OF CUPERTINO BUILDING PERMIT
BUILDING ADDRESS: 21354 DEXTER DR
CONTRACTOR: JITHENDER MAJJIGA PERMIT NO: 15070164
OWNER'S NAME: JITHENDER MAJJIGA
21354 DEXTER DR DATE ISSUED: 12/11/2015
OWNER'S PHONE: 4088022559
CUPERTINO, CA 95014-1317 PHONE NO:
n LICENSED CONTRACTOR'S DECLARATION
JOB DESCRIPTION: RESIDENTIAL E] COMMERCIAL
ADDITION TO SFD TO EXPAND (E) KITCHEN & FAMILY
License Class Lie. #
ROOM (238 S.F.), (N) COVERED PORCH (80 S.F.),
ContractorDate
CHANGE (E) ROOFLINE (420 S.F.), 12 (N) RECESSED
I hereby affirm that I am licensed under the provisions of Chapter 9
(commencing with Section 7000) of Division 3 of the Business & Professions
Code and that my license is in full force and effect.
I hereby affirm under penalty of perjury one of the following two declarations:
I have and will maintain a certificate of consent to self -insure for Worker's
Compensation, as provided for by Section 3700 of the Labor Code, for the
performance of the work for which this permit is issued,
Sq. Ft Floor Area:
Valuation: $37000
I have and will maintain Worker's Compensation Insurance, as provided for by
Section 3700 of the Labor Code, for the performance of the work for which this
permit is issued.
APN Number: 32641071.00
Occupancy Type:
APPLICANT CERTIFICATION
I certify that I have read this application and state that the above information is
PERMIT EXPIRES IF WORK IS NOT STARTED
correct. I agree to comply with all city and county ordinances and state laws relating
to building construction, and hereby authorize representatives of this city to enter
WITHIN 180 DAYS OF PERMIT ISSUANCE OR
upon the above mentioned property for inspection purposes. (We) agree to save
180 DAYS FROM LAST CALLED INSPECTION.
indemnify and keep harmless the City of Cupertino against liabilities, judgments,
costs, and expenses which may accrue against said City in consequence of the
AAAA
granting of this permit. Additionally, the applicant understands and will comply
Issued by: Date: ! ! t
with all non -point source regulations per the Cupertino Municipal Code, Section
9.18.
Signature Date
RE -ROOFS:
All roofs shall be inspected prior to any roofing material being installed. If a roof is
installed without first obtaining an inspection, I agree to remove all new materials for
inspection.
OWNER -BUILDER DECLARATION
hereby affirm that I am exempt from the Contractor's License Law for one of
Signature of Applicant: Date:
the following two reasons:
I, as owner of the property, or my employees with wages as their sole compensation,
ALL ROOF COVERINGS TO BE CLASS "A" OR BETTER
will do the work, and the structure is not intended or offered for sale (Sec:7044,
-Business & Professions Code)
I, as owner of the property, am exclusively contracting with licensed contractors to
HAZARDOUS MATERIALS DISCLOSURE
construct the project (Sec.7044, Business & Professions Code).
I have read the hazardous materials requirements under Chapter 6.95 of the
California Health & Safety Code, Sections 25505, 25533, and 25534. I will
I hereby affirm under penalty of perjury one of the following three
maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the
declarations:
Health & Safety Code, Section 25532(a) should I store or handle hazardous
I have and will maintain a Certificate of Consent to self -insure for Worker's
material. Additionally, should I use equipment or devices which emit hazardous
Compensation, as provided for by Section 3700 of the Labor Code, for the
air contaminants as defined by the Bay Area Air Quality Management District i
performance of the work for which this permit is issued.
will maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and
I have and will maintain Worker's Compensation Insurance, as provided for by
the Health & Safety Code, Sections 25505, 25533, and 25534.
Section 3700 of the Labor Code, for the performance of the work for which this
Owner or authorized agent: Date: 1/� tL
permit is issued.
I'certify that in the performance of the work for which this permit is issued, I shall
not employ any person in any manner so as to become subject to the Worker's
CONSTRUCTION LENDING AGENCY
Compensation laws of California. If, after making this certificate of exemption, I
become subject to the Worker's Compensation provisions of the Labor Code, I must
I hereby affirm that there is a construction lending agency for the performance of
forthwith comply with such provisions or this permit shall be deemed revoked..
work's for which -this permit is issued (Sec. 3097, Civ C.)
Lender's Name
APPLICANT CERTIFICATION
Lender's Address
I certify that I have read this application and state that the above information is
correct. I agree to comply with all city and county ordinances and state laws relating
to building construction, and hereby authorize representatives of this city to enter
upon the above mentioned property for inspection purposes. (We) agree to save
ARCHITECT'S DECLARATION
indemnify and keep harmless the City of Cupertino against liabilities, judgments, ;
costs, and expenses which may accrue against said City in consequence of the
I'. understand my plans shall be used as public records.
granting of this .permit. Additionally, the applicant understands and will comply
with all non -point source regulations per the Cupertino Municipal Code, Section
Licensed Professional
9.18.
G'f'�atEI i1
Signature Date t 2
CONSTRUCTION PERMIT APPLICATION
COMMUNITY DEVELOPMENT DEPARTMENT ® BUILDING DIVISION
10300 TORRE AVENUE m CUPERTINO, CA 95014-3255
(408) 777-3228 • FAX (408) 777-3333 o buiiding(Wcupertino.org
NEW`CONSTRUCTION ADDITION 0 ALTERATION/ Ti ❑ REVISION / DEFERRED
,/0- /
ORIGINAL PERMIT #
PROJECT ADDRESSIi ' 1I)V-APN
# 41-011
Z�
OWNERNAME ,/1 + _ `
((V
7
4&0E
-MAIL
STREET ADDRESS
CITY, STATE; IP
FAX
CONTACT NAM �P
a V V\ �5' l,Q
NE
IL 9N�iC f
STREET ADDRESS
CITY, STATE, IP
FAX
OWNER ❑ OWNER -BUILDER ❑ OWNER AGENT ❑ CONTRACTOR ❑ CONTRACTOR AGENT ARCHITECT ❑ ENGINEER ❑ DEVELOPER ❑ TENANT
CONTRACTORNAM QW1 eD OC..)
CJ SC %j
LI ENSE NUMBE _ wL
LICENSE TYPE
BUS. LIC #
COMPANY NAMEID. a� d N1 S f
E-MAIL
FAX
STREET ADDRESS" /'� a�L ! ( _ •„ „
�I� Y� S ATE, Z P CA
0 - v
ARCHI GO
Et�Il�C��
LICEN R
Z
BUS.LIC#
COMPANY NA
D V r • r ` s w G ( Liu . vv+
• 1"
FAX
STREET ADDRESS ( { ,^ C f (
V1
,(
CITY ST TE, ZIP
AM 0AA C-61
N6 6 2
DESCRIPTION OF WORK ,e _iG � q V CGL- "l lel 6 `w ` ( M
n 0 W of a �� G� LS � �t�l dt L t► W ,
v v v (lV{ A v10� 1 i vl S 1
odd V vt o'ev e •
EXIS U
PROP SED USE
CON TR TVe>YPE
# STORIES -
USE TYPE OCC. SQ.FT. VALUATION ($)
EXISTG
AREAL j
NEW FLOOk
AREA eb
AREA
TOTAL �t
NET APZ /aj % --
1
BATHROOM KITCHEN -
REMODEL AREA REMODEL AREA
OTHER jjy
REMODEL AREf�{'
PORCH AREA
-DECK AREA
TOTAL DECK/PORCH AREA
y, ^.
GARAGE AREA: DETACH -
,{. T ATTACH
7❑_YES
fj
#DWELLINGUNITS:
IS A SECOND UNrr ❑ YES
BEING ADDED? IQ0
SECOND STORY -
ADDITION? Seo - - -
T❑'TOTAL
PRE -APPLICATION ❑YES IF YES, PROVIDE COPY OF - IS TAE BLDG AN VALUATION:
PLANNING APPL # `{AVO PLANNING APPROVAL LETTER EICHLER HOME? 'WO 00 0 ® oo -
By my signature below, I certify to each of the following: I am the property owner or authorized agent to act on the property owner's behalf. I have read this
Work verify it is accurate. I agree to comply with all applicable local
application and the information I have provided is correct. I have read the Description of and
ordinances and state laws relatingte-buw g co struction. I auth a representatives of Cupertino to enter the above -id tified property for inspection purposes.
Signature of Applicant/Agent: Date: JJ
SUPPLEMENTAL INFORMATION REQUIRED
PLAN CHECK TYPE
ROUTINGSLIP
❑ OVER-THE-COUNTER
❑ BUILDING PIAN REVIEW
New SFD or Multifamily dwellings: Apply for demolition permit for
_
existing building(s). Demolition permit is required prior to issuance of building
11 EXPRESS
F-1PLANNiNGPLANREvrEW
permit for new building.
Commercial Bldgs: Provide a completed Hazardous Materials Disclosure
❑ STANDARD
El PUBLIC WORKS
_
form if any Hazardous Materials are being used as part of this project.
❑ LARGE
❑ HIREDEPT
Copy of Planning Approval Letter or Meeting with Planning prior to
El MAJOR
❑ SANITARY SEWER DISTRICT
_
submittal of Building Permit application.
❑ EIVYHtONMENTAL HEALTH
BldgApp 201 Ldoe revised 06121/11
I-
CITY OF CUPERTINO
FF.F ESTIMATOR — BUILDING DIVISION
21354 DEXTER DR
DATE: 07/2212015
REVIEWED BY: MELISSA
JimADDRESS:
APN: 326 41 071
BP#:
*VALUATION: 1$37,000 -�
*PERMIT TYPE: Building Permit
PLAN CHECK TYPE:
Addition
PRIMARY
SFD or Duplex
USE:
2nd Unit? Yes No
OTC? � Yes . No
PENTAMATION
PERMIT TYPE: 1 R3SFDADD
WORKI
ADDITION TO SFD TO EXPAND E KITCHEN & FAMILY ROOM238 S.F. N COVERED PORCH'
SCOPE
(80 S.F.), CHANGE (E) ROOF LINE (420 S.F.), 12 (N) RECESSED LIGHTS, 2 (N) SKYLIGHTS
OCCUPANCY TYPE: TYPE OF FLR AREA PC FEES PC FEE ID BP FEES BP FEE ID
CONSTR. s.L
R-3 (Custom) II-B,111-B,IV,V-B 238 $1,091.00' 1,4DDPLCK $1,057.00 ZDDINSP
TOTALS: I 238 $1,057.0
; kch. Plan Check Phtllt[z Nan Check Elec. Plan Check 10.0 1 hrs $0.00
1leclr. 1'erwif Cee: Plumb. I'er rnir Fee: Elec. Permit Fee: IEPERMIT
CJirrer .%clr. Inslk. ()thea 1'1urr215 Imp. Other Elec. Insp. 0.0 hrs $48.00
1, lec=. Ins Fee:
Isssl�, Fee:Prztrrrr�, 1rt.�1), Fe":I
NOTE__ This estimate does not include fees due to other Departments (Le. Planning, Public Works, Fire, Sanitary Sewer District, School
bd th l' in ormation available and are onl an estimate contact the ve t or aaan-z zn o.
Dzstrzct, ete . These ees are as on a re zmzna
FEE ITEMS (Fee Resolution 11-053 E : 711,13)
FEE
QTYIFEE
MISC ITEMS
Plan Check Fee:
$1,091.00
420 s.f.
Remodel, Other
Suppl. PC Fee. Reg. 0 OT
0.0
hrs
$0.00
$503.00
1REMRESOTH
PME Plan Check:
$0.00
2 #
$862.00
Skylight
ISKYL<IOSF <=10 s.f.
Permit Fee:
$1,057.00
Suppl. Insp. Fee:Q Reg. OOT
0,0
hrs
$0.00
12 Electrical
$72.00 IBREMFIXT Fixtures, Lighting
PME Unit Fee:
$0.00
PME Permit Fee:
$48.00
C -j # Covered Porch
$11,003-010I COVPORCH
C. C1n5t3'Ltc'tIC)fG .1 GI;I:
A..chninit•tratIv fqe'C':
0
Work Without Permit? 0 Yes � No
$0.00
Advanced Planning Fee: IPLLONGR
$33.32
Select a Non -Residential
Building or Structure
G
0
Travel Documentation Fee: ITRAVDOC
$48.00
A
Strom Motion Fee: IBSEISMICR
$4.81
Select an Administrative Item
Bldg Stds Commission Fee IBCBSC
$2.00
TT(3TALS; .
$2,284.131$2,440.00
* . } TOTAL F $4,724.13
I
CITY OF CUPERTINO
FEE ESTIMATOR - BUILDING DIVISION
NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public Works, Fire, Sanitary Sewer District, School
District, etc.. These fees are based on the vreliminar information available and are only, an estimate. Contact the De t or addn'l info.
FEE ITEMS (Fee Resolution 11-053 E(f. 7/1/13)
ADDRESS: 21354 Dexter Dr
DATE: 01/12/2016
REVIEWED BY: PAUL
r"
APN: 326 41 071
BP#: 15070164
'VALUATION: Iso
*PERMIT TYPE: Building Permit
PLAN CHECK TYPE: Addition
PRIMARY SFD or Du lex
USE: P
C)JAur Plumb i;;.,
PENTAMATION 1GENRES
PERMIT TYPE:
WORK
Revision #1 - Change location of Skylights and windows at East Elevation; Garage shearwall changed
SCOPE
from 18' to 12'; Shearwall at east wall changed; Floor addition changed to 2 / 2"x6"
NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public Works, Fire, Sanitary Sewer District, School
District, etc.. These fees are based on the vreliminar information available and are only, an estimate. Contact the De t or addn'l info.
FEE ITEMS (Fee Resolution 11-053 E(f. 7/1/13)
:iiEtclt. f'Irt!t (?irCa
..!1'71(:. i'laii t'{'dec:
MISC ITEMS
r"
]�
2 hours Plan Check, Hourly
$286.00 ISTPLNCK
Suppl. PC Fee: E) Reg. OT
0.0
1 hrs
r :; " e:"
C)JAur Plumb i;;.,
E30',41,
°feclt. Irsl,. h"'
Phimb..bisp. F,,(,
klec. Imp. t ee:
NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public Works, Fire, Sanitary Sewer District, School
District, etc.. These fees are based on the vreliminar information available and are only, an estimate. Contact the De t or addn'l info.
FEE ITEMS (Fee Resolution 11-053 E(f. 7/1/13)
FEE
QTY/FEE
MISC ITEMS
Plan Check Fee: Hourly Only? 0 Yes Q No
$0.00
2 hours Plan Check, Hourly
$286.00 ISTPLNCK
Suppl. PC Fee: E) Reg. OT
0.0
1 hrs
$0.00
PME Plan Check:
$0.00
Permit Fee:
$0.00
Suppl. Insp. Feer Reg. Q OT
0.0
hrs
$0.00
PME Unit Fee:
$0.00
PME Permit Fee:
$0.00
(..'(m:ar UClioj1 I L1.v:
T7
.4111linislruli ve .Feel
0
0
Work Without Permit? 0 Yes 0 No
$0.00
Advanced Planning Fee:
$0.00
Select a Non -Residential
Building or Structure 0
i
llwvc/ Dox:r, mentution Fees.
Strong Motion Fee:
$0.00
Select an Administrative Item
Bldg Stds Commission Fee:
$0.00
SUBTOTALS:
$0.00
$286.00 TOTAL FEE:
$286.00
Revised: 01/01/2016
. U-4.
CUPERTIN0
CONSTRUCTION PERrliiT APPLICATICN,�'XIOI(71icoaI
COMMUNITY DEVELOPMENT DEPARTMENT • BUILDING DIVISION
10300 TORRE AVENUE - CUPERTINO, CA 95014-3255
(408) 777-3226 • FAX (408) 777-3333 - building gecunel tino.org
❑ N TW CONSTRUC-TION ❑ ADDMON . ❑ ALTERATION / TI ❑ REVISION / DEFERRED ORIGINAL PERMIT a
PRO7ECf ADDRESS
OWNER NAI✓.EKC�I hf DE �I71�1� I PH �6Z _2 =_u.AIL 1 C (YI u
ST REST P DDRESS 5�►->� I Cil Y, STATE, ZIP I FAX
-
CONTACT NTAME PHONE EN
E
r1Io2A7otJ LS
W LsI o Z PL 117 -600-(�" 006'7c-,
STR-E ADDRESS
CITY, STATE, ZIP FAX
El OWNER ❑. OANER-BUILDER. ❑ Oti^,--RAGIENT ❑ CONTRACTOR ❑ CONIRACTORAGENT ❑ ARCHri✓-CT ❑ rT1GP.ncR "D_ aLOPr?E NAh?
CONTRACTOR NAME LiCzNSE NU1'G ER I L10EN5
COMPANY NA.,M E-M.A,IL W
STREET ADDRESS
CITY, STATE, ZIP
r
ARCHITECTry � A.WIE
�� I LICENSENUMBER 6 b� BUS. LIC 0
CAsO�
IftCOMPANY
NAME
E -MF Fp.X
CO*C04t-tO
ADDRESShC .( �V h
I CITY ATE, ZIP ^ I PH O (LL
DESCRIPTION OF WORK9 /I -SrC�� J � y L -/'K r5 �D eAT r W pe (—
A -r Cc MZ.Aq( -ft-o lti �q!n 12 S Kd?42. k) &,L f-7 ( Sr
luAte- CATYCA R-00 --70 1-5-r OS/t"C, 2 6
EXISTING USE PROPOSED USE CONSTR. TYPE # STORM
1
USE
TYPE
OCC.
SQ.FT. I
VALUATION(S)
ExISTG
NEW FLOOR DEMOI TOTAL
A2,EA
AREA AREA r�r'T AREA
-
BATHROOM
KITCHEN OTHER
REMODEL AREA
REMODEL AREA REMODEL AREA
PORCH AREA
DECK AREA
TOTAL DECYJPORCH P.R=A
GARAGE AREA: DDETAoi
❑ATTACH
I
�DIATILD'IGUNITS:
IS A SECOND UNIT ❑YES
SECOND STORY ❑YES
BEING ADDED? E] NO
ADDITION? ❑NO
!
PRE -APPLICATION ES IF YES, PROVIDE COPY OF
IS THE BLDG AN a YES
; OTAL'I TION:
❑❑Y
PLA.NNINGAPPL. NO PLANNDgGAPPROVAL LETTER
I
M
EICHLERHOE? NO
l I
By my signature below. I certify to each of the follo-Mng: I am the property owner or autl wiztd agent to act on the property owner's behalf. I ha a read this
application and the information I have provided is correct. I have read the Description of Work and verify it is accurate. I agree to comply with all applicable local
ordinances and state lava relating to b it I C ttvction. I authorize representatives -of Cupertino to enter the above- i entifV property for inspection purposes.
Signature of Applicant/Aeent: Date: l I Z
SUPPLEMENTAL INFORMATION REQUIRE'=
-
_° �' x ;•
��zl�f+tCfiECK T]PF I
New SFD or Multifamily dwellings: Apply for demolition permit for
. „�.OG
existing building(s). Demolition permit is required prior to issuance of building
permit for new building.
_ Commercial Bldgs: Provide a completed Hazardous Materials Disclosure
`
form if any Hazardous Materials are being used as part of this project.
I
_ Copy of Planning Approval Letter or Meeting with Planning prior to
submittal of Building Permit application.
Bld.-App_2011.doc revised 06121/11
CITY OF CUPERTINO BUILDING PERMIT
BUILDING ADDRESS:
CONTRACTOR:
PERMIT NO: 2016-1159 (15070164)
21354 DEXTER DR CUPERTINO, CA 95014-1317 (326 41 071)
OWNER/BUILDER
OWNER'S NAME: JITHENDER MAJJIGA
DATE ISSUED: 01/25/2016
OWNER'S PHONE: 408-802-2559
PHONE NO:
LICENSED CONTRACTOR'S DECLARATION
BUILDING PERMIT INFO:
License Class Lic. #
Contractor OWNERIBUILDER Date 01/25/2016
X BLDG —ELECT —PLUMB
MECH X RESIDENTIAL COMMERCIAL
I hereby affirm that I am licensed under the provisions of Chapter 9 (commencing
with Section 7000) of Division 3 of the Business & Professions Code and that my
license is in full force and effect.
JOB DESCRIPTION:
Revision #1 to 15070164 - Change location of Skylights and windows at East
I hereby affirm under penalty of perjury one of the following two declarations:
Elevation; Garage shearwall changed from 18' to 12% Shearwall at east wall
t. I have and will maintain a certificate of consent to self -insure for Worker's
changed; Floor addition changed to 2 / 2"x6"
Compensation, as provided for by Section 3700 of the Labor Code, for the
performance of the work for which this permit is issued.
2. I have and will maintain Worker's Compensation Insurance, as provided for
by Section 3700 of the Labor Code, for the performance of the work for which
Sq. Ft Floor Area:
Valuation: $37000.00
this permit is issued.
APPLICANT CERTIFICATION
1 certify that I have read this application and state that the above
information is correct. I agree to comply with all city and county
APN Number:
Occupancy Type:
ordinances and state laws relating to building construction, and hereby
326 41 071
authorize representatives of this city to enter upon the above mentioned
property for inspection purposes. (We) agree to save indemnify and keep
harmless the City of Cupertino against liabilities, judgments, costs, and
PERMIT EXPIRES IF WORK IS NOT STARTED
expenses which may accrue against said City in consequence of the
WITHIN 180 DAYS OF PERMIT ISSUANCE OR
granting of this permit. Additionally, the applicant understands and will
comply with all non -point source regulations per the Cupertino Municipal
180 DAYS FR AST CALLED INSPECTION.
Code, Section 9.18.
Iss
Signature Date 01/25/2016
Date. /25/2016
OWNER -BUILDER DECLARATION
RE -ROOFS:
I hereby affirm that I am exempt from the Contractor's License Law for one of the
All roofs shall be inspected prior to any roofing material being installed. If a roof is
following two reasons:
installed without first obtaining an inspection, I agree to remove all new materials for
r. I, as owner of the property, or my employees with wages as their sole
inspection.
compensation, will do the work, and the structure is not intended or offered
for sale (Sec.7044, Business & Professions Code)
Signature of Applicant:
I, as owner of the property, am exclusively contracting with licensed
Date: 01/25/2016
contractors to construct the project(Sec.7044, Business &Professions Code).
I hereby affirm under penalty of perjury one of the following three declarations:
ALL ROOF COVERINGS TO BE CLASS "A" OR BETTER
t. I have and will maintain a Certificate of Consent to self -insure for Worker's
Compensation, as provided for by Section 3700 of the Labor Code, for the
HAZARDOUS MATERIALS DISCLOSURE
performance of the work for which this permit is issued.
I have read the hazardous materials requirements under Chapter 6.95 of the
2. I have and will maintain Worker's Compensation Insurance, as provided for
California Health & Safety Code, Sections 25505, 25533, and 25534. I will
by Section 3700 of the Labor Code, for the performance of the work for which
maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the
this permit is issued.
Health & Safety Code, Section 25532(a) should I store or handle hazardous
s. ertify that in the performance of the work for which this permit is issued, I
material. Additionally, should I use equipment or devices which emit hazardous
shall not employ any person in any manner so as to become subject to the
air contaminants as defined by the Bay Area Air Quality Management District I
will maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and
Worker's Compensation laws of California. If, after making this certificate of
the Health & Safety Code, Sections 25533, and 25534.
exemption, I become subject to the Worker's Compensation provisions of the(`
Labor Code, I must forthwith comply with such provisions or this permit shall
2555005,
-'y
Owner or authorized agent: Q
be deemed revoked.
Date: 01/25/2016
APPLICANT CERTIFICATION
1 certify that I have read this application and state that the above information is
CONSTRUCTION
I hereby affirm that there is a construction lending agency for the performance
correct. I agree to comply with all city and county ordinances and state laws
of work's for which this permit is issued (Sec. 3097, Civ C.)
relating to building construction, and hereby authorize representatives of this city
Lender's Name
to enter upon the above mentioned property for inspection purposes. (We) agree
to save indemnify and keep harmless the City of Cupertino against liabilities,
Lender's Address
judgments, costs, and expenses which may accrue against said City in
consequence of the granting of this permit. Additionally, the applicant
ARCHITECT'S DECLARATION
understands and will comply with all non -point source regulations per the
I understand my plans shall be used as public records.
Cupertino Municipal Code, Section 9.18.
Licensed
Professional
Signature Date 01/25/2016
010
�j
r '
CUPERTINO
OWNER -BUILDER DISCLOSURE FORM
COMMUNITY DEVELOPMENT DEPARTMENT - BUILDING DIVISION
10300 TORRE AVENUE - CUPERTINO, CA 95014-3255
(408) 777-3228 - FAX (408) 777-3333 - buildings cuoertino.oro
Dear Property Owner(s):
An application for a building permit has been submitted in your name listing yourself as the builder of the property
improvements specified at:
We are providing you with an Ownef-Builder Ackhowledgment and Information Verification Form to make you aware of
your responsibilities and possible risk you may incur by having this permit issued in your name as the Owner -Builder. We
will not issue a building permit until you have read, initialed your understanding of each provision, signed, and
returned this form to us at our official address indicated. An agent of the owner cannot execute this notice unless
you, the property owner, obtain the prior approval of the permitting authority.
OWNER'S ACKNOWLEDGMENT AND VERIFICATION OF INFORMATION
(DIRECTIONS: Please read and initial each statement below to signify you understand or verify this information.)
�&<l understand a frequent practice of unlicensed persons is to have the property owner obtain an "Owner -
Builder" building permit that erroneously implies that the property owner is providing his or her own labor and material
personally. I, as an Owner -Builder, may be held liable and subject to serious financial risk for any injuries sustained by
an unlicensed person and his or her employees while working on my property. My homeowner's insurance may not
provide coverage for those injuries. I am willfully acting as an Owner -Builder and am aware of the limits of my
insurance coverage for ini0ries to workers on my property.
I understand. building permits are not required to be signed by property owners unless they are responsible for
the construction and are not hiring a licensed Contractor to assume this responsibility.
1 understand as an "Owner -Builder" I am the responsible party of record on the permit. I understand that I may
protect myself from potential financial risk by hiring a licensed Contractor and having the permit filed in his or her
name instead of my own.
Yom`+. I understand Contractors are required by law to be licensed and bonded in California and to list their license
numbers on permits and contracts.
VI understand if I employ or otherwise engage any persons, other than California licensed Contractors, and the
lue of my construction is at least five hundred dollars ($500), including labor and materials, I may be
considered an "employer" under state and federal law.
4_16 I understand if I am considered an "employer" under state and federal law, I must register with the state and
federal government, withhold payroll taxes, provide workers' compensation disability insurance, and contribute to
unemployment compensation for each "employee." I also understand my failure to abide by these laws may subject
me to serious financial risk.
I understand under California Contractors' State License Law, an Owner -Builder who builds single-family
Irdidentla
l structures cannot legally build them with the intent to offer them for sale, unless all work is performed by
licensed subcontractors and the number of structures does not exceed four within any calendar year, or all of the work
fperformed under contract with a licensed general building Contractor.
8. 1 understand as an Owner -Builder if I sell the property for which this permit is issued, I may be held liable for
y financial or personal injuries sustained by any subsequent owner(s) that result from any latent construction
defects in the workmanship or materials.
OwnerBuilderForm 2010.doc revised 04/14/10
k9. I understand I may obtain more information regarding my obligations as an "employer" from the Internal
Revenue Service, the United States Small Business Administration, the California Department of Benefit Payments,
and the California Division of Industrial Accidents. I also understand I may contact the California Contractors' State
License Board (CSLB) at 1-800-321-CSLB (2752) or v"Av.csib.ca.gov for more information about licensed
contractors.
ki. I am aware of and consent to an Owner -Builder building permit applied for in my name, and understand that I
Jthe party legally and financially responsible for proposed construction activity at the site address listed above.
1. I agree that, as the party legally and financially responsible for this proposed construction activity, I will abide
all applicable laws and requirements that govern Owner -Builders as well as employers.
. agree to notify the issuer of this form immediately of any additions, deletions, or changes to any of the
in mation l have provided on this form. Licensed contractors are regulated bylaws designed to protect the public. If
you contract with someone who does not have a license, the Contractors' State License Board may be unable to
assist you with any financial loss you may sustain as a result of a complaint,._ Your only remedy against unlicensed
Contractors may be in civil court. It is also important for you -to understand that if an unlicensed Contractor or
employee of that individual or irm is injured while working on your property, you maybe held liable for damages. If
you' obtain a permit as Owner -Builder and wish to hire Contractors, you will be responsible for verifying whether or not
those Contractors are properly licensed and the status of their workers' compensation insurance coverage.
CONSTRUCTION LENDING AGENCY
(DIRECTIONS: Please complete the following construction lending agency information.)
I hereby affirm that there is a construction lending agency for the performance of the work for which this permit is issued
(Sec 3097 Civ.)
Lender Name:
Lender Address:
Before a building permit can be issued, this form must be completed and signed by the property owner and
returned to the agency responsible for issuing the permit. Note: A copy of the property owner's driver's license,
form notarization, or other verification acceptable to the city may be required to be presented when the permit is issued
to verify the property owners signature. J / ��.. ., z „ z ,
Property Owner's Signature: Date: ( r4 1 r j 11-
-
(NOTE: The follow✓ing Authorization Form is required to be completed by the propertyov✓ner only when designating an
agent of the property owner to apply for a construction permit for the Owner -Builder).
AUTHORIZATION OF AGENT TO ACT ON PROPERTY OWNER'S BEHALF
Excluding the Notice to Property Owner, the execution of which I understand is my personal responsibility, I hereby
authorize the following person(s) to act as my agent(s) to apply for, sign, and file the documents necessary to obtain an
Owner -Builder Permit for my project.
Scope of Construction Project (or Description of Work):
Project Location or Address:
Name of Authorized Agent:
Address of Authorized Agent:
Tel No
I declare under penalty of perjury that I am the property owner for the address listed above and I personally filled out the
above information and certify its accuracy. Note: A copy of the property owner's driver's license, form notarization, or other
verification acceptable to the city may be required to be presented when the permit is issued to verify the property owner's
signature.
Property Owner's Signature:
Date:
OwnerBuilderForm 2010.doc revised 04/14110
V�
T H
O
R
N T
O N
W
E
I
L
E R
A k
C
H
I T
E C T
February 1, 2016
Special Inspection Final Report
Project: Residential Building Addition
Project address: 21354 Dexter Drive
Building Permit: 15070164
To Whom It May Concern:
This is to certify that in accordance with Section 1704.2 of the California Building Code
I have provided a special inspection for:
Lis
1. Inspection of anchors, post -installed in hardened concrete- Seismic anchor rods set in
high strength epoxy
This inspection was preformed by Thornton Weiler. To the best of my knowledge, the work is in
conformance with the approved plans and specifications and requirements of the current
Cupertino Building Code
Sincerely,
Thornton Weiler, Architect C27685
Thornton Weiler AIA, LEER AP 1 452 Lincoln Avenue I Alameda CA 94501
TEL 510.521 .7300 1 FAx 510.521.731 1 1 CEL 510.381.4829 1 thornton.weiler@comcast.net
BUILDING ENERGY ANALYSIS REPORT
PROJECT:
Jithender Majjiga
21354 Dexter Drive
Cupertino, CA 95014
*"%�P"
Project Designer: ;CE
Copuftk'l
Thornton Weiler
452 Lincoln Ave
Alameda, CA 94501
510-381-4829
Report Prepared by:
Rick Rocklewitz
NRG Compliance, Inc
PO Box 3777
Santa Rosa, California 95402
707-237-6957
In
COMP11ANCE, 1NC.
Job Number:
012115
Date:
7/21/2015
0
JUL 2 2101.
SU'RMITTAI
The EnergyPro computer program has been used to perform the calculations summarized in this compliance report. This program has approval and is
authorized by the California Energy Commission for use with both the Residential and Nonresidential 2013 Building Energy Efficiency Standards.
IThis program developed by EnergySoft, LLC — www.energysoft.com.
EnergyPro 6.6 by EnemySoft User Number: 5581 ID: 012115
I TABLE OF CONTENTS I
Cover Page
Table of Contents
Form CF -1 R -PRF -01-E Certificate of Compliance
Form RMS -1 Residential Measures Summary
Form MF -1 R Mandatory Measures Summary
EnergyPro 6.6 by EnergySoft Job Number: ID: 012115 User Number: 5581
1
2
3
12
14
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
CF1 R -PRF -01
Page 1 of 9
GENERAL INFORMATION
ENERGY USE SUMMARY
01
Project Name Residential Building
04
05
02
Calculation Description Title 24 Analysis
08
Energy Use (kTDV/ftZ-yr)
03
Project Location 21354 Dexter Drive
Compliance Margin
Percent Improvement
04
City Cupertino
05
Standards Version Compliance 2015
06
Zip Code 95014
07
Compliance Manager Version BEMCmpMgr 2013-4 (744)
08
Climate Zone CZ4
09
Software Version EnergyPro 6.6
10
Building Type Single Family
11
Front Orientation (deg/Cardinal) 0
12
Project Scope Addition and/or Alteration
13
Number of Dwelling Units 1
14
Total Cond. Floor Area (ftZ) 2593
15
Number of Zones 3
16
Slab Area (ft2) 0
17
Number of Stories 1
18
Addition Cond. Floor Area 238
19
Natural Gas Available Yes
20
Addition Slab Area (ftZ) 0
21
Glazing Percentage (%) 14.7%
COMPLIANCE RESULTS
01 Building Complies with Computer Performance
02 This building DOES NOT require HERS Verification
03 This building incorporates one or more Special Features shown below
Registration Number: Registration Date/Time:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CFiR-07082015-744
HERS Provider:
Report Generated at: 2015-07-2109:04:05
ENERGY USE SUMMARY
04
05
06
07
08
Energy Use (kTDV/ftZ-yr)
Standard Design
Proposed Design
Compliance Margin
Percent Improvement
Space Heating
39.60
37.93
1.67
4.2%
Space Cooling
23.26
24.87
-1.61
-6.9%
IAQ Ventilation
0.00
0.00
0.00
0.0%
Water Heating
12.28
12.28
0.00
0.0%
Photovoltaic Offset
----
0.00
0.00
----
Compliance Energy Total
75.14
75.08
0.06
0.1%
Registration Number: Registration Date/Time:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CFiR-07082015-744
HERS Provider:
Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building . Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis Input File Name: majjiga addition, phase 2.xml
REQUIRED SPECIAL FEATURES
The following are features that must be installed as condition for meeting the modeled energy performance for this computer analysis.
• Cathedral Ceiling
• Window overhangs and/or fins
• New ductwork added is less than 40 ft. in length
HERS FEATURE SUMMARY
CF1 R -PRF -01
Page 2 of 9
The following is a summary of the features that must be field -verified by a certified HERS Rater as a condition for meeting the modeled energy performance for this computer analysis. Additional detail is
provided in the building components tables below.
Building -level Verifications:
• -- None --
Cooling System Verifications:
• -- None --
HVAC Distribution System Verifications:
• -• None --
Domestic Hot Water System Verifications:
• -- None --
ENERGY DESIGN RATING
This is the sum of the annual TDV energy consumption for energy use components included in the performance compliance approach for the Standard Design Building (Energy Budget) and the annual
TDV energy consumption for lighting and components not regulated by Title 24, Part 6 (such as domestic appliances and consumer electronics) and accounting for the annual TDV energy offset by an
on-site renewable energy system.
Reference Energy Use Energy Design Rating Margin Percent Improvement
Total Energy (kTDV/f2-yr)' 120.31 120.25 0.06 0.0%
includes calculated Appliances and Miscellaneous Energy Use (AMEU)
BUILDING - FEATURES INFORMATION
01
02
03
04
05
06
07
Project Name
Conditioned Floor Area (ft2)
Number of Dwelling
Units
Number of Bedrooms
Number of Zones
Number of Ventilation
Cooling Systems
Number of Water
Heating Systems
Residential Building
2593
1
3
3
0
1
Registration Number: Registration Date/Time: HERS Provider:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744 Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
CF1 R -PRF -01
Page 3 of 9
ZONE INFORMATION
01
02
03
04
05
06
07
Zone Name
Zone Type
HVAC System Name
Zone Floor Area
(ft2)
Avg. Ceiling
Height
Water Heating System 1
Water Heating System 2
First Floor (Previous Add
Conditioned
HVAC System
155
8
DHW Sys 1
First Floor (Existing)
Conditioned
HVAC System
12200
18 1DHW
Sys 1
First Floor Addition
Conditioned
HVAC System
238
8
DHW Sys 1
OPAQUE SURFACES
01
02
03
04
05
06
07
08
09
10
Name
Zone
Construction
Azimuth
Orientation
Gross Area (ft2)
Window & Door
Area (ft2)
Tilt
(deg)
Status
Verified
Existing
Condition
South Wall
First Floor (Previous Add
R-13 Wall
180
Back
66
90
Existing
No
North Wall
First Floor (Previous Add
R-13 Wall
0
Front
40
30
90
Existing
No
East Wall
First Floor (Previous Add
R-13 Wall
90
Left
141.4
40
90
Existing
No
Roof 3
First Floor (Previous Add
R-30 Roof Attic
155
Existing
No
Raised Floor
First Floor (Previous Add
R-19 Floor Crawlspace
155
Existing
No
South Wall 2
First Floor (Existing)
Default Wall Prior to 197
180
Back
142
90
Existing
No
West Wall
First Floor (Existing)
Default Wall Prior to 197
270
Right
594
54
90
Existing
No
North Wall 2
First Floor (Existing)
Default Wall Prior to 197
0
Front
212
52
90
Existing
No
East Wall 2
First Floor (Existing)
Default Wall Prior to 197
90
Left
266.2
91.3
90
Existing
No
Interior Surface Wall
First Floor
(Existing)>>_Garage_
Default Wall Prior to 1971
289
16.7
Existing
No
Roof 4
First Floor (Existing)
Default Roof Prior to 197
2178.6
Existing
No
Raised Floor 2
First Floor (Existing)
Default Floor Crawlspace
2200
Existing
No
East Wall 3
First Floor Addition
R-13 Wall
90
Left
68
8
90
New
N/A
South Wall 3
First Floor Addition
R-13 Wall
180
Back
224
103.998
90
New
N/A
Raised Floor 3
First Floor Addition
R-19 Floor Crawlspace
238
New
N/A
West Wall 2
_Garage_
R-0 Wall
270
Right
64
90
Existing
No
North Wall 3
_Garage_
R-0 Wall
0
Front
180
90
Existing
No
East Wall 4
_Garage_
R-0 Wall
90
Left
179
90
Existing
No
Roof 5
_Garage_
R-0 Roof Attic
504
Existing
No
Registration Number: Registration Date/Time:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744
HERS Provider:
Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: maJiga addition, phase 2.xml
CF1 R -PRF -01
Page 4 of 9
OPAQUE SURFACES — Cathedral Ceilings
01
02
03
04
05
06
06
07
08
09
10
11
12
13
Radiant
Statu
Verified Existing
Name
Construction
Type
Roof
Roof Reflectance
Framin
Barrier
Verified
s
Condition
Attic Garage
Orientatio
Area
Skylight
Roof Rise
Roof
Roof
Reflectan
Roof
g
Statu
Existing
Name
Zone
Type
n
(ft2)
Area (ft2)
(x in 12)
Pitch
Tilt(deg)
ce
Emittance
Factor
s
Condifion
Roof
First Floor (Existing)
Default Roof Prior
Front
21.5
4.3
4
0.33
18.43
0.1
0.85
0.1
Existin
No
Attic First Floor (Existing)
Attic RoofFirst Floor (Existing)
to 1971
4
0.1
0.85
No
No
Ex9 ti
No
g
Roof 2
First Floor Addition
R-30 Roof
Back
238
0
4
0.33
18.43
0.1
0.85
0.1
New
N/A
Cathedral
ATTIC
01
02
03
04
05
06
07
08
09
10
Radiant
Statu
Verified Existing
Name
Construction
Type
Roof Rise
Roof Reflectance
Roof Emittance
Barrier
Cool Roof
s
Condition
Attic Garage
Attic Garage Roof Cons
Ventilated
4
0.1
0.85
No
No
Exi ti
No
ng
Attic First Floor (Previous Add
Attic RoofFirst Floor (Previous
Ventilated
4
0.1
0.85
Yes
No
Existi
No
Add
ng
Attic First Floor (Existing)
Attic RoofFirst Floor (Existing)
Ventilated
4
0.1
0.85
No
No
Ex9 ti
No
Registration Number: Registration Date/Time: HERS Provider:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744 Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
CF1 R -PRF -01
Page 5 of 9
WINDOWS
01
02 03 04 05 06
07 08 09 10
11 12 13 1 14
01
02
03
04
05
01
02
03
04
05
06
07
08
09
10
11
Name
Surface (Orientation -Azimuth)
Width(ft)
Height (ft)
Multiplie
r
Area (ft2)
U -factor
SHGC
Exterior Shading
Status
Verified
Existing
Condition
Window
North Wall (Front -0)
----
----
1
10.0
0.58
0.65
Insect Screen (default)
Existing
No
Window 2
East Wall (Left -90)
----
0
1
40.0
0.58
0.65
Insect Screen (default)
Existing
No
Window 3
West Wall (Right -270)
----
----
1
36.0
0.58
0.65
Insect Screen (default)
Existing
No
Window 4
West Wall (Right -270)
----
----
1
18.0
0.58
0.65
Insect Screen (default)
Existing
No
Window 5
North Wall 2 (Front -0)
----
----
1
52.0
0.58
0.65
Insect Screen (default)
Existing
No
Window 6
East Wall 2 (Left -90)
----
1
71.3
0.58
0.65
Insect Screen (default)
Existing
No
New Windows
East Wall 2 (Left -90)
----
----
1
10.0
0.32
0.25
Insect Screen (default)
New
N/A
New Windows 2
East Wall 2 (Left -90)
2.5
4.0
1
10.0
0.32
0.25
Insect Screen (default)
New
N/A
Solatubes
Roof (Front -0)
----
----
1
4.3
0.42
0.40
None
Existing
No
New Skylights
Roof (Front -0)
----
----
1
16.0
0.39
0.29
None
New
N/A
New Solatube
Roof (Front -0)
----
1
1.1
0.42
0.40
None
New
N/A
Window 7
East Wall 3 (Left -90)
----
----
1
8.0
0.32
0.25
Insect Screen (default)
New
N/A
Window 8
South Wall 3 (Back -180)
6.0
4.0
1
24.0
0.32
0.25
Insect Screen (default)
New
N/A
Window 9
South Wall 3 (Back -180)
12.0
6.7
0.995
80.0
0.32
0.25
1 Insect Screen (default)
New
N/A
DOORS
01
02 03 04 05 06
07 08 09 10
11 12 13 1 14
01
02
03
04
05
06
Name
Side of Building
Area (ft2)
U -factor
Status
Verified Existing Condition
Door
North Wall
20.0
0.50
Existing
No
Door 2
Interior Surface Wall
16.7
0.50
Existing
No
OVERHANGS AND FINS
01
02 03 04 05 06
07 08 09 10
11 12 13 1 14
Overhang
Left Fin
Right Fin
Window
Depth
Left
Dist Up Extent
Right
Extent
Flap Ht.
Depth
Top Up
DistL Bot Up
Depth
Top Up Dist R
Bot Up
New Windows 2
1
1 1
1
0
0
0
0 0
0
0 0
0
Window 8
1
1 1
1
0
0
0
0 0
0
0 0
0
Window 9
1
1 1
1
0
0
0
0 0
0
0 0
0
Registration Number: Registration Date/Time:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744
HERS Provider:
Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
CF1 R -PRF -01
Page 6 of 9
OPAQUE SURFACE CONSTRUCTIONS
01
02
03
04
05
06
07
Total Cavity
Winter Design
Construction Name
Surface Type
Construction Type
Framing
R -value
U -value
Assembly Layers
• Inside Finish: Gypsum Board
• Cavity/ Frame: no insul. / 2x4
• Exterior Finish: Wood
R-0 Wall
Exterior Walls
Wood Framed Wall
2x4 @ 16 in. O.C.
none
0.302
Siding/sheathing/decking
Ceilings (below
Inside Finish: Gypsum Board
R-0 Roof Attic
attic)
Wood Framed Ceiling
2x4 @ 24 in. O.C.
none
0.481
Cavity/ Frame: no insul. /2x4
• Cavity/ Frame: no insul. / 2x4 Top Chrd
2x4 Top Chord of Roof Truss @ 24
Roof Deck: Wood Siding/sheathing/decking
Attic Garage Roof Cons
Attic Roofs
Wood Framed Ceiling
in. O.C.
none
0.644
Roofing: Light Roof (Asphalt Shingle)
• Cavity/ Frame: no insul. / 2x4 Top Chrd
Attic RoofFirst Floor (Previous
2x4 Top Chord of Roof Truss @ 24
Roof Deck: Wood Siding/sheathing/decking
Add
Attic Roofs
Wood Framed Ceiling
in. O.C.
none
0.644
Roofing: Light Roof (Asphalt Shingle)
• Floor Surface: Carpeted
Floors Over
Floor Deck: Wood Siding/sheathing/decking
R-19 Floor Crawlspace
Crawlspace
Wood Framed Floor
2x6 @ 16 in. O.C.
R 19
0.049
Cavity/ Frame: R-19 / 2x6
• Inside Finish: Gypsum Board
• Cavity/ Frame: R-13 / 2x4
• Exterior Finish: Wood
R-13 Wall
Exterior Walls
Wood Framed Wall
2x4 @ 16 in. O.C.
R 13
0.095
Siding/sheathing/decking
• Inside Finish: Gypsum Board
Ceilings (below
Cavity/Frame: R-9.1 /2x4
R-30 Roof Attic
attic)
Wood Framed Ceiling
2x4 @ 24 in. O.C.
R 30
0.032
Over Floor Joists: R-20.9 insul.
• Cavity / Frame: no insul. / 2x4 Top Chrd
2x4 Top Chord of Roof Truss @ 24
Roof Deck: Wood Siding/sheathing/decking
Attic RoofFirst Floor (Existing)
Attic Roofs
Wood Framed Ceiling
in. O.C.
none
0.644
Roofing: Light Roof (Asphalt Shingle)
• Floor Surface: Carpeted
Floors Over
Floor Deck: Wood Siding/sheathing/decking
Default Floor Crawlspace
Crawlspace
Wood Framed Floor
202 @ 16 in. O.C.
none
0.216
Cavity/ Frame: no insul. /2x12
• Inside Finish: Gypsum Board
• Cavity/Frame: no insul. /2x4
• Exterior Finish: Wood
Default Wall Prior to 197
Exterior Walls
Wood Framed Wall
2x4 @ 16 in. O.C.
none
0.302
Siding/sheathing/decking
• Inside Finish: Gypsum Board
Ceilings (below
Cavity/Frame: R-9.1 /2x4
Default Roof Prior to 197
attic)
Wood Framed Ceiling
2x4 @ 16 in. O.C.
R 11
0.083
Over Floor Joists: R-1.9 insul.
• Inside Finish: Gypsum Board
• Cavity/ Frame: R-11 / 2x4
• Roof Deck: Wood Siding/sheathing/decking
Default Roof Prior to 1971
Cathedral Ceilings
Wood Framed Ceiling
2x4 @ 16 in. O.C.
R 11
0.088
Roofing: Light Roof (Asphalt Shingle)
Registration Number: Registration Date/Time:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744
HERS Provider:
Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
CF1 R -PRF -01
Page 7 of 9
WATER HEATING SYSTEMS
01
02
03
04
05
• Inside Finish: Gypsum Board
07
08
Name
System Type
Distribution Type
Water Heater
• Cavity/ Frame: no insul. / 2x4
Default Wall Prior to 1971
Interior Walls
Wood Framed Wall
2x4 @ 16 in. O.C.
none
0.277
Other Side Finish: Gypsum Board
1
Annual
Existing
No
Floor Area
• Inside Finish: Gypsum Board
Name
System Type
Name Ducted
Name Ducted
System
System
• Cavity / Frame: R-30 / 2x12
Status
Condition
HVAC System1
Other Heating and
Heating
Yes
• Roof Deck: Wood Siding/sheathing/decking
R-30 Roof Cathedral
Cathedral Ceilings
Wood Framed Ceiling
2x12 @ 16 in. O.C.
R30
0.036
Roofing: Light Roof (Asphalt Shingle)
WATER HEATING SYSTEMS
01
02
03
04
05
06
07
08
Name
System Type
Distribution Type
Water Heater
Number of
Heaters
Solar
Fraction
M
Status
Verified Existing
Condition
DHW Sys 1
DHW
Standard
DHW Heater 1
1
Annual
Existing
No
WATER HEATERS
01
02
03
04
05
06
07
08
Name
Heater Element Type
Tank Type
Tank Volume
(gal)
Energy Factor or
Efficiency
Input Rating
Tank Exterior
Insulation R -value
Standby Loss
(Fraction)
DHW Heater 1
Natural Gas
Small Storage
50
0.575 EF
40000-Btu/hr
0
0
WATER HEATING - HERS VERIFICATION
01
02
03
04
05
06
07
Name
Pipe Insulation
Parallel Piping
Compact Distribution
Point -of Use
Recirculation with
Manual Control
Recirculation with
Sensor Control
DHW Sys 1
n/a
n/a
n/a
n/a
n/a
n/a
SPACE CONDITIONING SYSTEMS
01
02
03
04
05
06
07
08
09
Heating System
Cooling System
Distribution
Fan
Floor Area
Verified Existing
Name
System Type
Name Ducted
Name Ducted
System
System
Served
Status
Condition
HVAC System1
Other Heating and
Heating
Yes
Cooling
NO
Air Distribution
HVAC Fan
2593
Existing
No
Cooling System
Component 1
Component 1
System 1
1
Registration Number: Registration Date/Time: HERS Provider:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744 Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
HVAC - HEATING SYSTEMS
01 02 03
Name Type Efficiency
Heating Component 1 CntrlFurnace - Fuel -fired central furnace 78 AFUE
CF1 R -PRF -01
Page 8 of 9
HVAC - COOLING SYSTEMS
01
02
03 04
05
06
07
Name
System Type
Efficiency
EER SEER
Zonally Controlled
Multi -speed
Compressor
HERS Verification
Cooling Component 1
NoCooling - No cooling equipment
N/A N/A
No
No
N/A
HVAC - DISTRIBUTION SYSTEMS
01
02
03
04
05
06
07
08
09
10
Insulation
Supply Duct
Return Duct
Verified Existing
HERS
Name
Type
Duct Leakage
R -value
Location
Location
Bypass Duct
Status
Condition
Verification
Air Distribution
Ducts located in attic
Existing (not
6.0
Attic
Attic
None
Existing + New
No
N/A
System 1
specified)
IAQ (Indoor Air Quality) FANS
01 02 03 04 05
Name IAQ CFM IAQ Fan Type IAQ Recovery Effectiveness(%) HERS Verification
SFam IAQVentRpt 0 Default 0 Not Required
Registration Number: Registration Date/Time:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744
HERS Provider:
Report Generated at: 2015-07-2109:04:05
CERTIFICATE OF COMPLIANCE - RESIDENTIAL PERFORMANCE COMPLIANCE METHOD
Project Name: Residential Building Calculation Date/Time: 09:02, Tue, Jul 21, 2015
Calculation Description: Title 24 Analysis
Input File Name: majjiga addition, phase 2.xml
CF1 R -PRF -01
Page 9 of 9
DOCUMENTATION AUTHOR'S DECLARATION STATEMENT
1. 1 certify that this Certificate of Compliance documentation is accurate and complete.
Documentation Author Name: Documentation Author Signature:
PE
Rick Rocklewitz RwNz
ROB -09-1887
Company:
Signature Date:
NRG Compliance, Inc
7/21/2015
Address:
CEA/HERS Certification Identification (If applicable):
PO Box 3777
City/State ip:
Santa Rosa, California 95402
Phone:
707-237-6957
RESPONSIBLE PERSON'S DECLARATION STATEMENT
I certify the following under penalty of perjury, under the laws of the State of California:
1. I am eligible under Division 3 of the Business and Professions Code to accept responsibility for the building design identified on this Certificate of Compliance.
2. 1 certify that the energy features and performance specifications identified on this Certificate of Compliance conform to the requirements of Title 24, Part 1 and Part 6 of the California Code of
Regulations.
3. The building design features or system design features identified on this Certificate of Compliance are consistent with the information provided on other applicable compliance documents,
worksheets, calculations, plans and specifications submitted to the enforcement agency for approval with this building permit application.
Responsible Designer Name:
Re a Gig ature-
Thornton Weiler
Company:
Date Signed:
Thornton Weiler
Address:
License:
452 Lincoln Ave
City/State/Zip:
Phone:
Alameda, CA 94501
510-381-4829
Registration Number: Registration Date/Time: HERS Provider:
CA Building Energy Efficiency Standards - 2013 Residential Compliance Report Version - CF1R-07082015-744 Report Generated at: 2015-07-2109:04:05
RESIDENTIAL MEASURES SUMMARY
RMS -1
Project Name
Jithender Ma#iga
Building Type
M Single Family ❑ Addition Alone
❑ Multi Family m Existing+ Addition/Alteration
Date
7/21/2015
Project Address
21354 Dexter Drive Cupertino
California Energy Climate Zone
CA Climate Zone 04
Total Cond. Floor Area
2,593
Addition
238
# of Units
1
INSULATION
Construction Type
Cavity
Area
(ft) Special Features Status
Floor Wood Framed w/Crawl Space R 19
155 Existing
Wall Wood Framed R 13
177 Existing
Door Opaque Door -
no insulation
20 Existing
Roof Wood Framed Attic R30
155 Existing
Floor Wood Framed w/Crawl Space no insulation
2,200 Existing
Wall Wood Framed no insulation
1,365 Existing
Roof Wood Framed Attic R11
2,179 Existing
Demising Wood Framed - no insulation
21 Existing
FENESTRATION I Total Area: 381 Glazing Percentage: 14.7%1 New/Altered Average U -Factor: 0.33
Orientation Area(ft) U -Fac SHGC Overhang Sidefins Exterior Shades Status
Front (N) 62.0 0.580
0.65 none
none Bug Screen Existing
Left (E) 111.3 0.580
0.65 none
none Bug Screen Existing
Right (W) 54.0 0.580
0.65 none
none Bug Screen Existing
Left (E) 18.0 0.320
0.25 none
none Bug Screen New
Left (E) 10.0 0.320
0.25 1.0
none Bug Screen New
Skylight 4.3 0.420
0.40 none
none None Existing
Skylight 16.0 0.390
0.29 none
none None New
Skylight 1.1 0.420
0.40 none
none None New
Rear (S) 104.0 0.320
0.25 1.0
none Bug Screen New
HVAC SYSTEMS
Qty. Heating Min. Eff
Cooling
Min. Eff Thermostat Status
1 Central Furnace 78% AFUE
No Cooling
13.0 SEER Setback
Existing
HVAC DISTRIBUTION
Location Heating
Cooling
Duct
Duct Location R -Value Status
HVAC System Ducted
Ducted
Attic 6.0
Altered
WATER HEATING
Qty. Type Gallons Min. Eff Distribution Status
Ener Pro 6.6 by Ener Soft User Number. 5581
RunCode: 2015-07-21T09:04:39 ID: 012115
Pae 12 of 17
RESIDENTIAL MEASURES SUMMARY
RMS -1
Project Name
Jithender Majjiga
Building Type M Single Family ❑ Addition Alone
❑ Multi Family m Existing+ Addition/Alteration
Date
7/21/2015
Project Address
21354 Dexter Drive Cupertino
California Energy Climate Zone
CA Climate Zone 04
Total Cond. Floor Area
2,593
Addition
238
# of Units
1
INSULATION
Construction Type
Area
Cavity (ft) Special Features Status
Floor Wood Framed w/Crawl Space R 19 238 New
Roof Wood Framed Rafter R30 238 New
Wall Wood Framed R 13 180 New
FENESTRATION I Total Area: 381 Glazing Percentage: 14.7 % New/Altered Average U -Factor: 0.33
Orientation Area(ft) U -Fac SHGC Overhang Sidefins Exterior Shades Status
HVAC SYSTEMS
Qty. Heating Min. Eff
Cooling Min. Eff Thermostat Status
HVAC DISTRIBUTION
Location Heating
Duct
Cooling Duct Location R -Value Status
WATER HEATING
Qty. Type Gallons Min. Eff Distribution Status
Ener Pro 6.6 by Ener Soft User Number: 5581
RunCode: 2015-07-21T09:04:39 ID. 012115
Pae 13 of 17
2013 Low -Rise Residential Mandatory Measures Summary
NOTE: Low-rise residential buildings subject to the Standards must comply with all applicable mandatory measures listed, regardless of the
»,.,li,,., .. , --h--i Frrnn/inns m n, nnnly Roviow tho rocnortivo endo .cectinn for mnre information_
Building Envelope Measures:
§ 110.6(a)1:
Doors and windows between conditioned and unconditioned spaces are manufactured to limit air leakage.
Fenestration products (except field -fabricated windows) have a label listing the certified U -Factor, certified Solar Heat Gain
§ 110.6(a)5:
Coefficient SHGC , and infiltration that meets the requirements of § 10-111 (a).
§ 110.7:
Exterior doors and windows are weatherstripped; all joints and penetrations are caulked and sealed.
§ 110.8(a):
Insulation specified or installed meets Standards for Insulating Material. Indicate type and include on the CF2R.
The thermal emittance and aged solar reflectance values of the cool roofing material meets the requirements of § 110.8(i) when the
§ 110.8(1):
installation of a cool roof is specified on the CFIR.
§ 110.86):
A radiant barrier shall have an emittance of 0.05 or less when the installation of a radiant barrier is specified on the CF 1 R.
Minimum R-30 insulation in wood -frame ceiling; or the weighted average U -factor shall not exceed 0.031. Minimum R-19 in a
§150.0(a):
rafter roof alteration. Attic access doors shall have permanently attached insulation using adhesive or mechanical fasteners. The
attic access shall be gasketed to prevent air leakage.
§150.0(b):
Loose fill insulation shall conform with manufacturer's installed design labeled R -value.
Minimum R-13 insulation in 2x4 inch wood framing wall or have a U -factor of 0.102 or less (R-19 in 2x6 or 0.074 maximum U -
§ I50.0(c):
factor).
§ 150.0(d):
Minimum R-19 insulation in raised wood -frame floor or 0.037 maximum U -factor.
In Climate Zones 14 and 16 a Class II vapor retarder shall be installed on the conditioned space side of all insulation in all exterior
§150.0(g)l:
walls, vented attics and unvented attics with air -permeable insulation.
In Climate Zones 1-16 with unvented crawl spaces the earth floor of the crawl space shall be covered with a Class I or Class II
§ 150.0(g)2:
vapor retarder.
In a building having a controlled ventilation crawl space, a Class I or Class Il vapor retarder shall be placed over the earth floor of
§I50.0(g)3:
the crawl space to reduce moisture entry and protect insulation from condensation, as specified in the exception to Section
150.0(d).
§150.00):
Slab edge insulation shall: have a water absorption rate, for the insulation material alone without facings, no greater than 0.3%;
have water vapor permeance rate is no greater than 2.0 perm/inch, be protected from physical damage and UV light deterioration;
and when installed as part of a heated slab floor meets the requirements of § 110.8( .
Fenestration, including skylights, separating conditioned space from unconditioned space or outdoors shall have a maximum U-
150.0
§ (q)'
factor of 0.58; or the weighted average U -factor of all fenestration shall not exceed 0.58.
Fireplaces, Decorative Gas Appliances and Gas Log Measures:
§ I50.0(e)1 A:
Masonry or factory -built fireplaces have a closable metal or glass door covering the entire opening of the firebox.
§150.0(e)IB:
Masonry or factory -built fireplaces have a combustion outside air intake, which is at least six square inches in area and is
equipped with a readily accessible, operable, and tight -fitting damper or a combustion -air control device.
§I50.0(e)IC:
Masonry or factory -built fireplaces have a flue damper with a readily accessible control.
§ I50.0(e)2:
Continuous burning pilot lights and the use of indoor air for cooling a firebox jacket, when that indoor air is vented to the outside
of the building, are prohibited.
Space Conditioning, Water Heating and Plumbing System Measures:
§ 110.0-§ 110.3:
HVAC equipment, water heaters, showerheads, faucets and all other regulated appliances are certified to the Energy Commission.
Water heating recirculation loops serving multiple dwelling units meet the air release valve, backflow prevention, pump isolation
§I 10.3(c)5:
valve, and recirculation loop connection requirements of § 110.3(c)5.
Continuously burning pilot lights are prohibited for natural gas: fan -type central furnaces, household cooking appliances (appli-
§ 110.5:
ances without an electrical supply voltage connection with pilot lights that consume less than 150 Btu/hr are exempt), and pool
ands a heaters.
§150.0(h)]:
Heating and/or cooling loads are calculated in accordance with ASHRAE, SMACNA or ACCA using design conditions specified
in § 150.0(h)2.
§ I50.0(h)3A:
Installed air conditioner and heat pump outdoor condensing units shall have a clearance of at least five feet from the outlet of any
dryer vent.
§ I50.0(i):
Heating systems are equipped with thermostats that meet the setback requirements of § 110.2(c).
§ 150.00)1 A:
Storage gas water heaters with an energy factor equal to or less than the federal minimum standards shall be externally wrapped
with insulation having an installed thermal resistance ofR-12 or greater.
§ 150.00)1 B:
Unfired hot water tanks, such as storage tanks and backup storage tanks for solar water -heating systems, have R-12 external
insulation or R-16 internal insulation where the internal insulation R -value is indicated on the exterior of the tank.
For domestic hot water system piping, whether buried or unburied: the first 5 feet of hot and cold water pipes from the storage
tank, all piping with a nominal diameter of 3/4 inch or larger, all piping associated with a domestic hot water recirculation system
§ 150.00)2A:
regardless of the pipe diameter, piping from the heating source to storage tank or between tanks, piping buried below grade, and
all hot water pipes from the heating source to kitchen fixtures must be insulated according to the requirements of TABLE 120.3-
A.
§ 150.06)2B:
F
All domestic hot water pipes that are buried below grade must be installed in a waterproof and non -crushable casing or sleeve
that allows for installation, removal, and replacement of the enclosed pipe and insulation.
2013 Low -Rise Residential Mandatory Measures Summary
Pipe for cooling system lines shall be insulated as specified in § 150.0(j)2A. Piping insulation for steam and hydronic heating
§ 150.0(j)2C:
systems or hot waters stems with pressure > 15 psig shall meet the requirements in TABLE 120.3-A.
§ 150.06)3:
Insulation is protected from damage, including that due to sunlight, moisture, equipment maintenance, and wind.
Insulation expos6d to weather shall either be rated for outdoor use or installed with a cover suitable for outdoor service. For
§ I50.06)3A:
example, protected by aluminum, sheet metal, painted canvas, or plastic cover. Cellular foam insulation protected as specified or
painted with coating that is water retardant and provides shielding from solar radiation that degrades the material.
Insulation covering chilled water piping and refrigerant suction piping located outside the conditioned space shall have a Class I
§ 150.0(j)3B:
or Class II vapor retarding facing, or the insulation shall be installed at the thickness that qualifies as a Class I or Class II vapor
retarder.
Systems using gas or propane water heaters to serve individual dwelling units shall include: a 120V electrical receptacle within 3
feet of the water heater; a Category III or IV vent, or a Type B vent with straight pipe between the outside termination and the
§ 150.0(n)1:
space where the water heater is installed; a condensate drain that is no more than 2 inches higher than the base of the installed
water heater, and allows natural draining without pump assistance; and a gas supply line with a capacity of at least 200,000
Btu/hr.
§ 150.0(n)2:
Recirculating loops serving multiple dwelling units shall meet the requirements of § 110.3(c)5.
Solar water -heating systems and collectors shall be certified and rated by the Solar Rating and Certification Corporation (SRCC)
§ 150.0(n)3:
or by a testing agency approved by the Executive Director.
Ducts and Fans Measures:
All air -distribution system ducts and plenums installed are sealed and insulated to meet the requirements of CMC §601.0, §602.0,
§603.0, §604.0, §605.0 and ANSI/SMACNA-006-2006 HVAC Duct Construction Standards Metal and Flexible 3rd Edition.
Supply -air and return -air ducts and plenums are insulated to a minimum installed level of R-6.0 (or higher if required by CMC
§605.0) or enclosed entirely in directly conditioned space as confirmed through field verification and diagnostic testing
(RA3.1.4.3.8). Connections of metal ducts and inner core of flexible ducts are mechanically fastened. Openings shall be sealed
§ 150.0(m)1:
with mastic, tape, or other duct -closure system that meets the applicable requirements of UL 181, UL 181 A, or UL 181 B or
aerosol sealant that meets the requirements of UL 723. If mastic or tape is used to seal openings greater than''/, inch, the
combination of mastic and either mesh or tape shall be used. Building cavities, support platforms for air handlers, and plenums
defined or constructed with materials other than sealed sheet metal, duct board or flexible duct shall not be used for conveying
conditioned air. Building cavities and support platforms may contain ducts. Ducts installed in cavities and support platforms
shall not be compressed to cause reductions in the cross-sectional area of the ducts.
Factory -Fabricated Duct Systems shall comply with specified requirements for duct construction, connections, and closures; joints
§ 150.0(m)2:
and seams of duct systems and their components shall not be sealed with cloth back rubber adhesive duct tapes unless such tape is
used in combination with mastic and draw bands.
§ I50.0(m)3-6:
Field -Fabricated Duct Systems shall comply with requirements for: pressure -sensitive tapes, mastics, sealants, and other
requirements specified for duct construction; duct insulation R -value ratings; duct insulation thickness; and duct labeling.
§150.0(m)7:
All fan systems that exchange air between the conditioned space and the outside of the building must have backdraft or automatic
dampers.
§ 150.0(m)8:
Gravity ventilating systems serving conditioned space have either automatic or readily accessible, manually operated dampers
except combustion inlet and outlet air openings and elevator shaft vents.
Insulation shall be protected from damage, including that due to sunlight, moisture, equipment maintenance, and wind but not
§150.0(m)9:
limited to the following: insulation exposed to weather shall be suitable for outdoor service. For example, protected by aluminum,
sheet metal, painted canvas, or plastic cover. Cellular foam insulation shall be protected as above or painted with a coating that is
water retardant and provides shielding from solar radiation.
§I50.0(m)10:
Flexible ducts cannot have porous inner cores.
When space conditioning systems use forced air duct systems to supply conditioned air to an occupiable space, the ducts shall be
§I50.0(m)11:
sealed and duct leakage tested, as confirmed through field verification and diagnostic testing, in accordance with Reference
Residential Appendix RA3.
Mechanical systems that supply air to an occupiable space through ductwork exceeding 10 feet in length and through a thermal
§ I50.0(m)12:
conditioning component, except evaporative coolers, shall be provided with air filter devices that meet the requirements of
§150.0(m)12.
Space conditioning systems that utilize forced air ducts to supply cooling to an occupiable space shall have a hole for the
placement of a static pressure probe (HSPP), or a permanently installed static pressure probe (PSPP) in the supply plenum. The
§ 150.0(m)13:
space conditioning system must also demonstrate airflow > 350 CFM per ton of nominal cooling capacity through the return
grilles, and an air -handling unit fan efficacy:5 0.58 W/CFM as confirmed by field verification and diagnostic testing, in
accordance with Reference Residential Appendix RA3.
Zonally controlled central forced air cooling systems shall be capable of simultaneously delivering, in every zonal control mode,
§I50.0(m)15:
an airflow from the dwelling, through the air handler fan and delivered to the dwelling, of>_ 350 CFM per ton of nominal cooling
capacity, and operating at an air -handling unit fan efficacy of 5 0.58 W/CFM as confirmed by field verification and diagnostic
testing, in accordance with Reference Residential Appendix RA3.
All dwelling units shall meet the requirements of ASHRAE Standard 62.2. Neither window operation nor continuous operation of
§ 150.0(0):
central forced air system air handlers used in central fan integrated ventilation systems are permissible methods of providing the
Whole Building Ventilation.
§I50.0(o)IA:
Whole Building Ventilation airflow shall be confirmed through field verification and diagnostic testing, in accordance with
Reference Residential Appendix RA3.
Pool and Spa Heating Systems and Equipment Measures:
Any pool or spa heating system shall be certified to have: a thermal efficiency that complies with the Appliance Efficiency
§ 1 10.4(a):
Regulations; an on-off switch mounted outside of the heater that allows shutting off the heater without adjusting the thermostat
setting; a permanent weatherproof plate or card with operating instructions; and shall not use electric resistance heating.
2013 Low -Rise Residential Mandatory Measures Summary
Any pool or spa heating equipment shall be installed with at least 36 inches of pipe between filter and heater or dedicated suction
§ 110.4(b)1:
and return lines, or built-up connections for future solar heating.
§ 110.4(b)2:
Outdoor pools or spas that have a heat pump or gas heater shall have a cover.
Pools shall have directional inlets that adequately mix the pool water, and a time switch that will allow all pumps to be set or pro-
§ 110.4(b)3:
grammed to run only during off-peak electric demand periods.
§ 110.5:
Natural gas pool and spa heaters shall not have a continuous burning pilot light.
§ 150.0(p):
Residential pool systems or equipment shall meet specified pump sizing, flow rate, piping, filters, and valve requirements.
Lighting Measures:
§ 110.9:
All lighting control devices and systems, ballasts, and luminaires shall meet the applicable requirements of § 110.9.
Installed luminaires shall be classified as high -efficacy or low -efficacy for compliance with §I50.0(k) in accordance with TABLE
§150.0(k)IA:
150.0-A or TABLE 150.0-B, as applicable.
When a high efficacy and low efficacy lighting system are combined in a single luminaire, each system shall separately comply
§ 150.0(k) I B:
with the applicable provisions of § 150.0(k).
The wattage and classification of permanently installed luminaires in residential kitchens shall be determined in accordance with
§ 130.0(c). In residential kitchens, the wattage of electrical boxes finished with a blank cover or where no electrical equipment has
§ 150.0(k)I C:
been installed, and where the electrical box can be used for a luminaire or a surface mounted ceiling fan, shall be calculated as 180
watts of low efficacy lighting er electrical box.
§150.0(k)ID:
Ballasts for fluorescent lamps rated 13 watts or greater shall be electronic and shall have an output frequency no less than 20 kHz.
Permanently installed night lights and night lights integral to installed luminaires or exhaust fans shall be rated to consume no
§ 150.0(k)I E:
more than 5 watts of power per luminaire or exhaust fan as determined in accordance with § I30.0(c). Night lights do not need to
be controlled by vacancy sensors.
Lighting integral to exhaust fans (except when installed by the manufacturer in kitchen exhaust hoods) shall meet the applicable
§ 150.0(k)IF:
requirements of § 15 0.0 k .
§ 150.0(k)2A:
High efficacy luminaires must be switched separately from low efficacy luminaires.
§ 150.0(k)2B:
Exhaust fans shall be switched separately from lighting systems.
§I50.0(k)2C:
Luminaires shall be switched with readily accessible controls that permit the luminaires to be manually switched ON and OFF.
§ 150.0(k)2D:
Controls and equipment are installed in accordance with manufacturer's instructions.
§ 150.0(k)2E:
No control shall bypass a dimmer or vacancy sensor function if the control is installed to comply with § 150.0(k).
§ 150.0(k)2F:
Lighting controls comply with applicable requirements of § 110.9.
An Energy Management Control System (EMCS) may be used to comply with dimmer requirements if: it functions as a dimmer
§ 150.0(k)2G:
according to § 110.9; meets Installation Certificate requirements of § 130.4; the EMCS requirements of § 130.5; and all other
requirements in § 150.0(k)2.
An Energy Management Control System (EMCS) may be used to comply with vacancy sensor requirements of § 150.0(k) if. it
§ 150.0(k)2H:
functions as a vacancy sensor according to § 110.9; meets Installation Certificate requirements of § 130.4; the EMCS requirements
of § 130.5; and all other requirements in § 150.0(k)2.
A multiscene programmable controller may be used to comply with dimmer requirements of this section if it provides the
§ I50.0(k)2I:
functionality of a dimmer according to § 110.9, and complies with all other applicable requirements in § 150.0(k)2.
§150.0(k)3A:
A minimum of 50 percent of the total rated wattage of permanently installed lighting in kitchens shall be high efficacy.
Kitchen lighting includes all permanently installed lighting in the kitchen except internal lighting in cabinets that illuminate only
§ 150.0(k)3B:
the inside of the cabinets. Lighting in areas adjacent to the kitchen, including but not limited to dining and nook areas, are
considered kitchen lighting if they are not separately switched from kitchen lighting.
Permanently installed lighting that is internal to cabinets shall use no more than 20 watts of power per linear foot of illuminated
§ 150.0(k)4:
cabinet.
A minimum of one high efficacy luminaire shall be installed in each bathroom; and all other lighting installed in each bathroom
§ 150.0(k)5:
shall be high efficacy or controlled by vacancy sensors.
§ 150.0(k)6:
Lighting installed in attached and detached garages, laundry rooms, and utility rooms shall be high efficacy luminaires and
controlled by vacancy sensors.
§ I50.0(k)7:
Lighting installed in rooms or areas other than in kitchens, bathrooms, garages, laundry rooms, and utility rooms shall be high
efficacy, or shall be controlled by either dimmers or vacancy sensors.
Luminaires recessed into ceilings shall: be listed for zero clearance insulation contact (IC) by Underwriters Laboratories or other
nationally recognized testing/rating laboratory; have a label that certifies that the luminaire is airtight with air leakage less than 2.0
CFM at 75 Pascals when tested in accordance with ASTM E283; be sealed with a gasket or caulk between the luminaire housing
§ 150.0(k)8:
and ceiling, and shall have all air leak paths between conditioned and unconditioned spaces sealed with a gasket or caulk; and
allow ballast maintenance and replacement without requiring cutting holes in the ceiling.
For recessed compact fluorescent luminaries with ballasts to qualify as high efficacy for compliance with § I50.0(k), the ballasts
shall be certified to the Energy Commission to comply with the applicable requirements in § 110.9.
For single-family residential buildings, outdoor lighting permanently mounted to a residential building or other buildings on the
same lot shall be high efficacy, or may be low efficacy if it meets all of the following requirements:
i. Controlled by a manual ON and OFF switch that does not override to ON the automatic actions of Items ii or iii below; and
§ 150.0(k)9A:
ii. Controlled by a motion sensor not having an override or bypass switch that disables the motion sensor, or controlled by a
motion sensor having a temporary override switch which temporarily bypasses the motion sensing function and automatically
reactivates the motion sensor within 6 hours; and
iii. Controlled by one of the following methods:
2013 Low -Rise Residential Mandatory Measures Summary
a. Photocontrol not having an override or bypass switch that disables the photocontrol; or
b. Astronomical time clock not having an override or bypass switch that disables the astronomical time clock, and which is
programmed to automatically turn the outdoor lighting OFF during daylight hours; or
c. Energy management control system which meets all of the following requirements: At a minimum provides the functionality o I
an astronomical time clock in accordance with §110.9; meets the Installation Certification requirements in §130.4; meets the
requirements for an EMCS in § 130.5; does not have an override or bypass switch that allows the luminaire to be always ON; and.
is programmed to automatically turn the outdoor lighting OFF during daylight hours.
For low-rise multifamily residential buildings, outdoor lighting for private patios, entrances, balconies, and porches; and outdoor
lighting for residential parking lots and residential carports with less than eight vehicles per site shall comply with one of the
§ 150.0(k)9B:
following requirements:
i. Shall comply with § 150.0(k)9A; or
ii. Shall comply with the applicable requirements in § 110.9, § 130.0, § 130.2, § 130.4, § 140.7 and § 141.0.
§ I50.0(k)9C:
For low-rise residential buildings with four or more dwelling units, outdoor lighting not regulated by § 150.0(k)9B or 150.0(k)9D
shall comply with the applicable requirements in § 110.9, § 130.0, § 130.2, § 130.4, § 140.7 and § 141.0.
§ 150.0(k)9D:
Outdoor lighting for residential parking lots and residential carports with a total of eight or more vehicles per site shall comply
with the applicable requirements in § 110.9, § 130.0, § 130.2, § 130.4, § 140.7 and § 141.0.
§150.0(k)10:
Internally illuminated address signs shall comply with § 140.8; or shall consume no more than 5 watts of power as determined
according to § 13 0.0 c .
§ 150.0(k)11:
Lighting for residential parking garages for eight or more vehicles shall comply with the applicable requirements for
nonresidential garages in §110.9, 130.0, 130.1, 130.4, 140.6, and 141.0.
In a low-rise multifamily residential building where the total interior common area in a single building equals 20 percent or less of
§ 150.0(k)12A:
the floor area, permanently installed lighting for the interior common areas in that building shall be high efficacy luminaires or
controlled by an occupant sensor.
In a low-rise multifamily residential building where the total interior common area in a single building equals more than 20
percent of the floor area, permanently installed lighting in that building shall:
§ 150.0(k)12B:
i. Comply with the applicable requirements in §110.9, §130.0, §130.1, §140.6 and §141.0; and
ii. Lighting installed in corridors and stairwells shall be controlled by occupant sensors that reduce the lighting power in each
space by at least 50 percent. The occupant sensors shall be capable of turning the light fully On and Off from all designed paths o t'
ingress and egress.
Solar Ready Buildings:
Single family residences located in subdivisions with ten or more single family residences and where the application for a
§1 10.10(a)l:
tentative subdivision map for the residences has been deemed complete, by the enforcement agency, on or after January 1, 2014,
shall comply with the requirements of § 110.10 b through § 110.10 e .
§ 110.10(a)2:
Low-rise multi -family buildings shall comply with the requirements of § 110.10(b) through § 110.10(d).
The solar zone shall have a minimum total area as described below. The solar zone shall comply with access, pathway, smoke
ventilation, and spacing requirements as specified in Title 24, Part 9 or other Parts of Title 24 or in any requirements adopted by a
local jurisdiction. The solar zone total area shall be comprised of areas that have no dimension less than 5 feet and are no less than
80 square feet each for buildings with roof areas less than or equal to 10,000 square feet or no less than 160 square feet each for
§ 110.10(b)l :
buildings with roof areas greater than 10,000 square feet.
For single family residences the solar zone shall be located on the roof or overhang of the building and have a total area no less
than 250 square feet. For low-rise multi -family buildings the solar zone shall be located on the roof or overhang of the building or
on the roof or overhang of another structure located within 250 feet of the building or on covered parking installed with the
building project and have a total area no less than 15 percent of the total roof area of the building excluding any skylight area.
§ 110.10(b)2:
All sections of the solar zone located on steep -sloped roofs shall be oriented between 110 degrees and 270 degrees of true north.
§110 .10(b)3A:
No obstructions, including but not limited to, vents, chimneys, architectural features, and roof mounted equipment, shall be
located in the solar zone.
Any obstruction, located on the roof or any other part of the building that projects above a solar zone shall be located at least twice
§ 110.10(b)3B:
the distance, measured in the horizontal plane, of the height difference between the highest point of the obstruction and the
horizontal projection of the nearest point of the solar zone, measured in the vertical plane.
§ 110.10(b)4:
For areas of the roof designated as solar -none, the structural design loads for roof dead load and roof live load shall be clearly
indicated on the construction documents.
The construction documents shall indicate: a location for inverters and metering equipment and a pathway for routing of conduit
§ 1 10.10(c):
from the solar zone to the point of interconnection with the electrical service (for single family residences the point of
interconnection will be the main service panel); a pathway for routing of plumbing from the solar zone to the water -heating
system.
§ 110.10(d):
A copy of the construction documents or a comparable document indicating the information from § 110.10(b) through § 110.10(c)
shall be provided to the occupant.
§1 10.10(e)l:
The main electrical service panel shall have a minimum busbar rating of 200 amps.
The main electrical service panel shall have a reserved space to allow for the installation of a double pole circuit breaker for a
§ 110.10(e)2:
future solar electric installation. The reserved space shall be: positioned at the opposite (load) end from the input feeder location or
main circuit location, and permanently marked as "For Future Solar Electric".