The URL can be used to link to this page

14060198I�e CITY OF CUPERTINO BUILDING PERMIT BUILDING ADDRESS: 7817 LUNAR CT CONTRACTOR: EVERSPRING PERMIT NO: 14060198 CONSTRUCTION INC OWNER'S NAME: CHUANG CHUN CHEN AND BINFU 1131 S DE ANZA BLVD DATE ISSUED: 10/06/2014 OWNER'S PHONE: 4088868346 SAN JOSE, CA 95129 PHONE NO: (408) 446-8398 5Y/LICENSED CONTRACTOR'S DECLARATION JOB DESCRIPTION: RESIDENTIAL COMMERCIAL CONSTRUCT ONE STORY ADDITION (1116 SQ FT); L License Class Lie. # g -c-0 3� ✓ COMPLETE INTERIOR REMODEL (1227 SQ FT); GARAGE r_yfyeeP{z1�� CAST ate ° b 1 REMODEL TO HABITABLE (39 SQ FT); FRONT COVERED Contractor I hereby affirm that I am licensed under the provisions of Chapter 9 (commencing with Section 7000) of Division 3 of the Business & Professions Code and that my license is in full force and effect. I hereby affirm under penalty of perjury one of the following two declarations: I have and will maintain a certificate of consent to self -insure for Worker's Compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. Sq. Ft Floor Area: Valuation: $301260 I have and will maintain Worker's Compensation Insurance, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this APN Number: 36220021.00 Occupancy Type: permit is issued. APPLICANT CERTIFICATION I certify that I have read this application and state that the above information is PERMIT EXPIRES IF WORK IS NOT STARTED correct. I agree to comply with all city and county ordinances and state laws relating WITHINjW DAYS OF PER ISSUANCE OR to building construction, and hereby authorize representatives of this city to enter S F C INSPECTION. upon the above mentioned property for inspection purposes. (We) agree to save 1 indemnify and keep harmless the City of Cupertino against liabilities, judgments, costs, and expenses which may accrue against said City in consequence of the —� Date: la C granting of this permit. Additionally, the applicant understands and will com Y with all non -point sourc egulations per the Cupertino Municipal Code, Section 9.18. RE -ROOFS: Signa Date i 0 ` l y All roofs shall be inspected prior to any roofing material being installed. If a roof is installed without first obtaining an inspection, I agree to remove all new materials for inspection. ❑ OWNER -BUILDER DECLARATION Signature of Applicant: Date: I hereby affirm that I am exempt from the Contractor's License Law for one of the following two reasons: ALL ROOF COVERINGS TO BE CLASS "A" OR BETTER I, as owner of the property, or my employees with wages as their sole compensation, will do the work, and the structure is not intended or offered for sale (Sec.7044, Business & Professions Code) 1, as owner of the property, am exclusively contracting with licensed contractors to HAZARDOUS MATERIALS DISCLOSURE construct the project (Sec.7044, Business & Professions Code). I have read the hazardous materials requirements under Chapter 6.95 of the California Health & Safety Code, Sections 25505, 25533, and 25534. I will I hereby affirm under penalty of perjury one of the following three maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the declarations: Health & Safety Code, Section 25532(a) should I store or handle hazardous I have and will maintain a Certificate of Consent to self -insure for Worker's material. Additionally, should I use equipment or devices which emit hazardous Compensation, as provided for by Section 3700 of the Labor Code, for the air contaminants as defined by the Bay Area Air Quality Management District I performance of the work for which this permit is issued. will maintain compliance with the Cu Bruno Municipal Code, Chapter 9.12 and I have and will maintain Worker's Compensation Insurance, as provided for by the Health & Safety Code, Section _, nd 25534. Section 3700 of the Labor Code, for the performance of the work for which this Owner or authorized agent: Date: a permit is issued. I certify that in the performance of the work for which this permit is issued, I shall not employ any person in any manner so as to become subject to the Worker's CONSTRUCTION LENDING AGENCY Compensation laws of California. If, after making this certificate of exemption, I become subject to the Worker's Compensation provisions of the Labor Code, I must I hereby affirm that there is a construction lending agency for the performance of forthwith comply with such provisions or this permit shall be deemed revoked. work's for which this permit is issued (Sec. 3097, Civ C.) Lender's Name APPLICANT CERTIFICATION Lender's Address I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby authorize representatives of this city to enter upon the above mentioned property for inspection purposes. (We) agree to save ARCHITECT'S DECLARATION indemnify and keep harmless the City of Cupertino against liabilities, judgments, costs, and expenses which may accrue against said City in consequence of the I understand my plans shall be used as public records. granting of this permit. Additionally, the applicant understands and will comply with all non -point source regulations per the Cupertino Municipal Code, Section Licensed Professional 9.18. Signature Date CITY OF CUPERTINO BUILDING PERMIT _ I BUILDING ADDRESS: 7817 LUNAR CT CONTRACTOR: EVERSPRING PERMIT NO: 14060198 CONSTRUCTION INC OWNER'S NAME: CHUANG CHUN CHEN AND BINFU 11131 S DE ANZA BLVD DATE ISSUED: 10/06/2014 OWNER'S PHONE: 4088868346 ❑ LICENSED CONTRACTOR'S DECLARATION License Class Lic.# S6 d `Z 23S Contractor y� e_4�1 x' CC^'`'iDab Lt f, f I hereby affirm that I am licensed under the provisions of Chapter 9 (commencing with Section 7000) of Division 3 of the Business & Professions Code and that my license is in full force and effect. I hereby affirm under penalty of perjury one of the following two declarations: I have and will maintain a certificate of consent to self -insure for Worker's Compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. I have and will maintain Worker's Compensation Insurance, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. APPLICANT CERTIFICATION I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby authorize representatives of this city to enter upon the above mentioned property for inspection purposes. (We) agree to save indemnify and keep harmless the City of Cupertino against liabilities, judgments, costs, and expenses which may accrue against said City in consequence of the granting of this permit. Additionally, the applicant understands and will comply with all non -point sqjrce regulations per the Cupertino Municipal Code, Section 9.18. SignatureDate t / 1-S ❑ OWNER -BUILDER DECLARATION I hereby affirm that I am exempt from the Contractor's License Law for one of the following two reasons: I, as owner of the property, or my employees with wages as their sole compensation, will do the work, and the structure is not intended or offered for sale (Sec.7044, Business & Professions Code) I, as owner of the property, am exclusively contracting with licensed contractors to construct the project (Sec.7044, Business & Professions Code). 1 hereby affirm under penalty of perjury one of the following three declarations: I have and will maintain a Certificate of Consent to self -insure for Worker's Compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. I have and will maintain Worker's Compensation Insurance, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. 1 certify that in the performance of the work for which this permit is issued, I shall not employ any person in any manner so as to become subject to the Worker's Compensation laws of California. If, after making this certificate of exemption, I become subject to the Worker's Compensation provisions of the Labor Code, I must forthwith comply with such provisions or this permit shall be deemed revoked. APPLICANT CERTIFICATION I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby authorize representatives of this city to enter upon the above mentioned property for inspection purposes. (We) agree to save indemnify and keep harmless the City of Cupertino against liabilities, judgments, costs, and expenses which may accrue against said City in consequence of the granting of this permit. Additionally, the applicant understands and will comply with all non -point source regulations per the Cupertino Municipal Code, Section 9.18. Signature Date SAN JOSE, CA 95129 I PHONE NO: (408) 446-8398 JOB DESCRIPTION: RESIDENTIAL ❑ COMMERCIAL ❑ CONSTRUCT ONE STORY ADDITION (1116 SQ FT); COMPLETE INTERIOR REMODEL (1227 SQ FT); GARAGE REMODEL TO HABITABLE (39 SQ FT); FRONT COVERED REVISION #1- RAISE THE ADDITION PLATE HEIGHT BY 1FT; REVISE FLOOR LAYOUT TO INCREASE ADDITION SQUARE FOOTAGE TO (1137 SQ FT); INCREASE GARAGE REMODEL TO HABITABLE TO (77 SQ FT)- ISSD 1/16/2015 Sq. Ft Floor Area: I Valuation: $301260 APN Number: 36220021.00 1 Occupancy Type: PERMIT EXPIRES IF WORK IS NOT STARTED WITHIN 180 DAYS OF PERMIT ISSUANCE OR 180 DAYSM "F CALLED INSPECTION. Issued by: Date: ! • 160.1 S RE -ROOFS: All roofs shall be inspected prior to any roofing material being installed. If a roof is installed without first obtaining an inspection, I agree to remove all new materials for inspection. Signature of Applicant: Date: ALL ROOF COVERINGS TO BE CLASS "A" OR BETTER HAZARDOUS MATERIALS DISCLOSURE I have read the hazardous materials requirements under Chapter 6.95 of the California Health & Safety Code, Sections 25505, 25533, and 25534. I will maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the Health & Safety Code, Section 25532(a) should I store or handle hazardous material. Additionally, should I use equipment or devices which emit hazardous air contaminants as defined by the Bay Area Air Quality Management District I will maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the Health &Safety Code, Secti fis��nd5534. Owner or authorized a n : Date: CONSTRUCTION LENDING AGENCY I hereby affirm that there is a construction lending agency for the performance of work's for which this permit is issued (Sec. 3097, Civ C.) Lender's Name -- Lender's Address ARCHITECT'S DECLARATION I understand my plans shall be used as public records. Licensed Professional CITY OF CUPERTINO BUILDING PERMIT BUILDING ADDRESS: 7817 LUNAR CT OWNER'S NAME: CHUANG CHUN CHEN AND BINFU OWNER'S PHONE: 4088868346 F, LICENSED CONTRACTOR'S DECLARATION License Class Li,. # O vy 3%S Contractor Cc-6'tDate 16 I hereby affirm that I am licensed under the provisions of Chapter 9 (commencing with Section 7000) of Division 3 of the Business & Professions Code and that my license is in full force and effect. I hereby affirm under penalty of perjury one of the following two declarations: t. I have and will maintain a certificate of consent to self -insure for Worker's Compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. SIhave and will maintain Worker's Compensation Insurance, as provided for by ection 3700 of the Labor Code, for the performance of the work for which this ermit is issued. APPLICANT CERTIFICATION I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby authorize representatives of this city to enter upon the above mentioned property for inspection purposes. (We) agree to save indemnify and keep harmless the City of Cupertino against liabilities, judgments, costs, and expenses which may accrue against said City in consequence of the granting of this pe it. Additionally, the applicant understands and will comply with all non -point sou ce re rtino Municipal Code, Section 9.18. Sign Date Id t b ❑ OWNER -BUILDER DECLARATION I hereby affirm that I am exempt from the Contractor's License Law for one of the following two reasons: t. I, as owner of the property, or my employees with wages as their sole compensation, will do the work, and the structure is not intended or offered for sale (Sec.7044, Business & Professions Code) 2. I, as owner of the property, am exclusively contracting with licensed contractors to construct the project (Sec.7044, Business & Professions Code). I hereby affirm under penalty of perjury one of the following three declarations: t. I have and will maintain a Certificate of Consent to self -insure for Worker's Compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. 2. I have and will maintain Worker's Compensation Insurance, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. 3. I certify that in the performance of the work for which this permit is issued, I shall not employ any person in any manner so as to become subject to the Worker's Compensation laws of California. If, after making this certificate of exemption, I become subject to the Worker's Compensation provisions of the Labor Code, I must forthwith comply with such provisions or this permit shall be deemed revoked. APPLICANT CERTIFICATION I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby authorize representatives of this city to enter upon the above mentioned property for inspection purposes. (We) agree to save indemnify and keep harmless the City of Cupertino against liabilities, judgments, costs, and expenses which may accrue against said City in consequence of the granting of this permit. Additionally, the applicant understands and will comply with all non -point source regulations per the Cupertino Municipal Code, Section 9.18. Signature Date CONTRACTOR: EVERSPRING i %7FRMT NO: 14060198 CONSTRUCTION INC I 1131 S DE ANZA BLVD I DATE ISSUED: 10/06/2014 SAN JOSE, CA 95129 1 PHONE NO: (408) 446-8398 JOB DESCRIPTION: RESIDENTIAL ❑ COMMERCIAL ❑ CONSTRUCT ONE STORY ADDITION (1116 SQ FT); COMPLETE INTERIOR REMODEL (1227 SQ FT); GARAGE REMODEL TO HABITABLE (39 SQ FT); FRONT COVERED REVISION #2: EXTEND THE FRONT PORCH (14 SQ FT). Issued 10-5-15. Sq. Ft Floor Area: I Valuation: 5301260 APN Number: 36220021.00 1 Occupancy Type: PERMIT EXPIRES IF WORK IS NOT STARTED WITHIN 180 DAYS OF PERMIT ISSUANCE OR 180 D S FROM LAST CALLED INS INS1�P,5CJ:N Issued by: t0/4vDate• ". RE -ROOFS: All roofs shall be inspected prior to any roofing material being installed. If a roof is installed without first obtaining an inspection, I agree to remove all new materials for inspection. Signature of Applicant: Date: ALL ROOF COVERINGS TO BE CLASS "A" OR BETTER HAZARDOUS MATERIALS DISCLOSURE I have read the hazardous materials requirements under Chapter 6.95 of the California Health & Safety Code, Sections 25505, 25533, and 25534. I will maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the Health & Safety Code, Section 25532(a) should I store or handle hazardous material. Additionally, should I use equipment or devices which emit hazardous air contaminants as defined by the Bay Area Air Quality Management District I will maintain compliance with the Cupertino Municipal Code, Chapter 9.12 and the Health & Safety Code, Sections 25505, 25533, and 25534. W al'5 CONSTRUCTION LENDING AGENCY I hereby affirm that there is a construction lending agency for the performance of work's for which this permit is issued (Sec. 3097, Civ C.) Lender's Name Lender's Address ARCHITECT'S DECLARATION I understand my plans shall be used as public records. Licensed Professional CONSTRUCTION PERMIT APPLICATION COMMUNITY DEVELOPMENT DEPARTMENT • BUILDING DIVISION O� 10300 TORRE AVENUE • CUPERTINO, CA 95014-3255 (408) 777-3228 • FAX (408) 777-3333 • build ing(a)cupertino.org CUPERTINO n NFr-7 W CONSTRI 1CTION 0 ADDITION I I ALTERATION/Tl ❑ REVISION /DEFERRED ORIGINAL PERMIT # ---- PROJECT ADDRESS nQ /7 un01v /'e. (G��C APN # // OWNER NAME G/fun /'G ]/� PHONE /�0 \�.p/��✓ U / Q E-MAIL r \Z1P G�IrgC�CAfa'[ STREET ADDRESS /� 7,/ �II��i ��K �, A�p Q /-1� CiTY,�� C14 FAX ✓. -17 �,JO fab /J CONTACT CONTACT NAME Q � W�jB PHONE V,) ) o L J ` (Zl!; ��`J E-MAIL STREET ADDRESS a0 /LdI pNf /� / yj .�i Y1 r❑r (� CITY, STATE`, /] FAX `�i ❑ OWNER ❑ OWNER -BUILDER OWNER(,JAGEENT ❑ CONTRACTOR ❑ CONTRACTOR AGENT -<ARCHITEECCT ❑ ENGINEER ❑ DEVELOPER ❑ TENANT CONTRACTOR NAME LICENSE NUMBER LICENSE TYPE BUS. LIC # COMPANY NAME E-MAIL FAX STREET ADDRESS CITY, STATE, ZIP PHONE ARCHITECT/ENGINEER NAME LICENSE NUMBER ` / f/� BUS. LIC # COMPANY NAME E-MAIL ` 0,1 1 l LO FAX / / „�0 , STREET ADDRESS O /. ob- / / O CITY, STATE, ZIP,, PHONE 1 02 f 02 .f7pe VIn, (fit Q (� , DESCRIPTION OF WORK / �B�v /_/ �e/ �O^ �/��•. ) 0 �X�� /` a. 7' �,.. x i,f LAJ= v/ rAlIfC U rc� � EXISTING USE P OPOSED USE CONSTR. ' \ TYPE U # S DRIES USE TYPE OCC. SQ.FT. VALUATION (S) EXISTG AREA / NEW FLOOR AREA /// 6 DEMO AREA TOTAL l NET AREA l P 4 �i. ✓ ' /116 /�8i �6 C BATHROOM REMODEL AREA 66 - J I KITCHEN 3 REMODEL AREA J� J OTHER REMODEL AREA g � 9 Moto&, 41 21 �1 �.,a,/ , � V PORCH AREA DECK AREA I TOTAL DECKIPORCH AREA GARAGE AREA: DETACH ATTACH 1 J1 T07 f+ # DWELLING UNITS: ISA SECOND U IT YES =DSTORY []YESf.I N BEING ADDED? O ON? 5�40 PRE -APPLICATION []YES IF YES, PROVIDE COPY OF PLANNING APPL # �PLANNING APPROVAL LETTER IS THE BLDG AN ❑ YES (NO EICHLER HOE? 1(NO M1j' RECEIVED BY: TOTAL VALUATION: 1 D /3 [,D / v By my signature below, I certify to each of the following: I am the property owner or authorized agent to act on the property owner's behalf. 1 have read this application and the information I have provided is correct. I have read the scription of Work and verify it is accurate. I agree to comply with all applicable local ordinances and state laws relating to building construction. 1 authorize re entatives of Cupertino to enter the above -identified property for inspection purposes. Signature of Applicant(Agent: Date: O SUPPLEMENTAL INFORMATION REQ D PLAN CHECK TYPE ROUTING SLIP ❑ OVER-THE-COUNTER ❑ BUILDING PLAN REVIEW _ New SFD or Multifamily dwellings: Apply for demolition permit for existing building(s). Demolition permit is required prior to issuance of building permit for new building. ❑ EXPRESS ❑ PLANNING PLAN REVIEW _ Commercial Bldgs: Provide a completed Hazardous Materials Disclosure ❑ STANDARD ❑ PUBLIC WORKS form if any Hazardous Materials are being used as part of this project. ❑ LARGE ❑ FIRE DEPT Copy of Planning Approval Letter or Meeting with Planning prior to ❑ MAJOR ❑ SANITARY SEWER DISTRICT submittal of Building Permit application. ❑ ENVIRONMENTAL HEALTH BldgApp_201 Ldoc revised 06/21/11 IN ❑ NEW CONSTRUCTIOP CONSTRUCTION PERMIT APPLICATION COMMUNITY DEVELOPMENT DEPARTMENT • BUILDING DIVISION 10300 TORRE AVENUE • CUPERTINO, CA 95014-3255 (408) 777-3228 • FAX (408) 777-3333 • building aQcupertino.org la 0-1 ❑ ADDITION ❑ ALTERATION / TI X REVISION /DEFERRED ORIGINAL PERMIT # / M / BldgApp_2011.doc revised 06/21/11 PROJECT ADDRESS /J / ) 'l yA r /' _ ,r� ' 'CPN 4 PHONE f a- px OWNER NAME h yn-ClIC11.IFaCIN4` (/,j+�,3 y� E -M AII�404CCr?a � I'�t� t STREET ADDRESS / CITY, STATE, IP A Q {i/ y I FAX A, �� `' (:;,4 n a aw !`JI' CONTACT NAME PHOATE p / E-MAIL /11 � G DAp (! �2+`'r K 4 a STREET ADDRESS CITY, STATE, ZIP FAX ❑ OWNER ❑ OWNER -BUILDER ❑ OWNER AGENT ❑ CONTRACTOR ❑ CONTRACTOR AGENT ❑ ARCHITECT ❑ ENGINEER ❑ DEVELOPER ❑ TENANT CONTRACTOR NAME LICENSE NUMBER LICENSE TYPE BUS. LIC K COMPANY NAME E-MAIL FAX STREET ADDRESS CITY, STATE, ZIP PHONE ARCHITECT/ENGINEER NAME LICENSE NUMBER BUS. LIC # COMPANY NAME E-MAIL FAX STREET ADDRESS CITY, STATE, ZIP PHONE DESCRIPTION OF WORK t + t L +y, �e Jre opt 1.rr�Pj•► ti� Ic +/`ate 407 /, fWctV oo10 fel �G ft�✓� v Y' oW a "em, / fit. /?efface H�e�r • .rbc � �f �n� fU�, EXISTING USE PROPOSED USE CONSTR. TYPE # STOPIES USE TYPE OCC. SQ.FT. VALUATION (S) EXISTG NEW FLOOR DEMO TOTAL AREA AREA AREA NET AREA BATHROOM REMODEL AREA AREA OTHER REMODEL AREA PORCH AREA DECAL tBErNG DECK/PORCH AREA GARAGE AREA: DETACH ❑ ATTACH DWELLING UNITS:D UNIT ❑ PES SECOND STORY ❑ YES DED? E]NO ADDITION? []NO PRE -APPLICATION ❑YES IF YES, PROVIDE COPY OF LETTER IS THE BLDG AN ❑ YES EICHLER HOAI E? NO RECEIVED BY - TOTAL VALUATION: PLANTING APPL9 []NO PLANNING APPROVAL By my signature below, I certify to each of the following: I am the property owner or authorized agent to act on the property owner's behalf. I have read this application and the information I have provided is correct. I have read the Description of Work and verify it is accurate. I agree to comply with all applicable local ordinances and state laws relating to build] o oils ruction. I authorize representatives of Cupertino to enter the above -identified property for inspection purposes. Signature of Applicant/Agent: Date: Y SUPPLEMENTAL INFORMATION REQUIRED PLANCHECKTYPE ROUTING'SLIP El OVER -THE COUNTER ❑ BUILDING PLAN REVIEW New SFD or Multifamily dwellings: Apply for demolition permit for existing building(s). Demolition permit is required prior to issuance of building permit for new building. ❑ EXPRESS ❑ PLANNING PLAN REVIEW i. Commercial B1d-s: Provide a completed Hazardous Materials Disclosure ❑ STANDARD ❑ PUBLIC\YORKS _ form if any Hazardous Materials are being used as part of this project. ❑ LARCE 0 FIRE DEPT Copy of Planning Approval Letter or Meeting with Planning prior to ❑ MA' JOR ❑ SANITARY SEWERDISTIUCT submittal of Building Permit application. El EN1'IRONNIENTAL HEALTH - BldgApp_2011.doc revised 06/21/11 CONSTRUCTION PERMIT APPLICATION COMMUNITY DEVELOPMENT DEPARTMENT • BUIL�ING•DIVISICN 10300 TORRE AVENUE • CUPERTINO, CA 95014-32b5',, (408) 777-3228 • FAX (408) 777-3333 • building(c-)cuperbno.crq CUPERTINO �yy n T.TFW Cn1NTSTRT1CTTnN I ADDTTT0N I AI_TFRATTnN / TT 17�t RFVTSTnN / DFFFRRFD ORIGINAL PERMIT T PROJECf ADDRESS ' APN k 12 { OWNER NAME PHONE E -MATE 1 I� aan u 3 nCnu C,htoF, hG STREET ADDRESS U CITY, STATE ZIF ( / //� FAX amm p bird Plot J b N Get CONTACT NAVE �J `� �� PHONE ` 21) E-MAIL 1 -73%\ J (Vw U M l l )� //// STREET ADDRESS / c) nI� CITY, STATE, ZIP + toFAX I' r ❑ OWNER ❑ O' NER-BUILDER ❑ OWNER AGENT ❑ CONTRACTOR ❑ CONTRACTOR AGENT ❑ ARCHITECT ❑ ENGINEER ❑ DEVELOPER ❑ TENANT CONTRACTORNAME LICENSENUI,1BER LICENSE TYPE BUS. LIC COMPANY NAME E-MAIL FAX STREET ADDRESS CITY, STATE, ZIP PHONE ARCH1TECT/E' WEER NAME LICENSENUMBER BUS. LIC I COMPANY TdAA3E E-MAIL — FAX STREET ADDRESS & I ^' CITY, ST TE, ZIP PHONE 17 'v Q 1 DESCRIPTION OF WORK p'E� r�i EXISTING USE PROPOSED USE CONSTR TYPE I STORIES USE TYPE OCC. SQ.FT. VALUATION (S) EXISTG NEW FLOOR DEMO TOTAL AREA AREA AREA NET AREA - BATHROOM KITCHEN OTHER REMODEL AREA REMODEL .AREA REMODEL AREA PORCH AREA DECK AREA TOTAL DECK/PORCH AREA GARAGE AREA: DETACH ❑ ATTACH DWELLDJG UNITS: IS ASECOND UNIT 1:3 YES SECONDSTORY [I YES BEING ADDED? []NO ADDITION? ❑NO PRE -APPLICATION ❑ YES IF YES, PROVIDE COPY OF IS THE BLDG AN ❑ YES R.ECEI Y 4: { '' TOTAL YOEj74ATION: PLANNING APPL R ❑ NO PLANNING APPROVAL LETTER EICHLER HOME? ❑ TO _ .1 By my signature below, I certify to each of the following: I am the property owner or authorized agent to act on the property owner's behalf. I have read this application and the information I have provided is correct. I have read the Description of Work and verify it is accurate. I agree to comply with all applicable local ordinances and state laws relating to building construction. I au rize representatives of Cupertino to enter the above -identified property for inspection purposes. Si_-natureofApplicant/Agent: Date: 0 7— SUPPLEMENTAL D\TFORMATI0 QUIRED = e-y_PLAN,CI�CKTIPE::�- 4 _= �.ti ;yr320iTfJNGSI:IP.,i , '�•�,, New SFD or Multifamily d%ellings: Apply for demolition permit for existing building(s). Demolition permit is required prior to issuance of building4,�.� " OS -ER THECOIIhTER BUII,DI'_�G PL+\N REVIEPV �. � permit for new building. E55 s's�# 4 P an7NT .GPi: REVIEW _ Commercial Bldgs: Provide a completed Hazardous Materials Disclosure g ❑ sral:DAxD O OPENER .__ uB� form if any Hazardo Materials are being used as part of this project. _ Copy of Planning Approval Letter or Meeting with Planning prior to ' ❑` xTA7oRzf submittal of Building Permit application. ;;, ARIFsERERDIsrRr BldgApp_2011.doc revised 06121/11 Cro CITY OF CUPERTINO FEE ESTIMATOR - BUILDING DIVISION NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public works, Tire, samrary newer District acnooi ba—d n" Aar/i nomin—, information availahle and are on1v an estimate. Contact the Dept for addn'l info. �wusu, e•a,.. u•wc cw ....c o.w�» ........, ...».........- FEE ITEMS (Fee Resolution 11-053 Ef ' Z/f 1!131 ADDRESS: 7817 lunar ct I DATE: 12/11/2014 REVIEWED BY: MENDEZ APN: BPO: "VALUATION: 1$4,000 *PERMIT TYPE: Building Permit PLAN CHECK TYPE: Alteration / Repair PRIMARY 0.0 PENTAMATION SFD or Duplex USE: p PME Plan Check: PERMIT TYPE: i WORK Revision #1- raise the addition plate height by 1ft. revise floor layout Permit Fee: SCOPE Suppl. Insp. Feer Reg. Q OT NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public works, Tire, samrary newer District acnooi ba—d n" Aar/i nomin—, information availahle and are on1v an estimate. Contact the Dept for addn'l info. �wusu, e•a,.. u•wc cw ....c o.w�» ........, ...».........- FEE ITEMS (Fee Resolution 11-053 Ef ' Z/f 1!131 FEE QTY/FEE MISC ITEMS �_ llec. I'arr�ait t�'et ED -L- Select a Misc Bldg/Structure or Element of a Building 0'bej' z Insp. E3 NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public works, Tire, samrary newer District acnooi ba—d n" Aar/i nomin—, information availahle and are on1v an estimate. Contact the Dept for addn'l info. �wusu, e•a,.. u•wc cw ....c o.w�» ........, ...».........- FEE ITEMS (Fee Resolution 11-053 Ef ' Z/f 1!131 FEE QTY/FEE MISC ITEMS Plan Check Fee: $0.00 Select a Misc Bldg/Structure or Element of a Building Suppl. PC Fee: Q Reg. Q OT 0.0 hrs $0.00 PME Plan Check: $0.00 Permit Fee: $0.00 Suppl. Insp. Feer Reg. Q OT 0.0 hrs $0.00 PME Unit Fee: $0.00 PMEPermit Fee: $0.00 i ()iC:li{ t.fe=f1i.3�i L ri.i. _T71 Y 17i72i11f,�it Ilb'r' t''c'(': E) Work Without Permit? 0 Yes (F) No $0.00 Advanced Planning Fee: $0.00 Select a Non -Residential Building or Structure 0 Strong Motion Fee: IBSEISMICR $0.52 1 it $716.00 Revisions IREVRESADD I Addition Bldg Stds Commission Fee: 1BCBSC $1.00 SUBTOTALS: $1.52 $716.00 TOTAL FEE: $717.52 Revised: 10/01/2014 CITY OF CUPERTINO WE FEE ESTIMATOR - BUILDING DIVISION im,ADDRESS: 7817 Lunar Ct DATE: 10/05/2015 REVIEWED BY: Sean Afech. Permit fees APN: BP#: *VALUATION: Iso *PERMIT TYPE: Building Permit PLAN CHECK TYPE: Alteration / Repair PRIMARY USE: SFD or Duplex PME Plan Check: PENTAMATION PERMIT TYPE: 1GENRE WORK Revision #2: Extend the front porch 14 sq ft). SCOPE Suppl. Insp. Fee -(F) Reg. OT NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public Works, Fire, Sanitary Sewer District, School District. etc-). These fees are based on the vreliminary information available and are onlv an estimate. Contact the Dept for addn'l info. FEE ITEMS (Fee Resolution 11-053 Eff 7%1/13) Afech, Plan Cheek 11hwrh_ Plein Check FT '7iec..Plan (;heck Afech. Permit fees Plumb. Permit Fee., Fli:c. Permit Fee Other Hech. Insp Other Plumb Insp. lrher Elec. Insp. $0.00 PME Plan Check: $0.00 NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public Works, Fire, Sanitary Sewer District, School District. etc-). These fees are based on the vreliminary information available and are onlv an estimate. Contact the Dept for addn'l info. FEE ITEMS (Fee Resolution 11-053 Eff 7%1/13) FEE QTY/FEE MISC ITEMS Plan Check Fee: Hourly Only? () Yes Q No $0.00 hours Plan Check, Hourly $286.00 ISTPLNCK Suppl. PC Fee: 0 Reg. 0 OT 0.0 1 hrs $0.00 PME Plan Check: $0.00 Permit Fee: $0.00 Suppl. Insp. Fee -(F) Reg. OT 0,0 hrs $0.00 PME Unit Fee: $0.00 PME Permit Fee: $0.00 Construction Tax: Administrative Fee: E) Work Without Permit? 0 Yes (j) No $0.00 Advanced Planning Fee: $0.00 Select allon-Residential Building or Structure i 1 rut=el Docunenlatiort fees: Strong Motion Fee: $0.00 Select an Administrative Item Bldg* Stds Commission Fee: $0.00 SUBTOTALS: $0.00 $286.00 TOTAL FEE: $286.00 Revised: 07/02/2015 CITY OF CUPERTINO li'i►►1 FFF. ESTIMATOR — BUILDING DIVISION im,ADDRESS: 7818 lunar ct TYPE OF CONSTR. DATE: 06/30/2014 REVIEWED BY: Mendez APN: BP#: (�cE�� *VALUATION: $301,260 *PERMIT TYPE: Building Permit II-B,III-B,IV,V-B PLAN CHECK TYPE: Addition PRIMARY USE: SFD or Duplex 2nd Unit? Yes '` No OTC? 0 Yes 0 N PENTAMATION 1 R3SFDADD PERMIT TYPE: i WORK 11116 sq ft addition to side of sfdwl remodel 1227 of existing, panel upgrade 200 am SCOPE Permit Fee: $1,760.50 OCCUPANCY TYPE: TYPE OF CONSTR. FLR AREA s.f. PC FEES PC FEE ID BP FEES BP FEE ID R-3 (Custom) II-B,III-B,IV,V-B 1,116 $2,617.06 IR3PLNCK $1,760.50 IR3INSP PME Plan Check: $0.00 200 amps $47.00 Electrical 1BELEC200 Services Permit Fee: $1,760.50 Suppl. Insp. Fee:Q Reg. OT 0.0 hrs $0.00 PME Unit Fee: $0.00 PME Permit Fee: $47.00 TOTALS: 1,116 $2,617.06 $1,760.50 MECH, HOURLY O Yes (j) No PLUMB, HOURLY Q Yes) No ELEC, HOURLY Q Yes Q No MISC ITEMS Elec. Plan Check 0.0 1 hrs $0.00 $2,617.06 1,227 s.f. $4,470.00 Elec. Permit Fee: IEPERMIT Suppl. PC Fee: Q Reg. Q OT Other Elea Insp. 0.0 hrs $0.00 PME Plan Check: NOTE: This estimate does not include fees due to other Departments (i.e. Planning, Public Works, Fire, Sanitary Sewer District, School Distri-etai These fees are based on the relimina in ormation available and are oniv an estimate. Contact the De t or addn'1 info. FEE ITEMS (Fee Resolution 11-053 Eff.' 711!13) FEE QTY/FEE MISC ITEMS Plan Check Fee: $2,617.06 1,227 s.f. $4,470.00 Remodel, Other 1REMRES2 Suppl. PC Fee: Q Reg. Q OT 0.0 hrs $0.00 PME Plan Check: $0.00 200 amps $47.00 Electrical 1BELEC200 Services Permit Fee: $1,760.50 Suppl. Insp. Fee:Q Reg. OT 0.0 hrs $0.00 PME Unit Fee: $0.00 PME Permit Fee: $47.00 G Work Without Permit? Yes No $0.00 Advanced Planning Fee: IPLLONGR $156.24 Select a Non -Residential Building or Structure E) 0 i Travel Documentation Fee: ITRAVDOC $47.00 Stronp, Motion Fee: IBSEISMICR $30.13 Select an Administrative Item Bldg* Stds Commission Fee: IBCBSC $13.00 SUBTOTALS: $4,670.931$4,517.00 TOTAL FEE: $9,187.93 Revised: 04/01/2014 CUPERTINO I/ CONTRACTOR / SUBCONTRACTOR LIST Building Department City Of Cupertino 10300 Torre Avenue Cupertino, CA 95014-3255 Telephone: 408-777-3228 Fax: 408-777-3333 JOB ADDRESS: %* WWU W- G,+.y PERMIT # 14060('%'9 OWNER'S NAME: CgtAAN(r G.Vv4Pa CEK PHONE # C4SI ) (6G2 -G( Z GENERAL CONTRACTOR: %,;vtor0W11/ F- Ce-* M -C-1 W BUSINESS LICENSE # 2-0tq 3a, ADDRESS: X131 e P& A644 13.,%4d'. CITY/ZIPCODE:sAIJ 0'2'* 1 RSl-2-' *Our municipal code requires all businesses working in the city to have a City of Cupertino business license. NO BUILDING FINAL OR FINAL OCCUPANCY INSPECTION(S) WILL BE SCHEDULED UNTIL THE GENERAL CONTRACTOR AND ALL SU RS HAVE OBTAINED A CITY OF CUPERTINO BUSINESS LICENSE. —a I am not using any subcontractors: ZS'/ ( � Signature Date Please check applicable subcontractors and complete the following information: Owner / Contractor Signature 545 t,c Date SUBCONTRACTOR BUSINESS NAME BUSINESS LICENSE # Cabinets & Millwork Cement Finishing Electrical Excavation Fencing Flooring / Carpeting Linoleum / Wood Glass / Glazing Heating Insulation Landscaping Lathing Masonry Painting / Wallpaper Paving Plastering Plumbing Roofing Septic Tank Sheet Metal Sheet Rock Tile Owner / Contractor Signature 545 t,c Date CUPERT1740 - CALGREEN RESIDENTIAL CHECKLIST — MANDATORY ITEMS RECEIVED COMMUNITY DEVELOPMENT DEPARTMENT • BUILDING DIVISION ALBERT SALVADOR—P.E.,C.B.Q.-BU ILD INGOFFLCIAI _ SEP 10 014 10300 TORRE AVENUE • CUPERTINO, CA 95014-3255 (408) 777-3228 • FAX (408) 777-3333 • building@cupertino.org BY PURPOSE: '' ``RR TTAL The 2013 CalGreen Code a lied'dltTi onstructed hotels, motels, lodging houses, dwellings, PP dormitories, condominiums, shelters, con residences, -bu' other types of swellings with sleeping acc mmodations and n i o t it uses. Existing site and landscaping improvements that are no is dis r of �e e requirements of CALGreen. Project Name: Project Address: Chuang Residence- Addition & Remodel 7817 Lunar Court Project Description: Addition & Remodel to Existing Single Story House Instructions: 1. The Owner or the Owner's agent shall employ a licensed professional experienced with the California Green Building Standards Codes to verify and assure that all required work described herein is properly planned and implemented in the project. 2. The licensed professional, in collaboration with the owner and the design professional shall initial Column 2 of this checklist, sign and date Section 1 - Design Verification at the end of this checklist and have the checklist printed on the approved plans for the project. 3. Prior to final inspection by the Building Department, the licensed professional shall complete Column 3 and sign and date Section 2 - Implementation Verification at the end of this checklist and submit the completed form to the Building Inspector. Column 2 Column 3 MANDATORY FEATURE OR MEASURE Project Verification Requirements Planning and Design - Site Development 4.106.2 Storm water drainage and retention during construction. A plan is developed and implemented to manage storm water drainage during ❑X ❑ construction. Y ..a 4.106.3 Grading and paving. The site shall be planned and d loped to Dep 1 keep surface water away from buildings. Construction plans sh fl indicate how ❑ site grading or a drainage system will manage all surface water Mows. tr RE'vo--v EL, 1-0O3 c Vi_% i3OVIPLANCE F[GYIC1nvCl By. Jam+>n f%fl Page I of 5 CalGreen_2014.doc revised 01/15/14 A4.2 General 4.201.1 Low-rise residential buildings shall meet or exceed the minimum 0 standard design required by the California Energy Standards. A4.3 WATER EFFICIENCY AND CONSERVATION Indoor Water Use 4.303.1 Water conserving plumbing fixtures and fittings. Plumbing fixtures (water closets and urinals) and fittings (faucets and showerheads) shall comply with the following: ❑ 4.303.1.3.2 Water Closets. The effective flush volume of all water closets shall not exceed 1.28 gallons per flush. Tank -type water closets shall be certified to the performance criteria of the U.S. EPA WaterSense Specifications for Tank -type Toilets. ❑ 4.303.1.3.2 Urinals. The effective flush volume of urinals shall not exceed 0.5 gallons per flush. ❑ 4.303.1.3.1 Single Showerheads. Showerheads shall have a maximum flow rate of not more than 2.0 gallons per minute at 80 psi. Showerheads shall be certified to the performance criteria of the U.S. EPA WaterSense Specification for showerheads. ❑ 4.303.1.3.2 Multiple Showerheads serving one shower. When a shower is served by more than one showerhead, the combined flow rate of all showerheads and/or other shower outlets controlled by a single valve shall not exceed 2.0 gallons per minute at 80 psi, or the shower shall be designed to allow only one shower outlet to be in operation at a time. ❑ 4.303.1.4.1 Residential lavatory faucets. The maximum flow rate of residential lavatory faucets shall not exceed 1.5 gallons per minute at 60 psi. The minimum flow rate of residential lavatory faucets shall not be less than 0.8 gallons per minute at 20 psi. ❑ 4.303.1.3.2 Lavatory faucets in common and public use areas. The maximum flow rate of lavatory faucets installed in common and public use areas (outside of dwellings or sleeping units) in residential buildings shall not exceed 0.5 gallons per minute at 60 psi. ❑ 4.303.1.4.3 Metering faucets. Metering faucets when installed in residential buildings shall not deliver more than 0.25 gallons per cycle. ❑ 4.303.1.4.4 Kitchen Faucets. The maximum flow rate of kitchen faucets shall not exceed 1.8 gallons per minute at 60 psi. Kitchen faucets may temporarily increase the flow above the maximum rate, but not to exceed 2.2 gallons per minute at 60 psi, and must default to a maximum flow rate of 1.8 gallons per minute at 60 psi. 4.303.2 Standards for plumbing fixtures and fittings. Plumbing fixtures and fittings shall be installed in accordance with the California Plumbing Code, and shall meet the applicable standards referenced in Table 1401.1 of the California Plumbing Code. Page 2 of 5 CalGreen_2014.doc revised 01/15/14 Outdoor Water Use 4.304.1 Irrigation controllers. Automatic irrigation systems installed at the time of final inspection shall be weather -based. ❑ 4.304.1.1 Controllers shall be weather- or soil moisture -based controllers that automatically adjust irrigation in response to changes in plants' needs as weather conditions change. ❑ ❑ ❑ 4.304.1.2 Weather -based controllers without integral rain sensors or communication systems that account for local rainfall shall have a separate wired or wireless rain sensor which connects or communicated with the controller(s). Soil moisture -based controllers are not required to have rain sensor input. ... MATERIAL Enhanced Durability and Reduced Maintenance 4.406.1 Rodent proofing. Annular spaces around pipes, electric cables, conduits, or other openings in plates at exterior walls shall be protected ❑ ❑ against the passage of rodents by closing such openings with cement mortar, concrete masonry or similar method acceptable to the enforcing agency. Construction Waste Reduction, Disposal and Recycling 4.408.2 Construction waste management plan. Where a local jurisdiction does not have a construction and demolition waste management ordinance, a ® ❑ construction waste management plan shall be submitted for approval to the enforcing agency. Building Maintenance and Operation 4.410.1 Operation and maintenance manual. At the time of final inspection, an operation and maintenance manual shall be provided to the building ® ❑ occupant or owner. A4.5 ENVIRONMENTAL Fireplaces 4.503.1 General. Install only a direct -vent sealed -combustion gas or sealed ❑ ❑ wood -burning fireplace, or a sealed woodstove. Pollutant Control 4.504.1 Covering of duct openings and protection of mechanical equipment during construction. Duct openings and other related air ❑X ❑ distribution component openings shall be covered during construction. 4.504.2.1 Adhesives, sealants and caulks. Adhesives, sealants and caulks ❑ shall be compliant with VOC and other toxic compound limits. 4.504.2.2 Paints and coatings. Paints, stains and other coatings shall be ❑ compliant with VOC limits. 4.504.2.3 Aerosol paints and coatings. Aerosol paints and other coatings shall be compliant with product weighted MIR Limits for ROC and other toxic ❑X ❑ compounds. Page 3 of 5 CalGreen_2014.doc revised 01/15/14 4.504.2.4 Verification. Documentation shall be provided to verify that © ❑ compliant VOC limit finish materials have been used. 4.504.3 Carpet Systems. Carpet and carpet systems shall be compliant with ❑ ❑ VOC limits.- --- ----- -- - — -- 4.504.4 Resilient flooring systems. Eighty (80) percent of floor area receiving resilient flooring shall comply with the VOC-emission limits defined in the Collaborative for High Performance Schools (CHPS) Low -emitting ❑X ❑ Materials List or be certified under the Resilient Floor Covering Institute (RCFI) FloorScore program. 4.504.5 Composite wood products. Particleboard, medium density fiberboard (MDF), and hardwood plywood used in interior finish systems shall ❑X ❑ comply with low formaldehyde emission standards. Interior Moisture Control 4.505.2 Concrete slab foundation. Required vapor retarders and capillary ❑ ❑ breaks are also required to comply with CalGreen Section 4.505.2.1. 4.505.3 Moisture content of building materials. Moisture content of building ❑ ❑ materials used in wall and floor framing is checked before enclosure. Indoor Air Quality and Exhaust 4.506.1 Bathroom exhaust fans. Exhaust fans which terminate outside the ❑ ❑ building are provided in every bathroom. Environmental Comfort 4.507.2. Duct systems are sized and designed and equipment is selected using the following methods: 1. Establish heat loss and heat gain values according to ACCA Manual J or equivalent. ❑ ❑ 2. Size duct systems according to ACCA 29-D (Manual D) or equivalent. 3. Select heating and cooling equipment according to ACCA 36-S (Manual S) or equivalent. INSTALLER AND SPECIAL INSPECTOR QUALIFICATIONS Qualifications 702.1 Installer training. HVAC system installers are trained and certified in ❑ ❑ the proper installation of HVAC systems. 702.2 Special inspection. The Licensed Professional responsible to verify CALGreen compliance is qualified and able to demonstrate competence in the ❑X ❑ discipline they inspect and verify. Verifications 703.1 Documentation. Verification of compliance with CALGreen may include construction documents, plans, specifications, builder or installer certification, inspection reports, or other methods acceptable to the enforcing ❑ ❑ agency which show substantial conformance. Implementation verification shall be submitted to the Building Department after implementation of all required measures and prior to final inspection approval. Page 4 of 5 CalGreen_2014.doc revised 01/15/14 Project Name: Project Address: Project Description: CALGREEN SIGNATURE DECLARATIONS Chuang Residence- Addition & Remodel 7817 Lunar Court Addition & Remodel to Existing Single Story House SECTION 1 — DESIGN VERIFICATION Complete all lines of Section 1 — "Design Verification" and submit the completed checklist (Columns 1 and 2) with the plans and building permit application to the Building Department. The owner and design professional responsible for compliance with CalGreen Standards have revised the plans and certify that the items checked above are hereby incorporated into the project plans and will be implemented into the project in accordance with the requirements set forth in the 2013 California Green Building Standards Code as adopted by the City of Cupertino. Owner's Signature Owner's Name (Please P Design Professional's Signature Mike Ma Design eG►L�Vt C41eyt C?G a -at, P ri nt) Signature—of License Professional responsible f:�CalGreen compliance Name of License Professional responsible for CalGreen compliance (Please Print) 1rW �.ur , e.12✓s�d , .� q �,ns. _ e aM- Email Address for License Professi3 oval dresponsible for CalGreen compliance SECTION 2 — IMPLEMENTATION VERIFICATION q/q Date Date Cis)-c�t."t2 Phone Complete, sign and submit the competed checklist, including column 3, together with all original signatures on Section 2 to the Building Department prior to Building Department final inspection. I have inspected the work and have received sufficient documentation to verify and certify that the project identified above was constructed in accordance with this Green Building Checklist and in accordance with the requirements of the 2013 California Green Building Standards Code as adopted by the City of Cupertino. Signature of License Professional responsible for CalGreen compliance Date Name of License Professional responsible for CalGreen compliance (Please Print) Phone Email Address for License Professional responsible for CalGreen compliance Page 5 of 5 CalGreen_2014.doc revised 01/15/14 BUILDING ENERGY ANALYSIS REPORT PROJECT: A New Residence 7817 Lunar Ct. Cupertino, CA 95014 Project Designer: March design RECEIVED JUN 10 104 Report Prepared by: BY• JNB Associates Job Number: 2014-21 Date: 6/22/2014 '77! CUPERTINO I ! 2014 ,tr V1PAtE D 1-:0k Cr,)DE: COMPLIANCE t\4k�C:Ve LIi ley. �i.;- h4wl The EnergyPro computer program has been used to perform the calculations summarized in this compliance report. This program has approval and is authorized by the California Energy Commission for use with both the Residential and Nonresidential 2008 Building Energy Efficiency Standards. This program developed by EnergySoft, LLC —www.energysoft.com. EnergyPro 5.1 by EnergySoft User Number: 4066 RunCode: 2014-06-22T05:21:40 ID: 2014-21 I TABLE OF CONTENTS I Cover Page Table of Contents Form CF -1 R Certificate of Compliance 2 3 C'nrm RAF -:-AD AAnnAn+nrxi AAnnei mme Ci immnrw R PERFORMANCE CERTIFICATE: Residential Part 1 of 5 CF -1 R Project Name A New Residence Building Type m Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 6/22/2014 Project Address 7817 Lunar Ct. Cupertino California Energy Climate Zone CA Climate Zone 04 Total Cond. Floor Area 2,352 Addition n/a # of Stories 1 FIELD INSPECTION ENERGY CHECKLIST ❑ Yes ❑ No HERS Measures -- If Yes, A CF -4R must be provided per Part 2 of 5 of this form. ❑ Yes El No Special Features -- If Yes, see Part 2 of 5 of this form for details. INSULATION Area Special Construction Type Cavity (ft) Features (see Part 2 of 5) Status Roof Wood Framed Attic R-38 2,340 New Wall Wood Framed R-15 1,935 New Door Opaque Door None 24 New Floor Wood Framed w/Crawl Space R-19 2,352 New FENESTRATION U- Exterior Orientation Area(ft2) Factor SHGC Overhang Sidefins Shades Status Skylight 12.0 0.550 0.67 none none None New Front (SE) 94.0 0.390 0.37 none none Bug Screen New Left (SM 102.0 0.390 0.37 none none Bug Screen New Rear (NW) 115.0 0.390 0.37 none none Bug Screen New Right (NE) 68.0 0.390 0.37 none none Bug Screen New HVAC SYSTEMS Qty. Heating Min. Eff Cooling Min. Eff Thermostat Status 1 Central Furnace 93% AFUE Split Air Conditioner 13.0 SEER Setback New HVAC DISTRIBUTION Duct Location Heating Cooling Duct Location R -Value Status Res HVAC Ducted Ducted Crawlspace 8.0 New WATER HEATING Qty. Type Gallons Min. Eff Distribution Status 1 Instant Gas 0 0.82 No Pipe Insulation New EnergyPro 5.1 by Ener Soft User Number: 4066 RunCode: 2014-06-22705:21:40 ID: 2014-21 Page 3 of 12 PERFORMANCE CERTIFICATE: Residential (Part 2 of 5) CF -1 R Project Name A New Residence Building Type m Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 6/22/2014 SPECIAL FEATURES INSPECTION CHECKLIST The enforcement agency should pay special attention to the items specified in this checklist. These items require special written justification and documentation, and special verification to be used with the performance approach. The enforcement agency determines the adequacy of the justification, and may reject a building or design that otherwise complies based on the adequacy of the special justification and documentation submitted. HERS REQUIRED VERIFICATION Items in this section require field testing and/or verification by a certified HERS Rater. The inspector must receive a completed CF -4R form for each of the measures listed below for final to be given. Ener Pro 5.1 by Ener Soft User Number: 4066 RunCode: 2014-06-22T05:21:40 ID: 2014-21 Pa e 4 of 12 PERFORMANCE CERTIFICATE: Residential (Part 3 of 5) CF-1 R Project Name Building Type m Single Family ❑ Addition Alone Date A New Residence ❑ Multi Family ❑ Existing+ Addition/Alteration 6/22/2014 ANNUAL ENERGY USE SUMMARY Standard Proposed Margin TDV (kBtu/ft2-yr) Space Heating 23.21 16.00 7.21 Space Cooling 6.96 9.10 -2.14 Fans 4.63 4.79 -.0.16 Domestic Hot Water 17.31 13.84 3.47 Pumps 0.00 0.00 0.00 Totals 52.11 43.73 8.38 Percent Better Than Standard: 16.1 i BUILDING COMPLIES - NO HERS VERIFICATION REQUIRED Fenestration Building Front Orientation: (SE) 135 deg Ext. Walls/Roof Wall Area Area Number of Dwelling Units: 1.00 (SE) 608 94 Fuel Available at Site: Natural Gas (Sw) 561 102 Raised Floor Area: 2,352 (NO9 608 115 Slab on Grade Area: 0 (NE) 561 68 Average Ceiling Height: 8.5 Roof 2,352 12 Fenestration Average U-Factor: 0.39 TOTAL: 391 Average SHGC: 0.31 Fenestration/CFA Ratio: 16.6 REMARKS STATEMENT OF COMPLIANCE This certificate of compliance lists the building features and specifications needed to comply with Title 24, Parts 1 the Administrative Regulations and Part 6 the Efficiency Standards of the California Code of Regulations. The documentation author hereby certifies that the documentation is accurate and complete. Documentation Author Comoany JN8 Associates4 6/22/2014 I- Address Name City/State/ZipPhone Signed Date The individual with overall design responsibility hereby certifies that the proposed building design represented in this set of construction documents is consistent with the other compliance forms and worksheets, with the specifications, and with any other calculations submitted with this permit application, and recognizes that compliance using duct design, duct sealing, verification of refrigerant charge, insulation installation quality, and building envelope sealing require installer testi; g arid certification and field verification by an approved HERS rater. Designer or Owner (per Business & Professions Code) Company March design Address Name Z City/State/Zip Phone Signed License # Date Ener Pro .5.: bEner Soft User Number- 4066 RunCode: 2014-06-22705:21:40 ID: 2014-21 Page 5 of 12 CERTIFICATE OF COMPLIANCE: Residential (Part 4 of 5) CF -1 R Project Name A New Residence Building Type m Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 6/22/2014 OPAQUE SURFACE DETAILS Surface Type U- Insulation Joint Appendix Area Factor Cavity Exterior Frame Interior Frame Azm Tilt Status 4 Location/Comments Roof 2,340 0.025 R-38 0 22 New 4.2.1-A21 1 st Floor Zone Wall 490 0.095 R-15 135 90 New 4.3.1-A4 1st Floor Zone Door 24 0.500 None 135 90 New 4.5.1-A4 1st Floor Zone _ Wal. 4 5,C, i 0.095 r<-15 225 90 New 4.3.1-A4 1st Floor Zone Wall 4931 0.095 R-15 1 1 315 90 New 4.3.1-A4 1st Floor Zone Wall 493 0.095 R-15 45 90 New 4.3.1-A4 1st Floor Zone Floor 2,352 0.037 R-19 0 180 New 4.4.1-A4 1st Floor Zone I i I I ' FENESTRATION SURFACE DETAILS ID T e Area U -Factor SHGC2 Azm Status Glazing Type Location/Comments 1 ISkylight 12.0 0.550 Default 0.67 Default 0 New Double Non Metal Clear 1st Floor Zone 2 Window 94.0 0.390 NFRC 0.37 NFRC 135 New Milgard Classic Low -E Vinyl 1 st Floor Zone 3 Window 102.0 0.390 NFRC 0.37 NFRC 225 New Milgard Classic Low -E Vinyl 1st Floor Zone 4 Window 115.0 0.390 NFRC 0.37 NFRC 315 New Milgard Classic Low -E Vinyl 1st Floor Zone 5 Wincow 68.0 0.390 NFRC 0.37 NFRC 45 New Milgard Classic Low -E Vinyl 1 st Floor Zone i I (1) U -Factor Type: 116-A= Default Table from Standards, NFRC = Labeled Value (2) SHGC Type: 116-B = Default Table from Standards, NFRC = Labeled Value EXTERIOR SHADING DETAILS Window ID Exterior Shade Type SHGC H t Wd Ove hang Left Fin Right Fin Len H t LExt RExt Dist Len H t Dist Len H t 1 None 1.00 2 Bug Screen 0.76 3 Bug Screen 0.76 4 !Bug Screen 0.76 5 Bug Screen 0.76 I Ener Pro 5.1 by Ener Soft User Number: 4066 RunCode: 2014-06-22T05:21:40 ID: 2014-21 Page 6 of 12 CERTIFICATE OF COMPLIANCE: Residential (Part 5 of 5) CF -1 R Project Name A New Residence Building Type © Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 6/22/2014 BUILDING ZONE INFORMATION System Name Zone Name Floor Area ft New Existing Altered Removed Volume Year Built Res HVAC 1st Floor 2,352 19,992 I I I Totals 1 2,352 0 0 0 HVAC SYSTEMS System Name Qty. Heating Type Min. Eff. Cooling Type Min. Eff. Thermostat Type Status Res HVAC 1 Central Furnace 93% AFUE Split Air Conditioner 13.0 SEER Setback New HVAC EXETRIBUTION System NameHeatin Duct Coolin Duct Location R -Value Ducts Tested? Status Res HVAC Ducted Ducted Crawlspace 8.0 ❑ New -- ❑ WATER HEATING SYSTEMS Sy ,_iem Name Qty. Type Distribution Rated Input Btuh Tank Cap. al Energy Factor or RE Standby Loss or Pilot Ext. Tank Insul. R - Value Status Takagi T-114199 1 Instant Gas No Pipe Insulation 199,000 0 0.82 n/a n/a New MULTI -FAMILY WATER HEATING DETAILS HYDRONIC HEATING SYSTEM PIPING a Control Hot Water Piping Length ft 0 .C's Q System Name Pipe Length Pipe Diameter Insul. Thick. Qt . HP Plenum Outside Buried ❑ EnergyPro 5.1 by EnergySoft User Number., 4066 RunCode: 2014-06-22Tr05:21:40 ID: 2014-21 Page 7 of 12 MANDATORY MEASURES SUMMARY: Residential Pae 1 of 3 MF -1 R Project Name Date A New Residence 6/22/2014 NOTE: Low-rise residential buildings subject to the Standards must comply with all applicable mandatory measures listed, regardless of the compliance approach used. More stringent energy measures listed on the Certificate of Compliance (CF -1 R, CF -1 R -ADD, or CF - 1 R -ALT Form) shall supersede the items marked with an asterisk (*) below. This Mandatory Measures Summary shall be incorporated into the permit documents, and the applicable features shall be considered by all parties as minimum component performance specifications whether they are shown elsewhere in the documents or in this summary. Submit all applicable sections of the MF -1 R Form with plans. BuNclnd ►=nv�It;pE� M ;ast1 es: 116(a)!: Doors and windows between conditioned and unconditioned spaces are manufactured to limit air leakage. §116(".)4: t=er,estration products (except field -fabricated windows) have a label listing the certified U -Factor, certified Solar Heat Gain Coefficient L5r-i!ac,1, and infiltration that meets the requirements of 10 11 i�a� 117: Exter:cr doors and windows are weather-stripped; all joints and penetrations are caulked and sealed. 118(ay._Insulation specified or installed meets Standards for Insulating Material. Indicate type and include on CF -6R Form. §118(1): 1`he thermal emittance and solar reflectance values of the cool roofing material meets the requirements of §118(1) when the installation of a Cool Roof is specified on the CF -1 R Form. *§1 `=0(a.,- iv!rimum a-' 9 insulation in wood -frame ceiling or equivalent U -factor. §15QLb.: Loose fill insulation shall conform with manufacturer's installed design labeled R -Value. *§150(c): Minimum R-13 insulation in wood -frame wall or equivalent U -factor. *§151i d`: I\,inimum R-13 insulation in raised wood -frame floor or equivalent U -factor. 150(f): Air retardingwcap is tested, labeled, and installed according to ASTM E1677-95 2000 when specified on the CF -1 R Form. 150 : 'Mandatory Vapor barrier installed in Climate Zones 14 or 16. §150(I):Water absorption rate fcr slab edge insulation material alone without facings is no greater than 0.3%; water vapor permeance rate is no greater than 2.0 perm/inch and shall be protected from physical damage and UV light deterioration. Fire +laver , Decorative Gas Appliances and Gas Log Measures: 156; 1 '. P Iasonry or factor --built fire laces have a closable metal or giass door covering the entire opening of the firebox. §150(e)1 B- Masonry or factory -built fireplaces have a combustion outside air intake, which is at least six square inches in area and is e uipped inrith a with a readil�ccessible, operable, and tiq_ht-fitting dammer and or a combustion -air control device. §150(e)2: s ontinuous burning pilot lights and the use of indoor air for cooling a firebox jacket, when that indoor air is vented to the outside of ,hu bui;d;,^g, are prohibited. Space CundlConing, Water Beating and Plumbing System Measures: §110-§1' 3: I-IVAC equipment, Neater heaters, showerheads, faucets and all other regulated appliances are certified by the Energy Commission,. §113(r'S' r- =te- he71i-g mci�-rt:'a-tion loops serving mu!tip'e dirveilin:C, ur:its and High -Rise residential occupancies meet the air release valve, backthow prevention, pump isolation valve, and recirculation loo connection requirements of §113(c)5. §115: Co-77 ntinuously burning pilot iights are prohibited for natural gas: fan -type central furnaces, household cooking appliances (appliances with an electrical supply voltage connection with pilot lights thai consume less than 150 Btu/hr are exempt), and pool and s a naaterr•. 150(hZ Hestinc. and/or cooling loads are calculated in accordance with ASHRAE, SMACNA or RCCA. 15^(i): H° at*ng systems are eqL i;Dped with tl-ermostats that meet the eetback requirements of Section 112(c). §'50(P'.1A. St:.ir7 ge gas %.iter heaters rated with an Energy, Factor no greater than the federal minimal standard are externally wrapped with insula!;_on having an installed thermal resistance of R-12 or greater. §150(i)13: ' ln`ired storage tanks, such as storage Larks or backup tanks for solar water -heating system, or other indirect hot water tanks have R-12 exierral insulation or R-16 internal insulation where the internal insulation R -value is indicated on the exterior of the tang. _ §155(j)2: '=`rs'- 5 fact of I,ot and -cold water pipes closest to water heater tank, non -recirculating systems, and entire length of recirculatin-I sections of hot water pipes are insulated per Standards Table 150-B. §1500i2: Cooling system piping (suction, chilled water, or brine lines),a.nd piping insulated between heating source and indirect hot water tank shall oe ;nsulated to ,-able 150-B and Equation 150-A. §',I:OT2: Fi,,X :nsula.ion for :steam. hvdronic 'neating systerns or t.ot wa;e; systems >15 psi, meets the requirements of Standards Table 123 .I�. 150!;?3. `.: i �sulation is protected from damage, including that due to sunlight, moisture, equipment maintenance, and wind. §15 r;�'�3,y nsulat;on for chiiied water piping and refrigerant suction lines includes a vapor retardant or is enclosed entirely in conditioned space. '.5 "`»: Ro'^.r wafer heating systems and/or collectors are certified by the Solar Rating and Certification Corporation. Er,,- g;P c y 1 by EnergySoft-- User Number: 4066 _.�- R+#rGocle: 2014-06-22705:21:40 ID: 2014-21 Page 8 of 12 MANDATORY MEASURES SUMMARY: Residential (Page 2 of 3 MF -1 R Project Name Date A New Residence 6/22/2014 §150(m)l : All air -distribution system ducts and plenums installed, are sealed and insulated to meet the requirements of CMC Sections 601, 602, 603, 604, 605 and Standard 6-5; supply -air and return -air ducts and plenums are insulated to a minimum installed level of R- 4.2 or enclosed entirely in conditioned space. Openings shall be sealed with mastic, tape or other duct -closure system that meets the applicable requirements of UL 181, UL 181 A, or UL 181 B or aerosol sealant that meets the requirements of UL 723. If mastic or tape is used fo seai oo(Linesgregter than 1/4 inch, the combination of mastic and either mesh or tape shall be used §15u( T.) .: oa,lol.ny o&vitiea, 3uppor: platforms iw ail and plenums defined or constructed with materials other than sealed sheet mea', duct board or flexible duct shall not be used for conveying conditioned air. Building cavities and support platforms may contain dkicts. Ducts installed in cavities and support platforms shall not be compressed to cause reductions in the cross-sectional area of the dui;ib. §150(m)2D: Joints and seams of duct systems and their components shall not be sealed with cloth back rubber adhesive duct tapes unless such tape is used in combination with mastic and draw bands. 150(m)7: Exhaust fan systems have back draft or automatic dampers._ §150(m)8: Gravity ventilating systems serving conditioned space have either automatic or readily accessible, manually operated dampers.___ §' 50(ir.)9- Insulation shall be protected from damage, including that due to sunlight, moisture, equipment maintenance, and wind. Cellular foam insulation shall be protected as above or painted with a coating that is water retardant and provides shielding from solar radiation tnat can cause degradation of the material. 150,(rr.)10: Flexible ducts cannot have porous inner cores. §150(0): All dwelling units shall meet the requirements of ANSI/ASHRA.E Standard 62.2-2007 Ventilation and Acceptable Indoor Air Quality in Low -Rise Residential Buildings. Window operation is not a permissible method of providing the Whole Building Ventilation required in Section 4 of that Standard. Pa l an::d Sea Heating Systems and Equipment Meast.ires: §114(8): Any pool or spa heating system shall be certified to have: a thermal efficiency that complies with the Appliance Efficiency Regulations; an cm -off switch mounted outside of the heater; a permanent weatherproof plate or card with operating instructions; and shall not Use electric resistance heating or a pilot light. §1 14;b) ! : Any pool or spa heating equipment shall be installed with at least 36" of pipe between filter and heater, or dedicated suction and return lines, or built-up connections for future solar heating. 1 .4(b)2: OGtdoor pools or spas that have a heat pump or gas heater shall have a cover. §114(b)3: Pools shall have directional inlets that adequately m"x the pool water, and a time switch that will allow all pumps to be set or regran_ime to run only duri,no off -beak electric demand periods._ !:tEc;dantia1 poo sv to= ns or eq iie„gent meet the E;: sizing, flow rate, piRing, filters, and valve requirements of 150 Residential Lighting Measures: §-i 50(k)1: High efficacy luminaires or LED Light Ergine with Integral Heat Sink has an efficacy that is no lower than the efficacies contained in Table 150-C and is nota iow efficacy luminaire asspecified by §150(k)2. i 5UjKa. -i he wattage of permanently installed luminaires shall be determined asspecified by §130(d). §150{(k)4: Baliasts for fluorescent lamps rated 13 Watts or greater shall be electronic and shall have an output frequency no less than 20 kAz• §-. 50,!K)5: Pet'manently installed night lights and night lights integral to a per:-nanently installed luminaire or exhaust fan shall contain only hi•gin of! cacy !amps meeting the minimum efficacies contained in Table 150-C and shall not contain a line -voltage socket or line - voltage I2me holder; OR shall be rated to consume no more than five wafts of power as determined by §130(d), and shall not contain a madiu�rs��aJr-t.as� sucKei. lting integral tc exhaust fans, in rooms other than kitchens, shall meet the applicable requirementsof §150(k). 150(k)7: AllswitcNnq devices and controls shall meet the requirements of §150(k)7. §150(u)8: A minimum of 50 percent of the total rated waftage of permanently installed lighting in kitchens shall be high efficacy. EXt ;EPI i0N: Un to 50 watts for dwelling units less than or equal to 2,500 ft2 or 100 watts for dwelling units larger than 2,500 ft2 may be exempt from the 50% high efficacy requirement when: all low efficacy luminaires in the kitchen are controlled by a manual on occupant sensor, dir, mer, energy maragement system ('FMCS), ora multi -scene programmable control system; and all permanently installed luminaries in garages, laundry rooms, closets greater than 70 square feet, and utility rooms are high efficacy and controlled by a manual -on occu ant sensor._ §150(k)9: Permanently installed lighting that is internal to cabinets shall use no more than 20 watts of power per linear foot of illuminated cabinet. tEeryyP: 0 5.1 by i=reryy5a, t R User Nurnoer: 4000 �.� RunCade: 2074-06-22M:21:40 !D: 2014-21 Page 9 of 12 MANDATORY MEASURES SUMMARY: Residential (Page 3 of 3 MF -1 R Project Name Date A New Residence 6/22/2014 §150(k)10: Permanently installed luminaires in bathrooms, attached and detached garages, laundry rooms, closets and utility rooms shall be high efficacy. EXCEPTION 1: Permanently installed low efficacy luminaires shall be allowed provided that they are controlled by a manual -on occupant sensor certified to comply with the applicable requirements of §119. EXC,,EP T i&N %: Permanentiy insiaiied iow efficacy luminaires in ciosets less than 70 square feet are not required to be controlled by a §150(k)11: Permanently installed luminaires located in rooms or areas other than in kitchens, bathrooms, garages, laundry rooms, clr:s;ets, and utility rooms shall be high efficacy luimnaires. EXCEPTION 1: Permanently installed low efficacy luminaires shall be alluv✓cJ pioviued They ar6 6ontro:1ed by either a dimmer switch that coi-npfias with the applicable requirements of §119, or by a manual - on occupant sensor that complies with the applicable requirements of §119. EXCEPTION 2: Lighting in detached storage building less than 1800 sq: faa feet located on a residential site is not required to cornply with §150 k 11. §150(k)12: Lu ,,inaires recessed into insulated ceilings shall be listed for zero clearance insulation contact (IC) by Underwriters Laboratories or other nationally recognized testing/rating laboratory; and have a label that certifies the lumiunaire is airtight with air leakagD ess then 2.0 CFM at 75 Pascals when tested in accordance with ASTM E283; and be sealed with a gasket or caulk between tha lurninaue housing and ceiling. _ §1 501k)13: Luminaires providing outdoor lighting, including lighting for private patios in low-rise residential buildings with four or more dwelling units, entrances, balconies, and porches, which are permanently mounted to a residential building or to other buildings on the sarne !ot shall be high efficacy. EXCEPTION 1: Permanently installed outdoor low efficacy luminaires shall be allowed provided that they are controlled by a manual on/off switch, a motion sensor not having an override or bypass switch that disables the motion sensor, and one of the following controfs: a photocontrol not having an override or bypass switch that disables the photocontrol; OR an astron,-mical time :lock not' -saving an override or bypass s/itch that disables the astronomical time clock; OR an energy management corIrcl syste^: 'E°.fCS) not having an override or bypass switch that allows the luminaire to be always on EXCEPTION 2: Outdoor lun•iinaires used `c. cornply with Exceptloni to §150;k`,13 may be controlled by a temporary override switch which bypasses the motion sensing funct' -c p ovided that the motion sensor is automaticaVy reactivated within six hours. EXCEPTION 3: Permanently installed lurninairev ir: or around swimming pool, water features, or other location subject to Article 680 of the California Electric Code need not be `sigh ffit:acy h,�,inaires. §15W',11,1_: 'nternally °lluminated address signs shall comply with Section 148; OR not contain a screw -base socket, and consume no more than five watts of power as determined according to §130(d). §1 E 1 ' ;15• Lig! iting for parking lots and carports with a tota' of for 8 or more vehicles per site shall comply with the applicable req, , ,i, its in Sections 130, 132; 134, and 147. Lighting for parking garages for 8 or more vehicles shall comply with the applicable re: Ll'._ t+ ?'. Sections '30, 131, 134, and 14.6. §1 s_ 'ern. ,entiy installed lighting in the enclosed, non. -dwelling spaces of low-rise residential buildings with four or more dwc'.;::y L [,.t3 ,hail be high efficacy luminaires. -EXCEPTION: Permanently installed low efficacy luminaires shall be allowed provided that they are ucntrolled by an occupant sensors certified to comply with the applicable requirements of 119. EnergyPro 5.1 by EnergySoff User Number: 4066 RunCode: 2014-06-22705:21:40 ID: 2014-21 Page 10 of 12 ENERGY USE AND COST SUMMARY._._.____-_____ ECON-1 Project Name Date A New Residence 6/22/2014 Rate: Electric Alameda H Fuel Type: Electricity STANDARD PROPOSED MARGIN Energy Peak Energy Peak Energy Peak Use Demand Cost Use Demand Cost Use Demand Cost kWh (kW) ($) kWh) (kW) ($) (kWh) (kW) $) 105 1 16 18 0 2 ----- 1=eb � ----- 61 1 ------13 1---- 69 2 12 13 0 1 MIar 64 2 12 54 3 11 9 0 1 Apr 79 3 13 77 3 13 2 0 0 May 38 '11 9 60 ` 11 -22 -1 -2 Jun 133 , 6 19 199 6 251, -66 0 -7 Jul 170 5 22 - 241 5 30 - - -71 0 -7 Aura - - 207 -----61 26 2551 6 31 -•49 0 -5 Ser, 118 71 17 :1 128 ! 7 18 , -10 1 -1 0ct50 5 10 1 46 4 10 3 0 0 Nov_ - 75 j 1 13 1 631 1 11 12 0 1 Dec _!-- 121- 1 17 1021 _1 16 1 18 0 2 Year 1.2.58 ------- -7 189 40 ; 7 204 jj -142 1 -15 1,012 Ibs!yr 1,127 ; lbs/yr -115 lbs/yr r., Rate: Gas PG&E P Fuel Type: Natural Gas STANDARDPROPOSED MARGIN Energy Peak Energy ir Peak Energy Peak Use Demand Cost Use Demand Cost Use Demand Cost (therms) (kBtu/hq $ _11 (therms) _ (kBtu/hr} _ ($) (therms (kBtu/hr) ($ -110 76 147 - i - —_ 65 04 29 13 43 Feb 74 i 66 95 54 56 1-- 67----- - 20 �.-- -- 90 27 r 62 63 77 451 53 56 ' 17 9 22 bier 5? I 5465 37 47 46 1 15 8 19 Mi% 25134 34 — �., 26 5 6 8 Jun - 23 34 30 18 22 23 5 12 7 Jul 23 6 30 ' 18 ; 6 23 5 0 7 Auu_ 22 6 ! 29 -17 6 { 22 5 0 7 Ser,21 6 i 28 17 ; 6 i 21 5 0 7 Oct � 28' 49� 37 21 42 28 6 7 9 140V 73 69i� X94 .53 i 58 6_5_�20 11 28 Dec -- 108 ---78 45 78 s44 101 30 E 14 44 ---_--------- -- i, Year 621 781 811_-- - 458, 64 582 -- 163 14 229 CC = 7,208 i Ibs/yr !_ 5,358 i lbs/yr 1,910 lbs/yr Anrwuiil Totals Energy _Demand Cost cost/sgft Virtual Rate t=lectricity __ 1,400 kNih 7 kW $ 204 $ 0.09 /sqft $ 0.15 /kWh - iVaturai Gas I 458 therms -- 64 kBtu/hr $ - 582 $ _ 0.25 /sgft _� $ 1.27 /therm __ Total 786 $ -- 0.33 /Sgft-J Avoided COL E miss!ons: 1,795 lbs/yr EnergyPro 5.1 by Energy Soft User Number: 4066 RunCode. 2014-06-22T05:21.4 ID: :1014-21 Page 11 of 12 UTILITY INCENTIVE WORKSHEET UTIL-1 R Project Name Date A New Residence 6/22/2014 • ANNUAL TDV ENERGY USE (kBtu/sqft-yr) PERCENT BELOW TITLE 24 ENERGY COMPONENT Standard Proposed Margin Margin Standard % Better* Space Heating 23.21 16.00 7.21 8.38 / 52.11 = 16.1% Space Cooling 6.96 9.10 -2.14 Cooling Standard H att REj6CtF�C _ C. 001 i ^.0000 0.00 2.14 / 6.96 = __-30.8 4.83 4.7y' _ -0. i6 Indoor Fans I Incentive Eligibility 9� Y Yes No Dorr;estic Hot Water 17.31 13.84 3.47 Owner Incentive (>=15%) 10 ❑ 1 1111 P �� 70. 0.00 i .tive �P I�cer(>-30%) ❑ ❑ Conditioned Floor Area = 2,352.0 ftz TOTALS: 52.11 _ 4.3.73 8.38 Number of Bedrooms = 1 Energy Star V3Target = _-. 31% ANNUAL SITE ENERGY USE Averagc 2Fm - 5pm Standard Proposed margin Peak Demand (M) 1 3.9 1 4.3 1 -0.4 Single Orientation Standard Prop,,3se.i _ _ Margin -- _ • 'ONENT - -- -- - - Electricity � Natural Gas Electricity Natural Gass Electricity Natural Gas (kWh)_ (therms) (kWh) (therms) (kWl-.) (therms) _ ! _ Space Pleating 0.03 346.77 0.00 238.70 0.00 108.07 Space Cooling - -557.4 _-_-_ 0.00 I _ 735.61 -0_00 � 178.17 0.00 0.0�' 0.00 I 0.00 I 0.00 0.00 0.00 Indoor } an s 700.29 C.00 66n.51 0.00 _ 35.78.-0.00 Dornestiln Hot Water 0.00 274.42 0.00 219.24 0.00 55.18 Pumps 0.00 0.00 0.00 0.00 0.00 0.00 7OIALS: 125%.73 621.79 1.406.12 J- 457.94 .142.39 - 163.25 • . POTENTIAL OWNER INCENTIVE CALCULATION - Potential incentives indicatea % Better than Title -24* Incentive savings On i;. ?r rt are available (from step 2) California Piectricity (kWh)l 16.1 / Rate (frost Step 3) Subtotal o.as� x 10.00 = $o of iiy t„. trie Advan *J Homes Program for $/kwh kwh new construction. and are Electricity (kW) 16.1 � �*� �o X1 0.0 = $o NOT GUARANTEED. Projects $/kW kW must meet ail other prograr,, (�i�tural Gas 1•i 1 � 1.85 X 163 25 $302 rart,tirami_t antR to �aijfy, p,%rc. -�iVeS dee to limitations $/therm therm � $302 subject program Base Incentive = } ai. Jiit* �uiuj, Energy star Incentive X ? 0/ ,,,p 0 = i n/a rl-vabri"', Company C; rPen Home Incentive We j x 100%0 50tAM-NN CA1,-11FOR tIA '", O k Compact Horne incentive n e x 15% r Pnotovoltaic'v�s�o x 2.0� $160 C RngkWsDi ITEM ) Sernpi a Energy utiliity' N SIH P a Total ted „CTMKpmy c �*tayli Jl xc 11) `% Better than in this equation is limited to 45% EnergyPrt� 5.1.7.3 by EnergySoft User Number. 4066 Zu,.,Llodv= 2014-16-=05:21:40 ID: 20`4-21 _ Page 12 of 12 BUILDING ENERGY ANALYSIS REPORT PROJECT: A New Residence 7817 Lunar Ct. Cupertino, CA 95014 Project Designer: CUI'ERTINO March desi Wlidif,,g Department 1 JAN 15 20 REVIEWED FOR CODE COMPLIANCE Reviewed By: j� h4w Report Prepared by: REVISION�F._y _ _ DATE JNB Associates Job Number: 2014-21 Date: 12/8/2014 The EnergyPro computer program has been used to perform the calculations summarized in this compliance report. This program has approval and is authorized by the California Energy Commission for use with both the Residential and Nonresidential 2008 Building Energy Efficiency Standards. This program developed by EnergySoft, LLC — www.energysoft.com. EnergyPro 5.1 by EnergySoft User Number: 4066 RunCode: 2014-12-08T17:38:53 ID: 2014-21 I TABLE OF CONTENTS I Cover Page 1 Table of Contents 2 Form CF -1 R Certificate of Compliance 3 Form MF -1 R Mandatory Measures Summary 8 Form ECON-1 Energy Use and Cost Summary 11 Form UTIL-1 R Utility Incentive Worksheet 12 EnergyPr.5.1 by EnergySoft Job Number: ID: 2014-21 User Number: 4066 PERFORMANCE CERTIFICATE: Residential Part 1 of 5 CF -1 R Project Name A New Residence Building Type m Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 12/8/2014 Project Address 7817 Lunar Ct. Cupertino California Energy Climate Zone CA Climate Zone 04 Total Cond. Floor Area 2,441 Addition n/a # of Stories 1 FIELD INSPECTION ENERGY CHECKLIST ❑ Yes ❑ No HERS Measures -- If Yes, A CF -4R must be provided per Part 2 of 5 of this form. ❑ Yes ❑ No Special Features -- If Yes, see Part 2 of 5 of this form for details. INSULATION Area Special Construction Type Cavity (fl Features (see Part 2 of 5) Status Roof Wood Framed Attic R-30 2,344 New Wall Wood Framed R-15 1,944 New Door Opaque Door None 24 New Floor Wood Framed w/Crawl Space R-19 2,441 New FENESTRATION U- Exterior Orientation Area(ft2) Factor SHGC Overhang Sidefins Shades Status Skylight 8.0 0.550 0.67 none none None New Front (SE) 94.0 0.390 0.37 none none Bug Screen New Left (SIAL 56.0 0.390 0.37 none none Bug Screen New Rear (NM 152.0 0.390 0.37 none none Bug Screen New Right (NE) 68.0 0.390 0.37 none none Bug Screen New HVAC SYSTEMS Ot . Heating Min. Eff Cooling Min. Eff Thermostat Status 1 Central Furnace 93% AFUE Split Air Conditioner 13.0 SEER Setback New HVAC DISTRIBUTION Duct Location Heating Cooling Duct Location R -Value Status Res HVAC Ducted Ducted Crawlspace 8.0 New WATER HEATING Ot . Type Gallons Min. Eff Distribution Status 1 Instant Gas 0 0.82 No Pipe Insulation New EnergyPro 5.1 by EnergySoft User Number: 4066 RunCode: 2014-12-08717:38:53 ID: 2014-21 Page 3 of 12 PERFORMANCE CERTIFICATE: Residential (Part 2 of 5) CF -1 R Project Name A New Residence Building Type m Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 12/8/2014 SPECIAL FEATURES INSPECTION CHECKLIST The enforcement agency should pay special attention to the items specified in this checklist. These items require special written justification and documentation, and special verification to be used with the performance approach. The enforcement agency determines the adequacy of the justification, and may reject a building or design that otherwise complies based on the adequacy of the special justification and documentation submitted. HERS REQUIRED VERIFICATION Items in this section require field testing and/or verification by a certified HERS Rater. The inspector must receive a completed CF -4R form for each of the measures listed below for final to be given. Ener Pro 5.1 by Ener Soft User Number: 4066 RunCode: 2014-12-08717:38:53 ID: 2014-21 Pa e 4 of 12 PERFORMANCE CERTIFICATE: Residential (Part 3 of 5) CF -1 R Project Name Building Type ❑ Single Family ❑ Addition Alone Date A New Residence ❑ Multi Family ❑ Existing+ Addition/Alteration 12/8/2014 ANNUAL ENERGY USE SUMMARY Standard Proposed Margin TDV (kBtu/V- r) Space Heating 22.67 16.25 6.42 Space Cooling 6.28 8.02 -1.75 Fans 4.40 4.54 -0.14 Domestic Hot Water 17.01 13.73 3.28 Pumps 0.00 0.00 0.00 Totals 50.36 42.55 7.81 Percent Better Than Standard: 15.5% BUILDING COMPLIES - NO HERS VERIFICATION REQUIRED Fenestration Building Front Orientation: (SE) 135 deg Ext. Walls/Roof Wall Area Area Number of Dwelling Units: 1.00 (SE) 608 94 Fuel Available at Site: Natural Gas (SM 561 56 Raised Floor Area: 2,441 (NM 608 152 Slab on Grade Area: 0 (NE) 561 68 Average Ceiling Height: 9.0 Roof 2,352 8 Fenestration Average U -Factor: 0.39 TOTAL: 378 Average SHGC: 0.37 Fenestration/CFA Ratio: 15.5 REMARKS STATEMENT OF COMPLIANCE This certificate of compliance lists the building features and specifications needed to comply with Title 24, Parts 1 the Administrative Regulations and Part 6 the Efficiency Standards of the California Code of Regulations. The documentation author hereby certifies that the documentation is accurate and complete. Documentation Author Company JNB Associates 1218/2014 Address Name / City/State/ZipCity/State/Zip Phone Signed Date The individual with overall design responsibility hereby certifies that the proposed building design represented in this set of construction documents is consistent with the other compliance forms and worksheets, with the specifications, and with any other calculations submitted with this permit application, and recognizes that compliance using duct design, duct sealing, verification of refrigerant charge, insulation installation quality, and building envelope sealing require installer testing and certification and field verification by an approved HERS rater. Designer or Owner (per Business & Professions Code) Company March design Address Name 'i City/State/Zip Phone Signed License # Date Ener Pro 5.1 by Ener Soft User Number: 4066 RunCode: 2014-12-08T17:38:53 ID: 2014-21 Pae 5 of 12 CERTIFICATE OF COMPLIANCE: Residential (Part 4 of 5) CF -1 R Project Name A New Residence Building Type m Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 12/8/2014 OPAQUE SURFACE DETAILS Surface U- Insulation Joint Appendix Type Area Factor Cavity Exterior Frame Interior Frame Azm Tilt Status 4 Location/Comments Roof 2,344 0.031 R-30 0 22 New 4.2.1-A20 1st Floor Zone Wall 490 0.095 R-15 135 90 New 4.3.1-A4 1st Floor Zone Door 24 0.500 None 135 90 New 4.5.1-A4 1st Floor Zone Wall 505 0.095 R-15 225 90 New 4.3.1-A4 1st Floor Zone Wall 4561 0.095 R-15 1 1 315 90 New 4.3.1-A4 1st Floor Zone Wall 493 0.095 R-15 45 90 New 4.3.1-A4 1st Floor Zone Floor 2,441 0.037 R-19 0 180 New 4.4.1-A4 1st Floor Zone FENESTRATION SURFACE DETAILS ID Type Area U -Factor SHGCL Azm Status Glazing Type Location/Comments 1 Skylight 8.0 0.550 1 Default 0.67 Default 0 New Double Non Metal Clear 1st Floor Zone 2 Window 94.0 0.390 NFRC 0.37 NFRC 135 New Milgard Classic Low -E Vinyl 1st Floor Zone 3 Window 56.0 0.390 NFRC 0.37 NFRC 225 New Milgard Classic Low -E Vinyl 1st Floor Zone 4 Window 152.0 0.390 NFRC 0.37 NFRC 315 New Milgard Classic Low -E Vinyl 1st Floor Zone 5 Window 68.0 0.390 NFRC 0.37 NFRC 45 New Milgard Classic Low -E Vinyl 1st Floor Zone (1) J -Factor Type: 116-A = Default Table from Standards, NFRC = Labeled Value (2) SHGC Type: 116-B = Default Table from Standards, NFRC = Labeled Value EXTERIOR SHADING DETAILS Window ID Exterior Shade Type SHGC HIM Wd Ove hang Left Fin Right Fin Len H t LExt REA Dist Len H t Dist Len H t 1 None 1.00 2 Bug Screen 0.76 3 Bug Screen 0.76 4 Bug Screen 0.76 5 JBug Screen 0.76 Ener Pro 5.1 by Ener Soft User Number: 4066 RunCode: 2014-12-08T17:38:53 ID: 2014-21 Page 6 of 12 CERTIFICATE OF COMPLIANCE: Residential (Part 5 of 5) CF -1 R Project Name A New Residence Building Type © Single Family ❑ Addition Alone ❑ Multi Family ❑ Existing+ Addition/Alteration Date 12/8/2014 BUILDING ZONE INFORMATION System Name Zone Name Floor Area ft New Existing Altered Removed Volume Year Built Res HVAC 1st Floor 2,441 21,969 Totals 2,4411 01 01 0 HVAC SYSTEMS System Name Qty. I Heating Type Min. Eff. Cooling Type Min. Eff. Thermostat Type Status Res HVAC 1 Central Furnace 93% AFUE Split Air Conditioner 13.0 SEER Setback New HVAC DISTRIBUTION System Name Heating Duct Coolin Duct Location R -Value Ducts Tested? Status Res HVAC Ducted Ducted Crawlspace 8.0 ❑ New WATER HEATING SYSTEMS S stem Name Qty. Type Distribution Rated Input Btuh Tank Cap. al Energy Factor or RE Standby Loss or Pilot Ext. Tank Insul. R- Value Status Takagi T -M199 1 Instant Gas No Pipe Insulation 199,000 0 0.82 n/a n/a New MULTI -FAMILY WATER HEATING DETAILS HYDRONIC HEATING SYSTEM PIPING Control Hot Water Piping Length ft 75o n a S stem Name Pipe Len th Pipe Diameter Insul. I Thick. Qty. HP Plenum Outside Buried EnergyPro 5.1 by EnergySoft User Number. 4066 RunCode: 2014-12-08717:38:53 ID: 2014-21 Page 7 of 12 MANDATORY MEASURES SUMMARY: Residential Pae 1 of 3 MF -1 R Project Name A New Residence Date 12/8/2014 NOTE: Low-rise residential buildings subject to the Standards must comply with all applicable mandatory measures listed, regardless of the compliance approach used. More stringent energy measures listed on the Certificate of Compliance (CF -1 R, CF -1 R -ADD, or CF - 1 R -ALT Form) shall supersede the items marked with an asterisk (*) below. This Mandatory Measures Summary shall be incorporated into the permit documents, and the applicable features shall be considered by all parties as minimum component performance specifications whether they are shown elsewhere in the documents or in this summary. Submit all applicable sections of the MF -1 R Form with plans. Building Envelope Measures: 116(a)l: Doors and windows between conditioned and unconditioned spaces are manufactured to limit air leakage. §116(a)4: Fenestration products (except field -fabricated windows) have a label listing the certified U -Factor, certified Solar Heat Gain Coefficient SHGC , and infiltration that meets the requirements of 10-111 (a). 117: Exterior doors and windows are weather-stripped; all joints and penetrations are caulked and sealed. 118(a): Insulationspecified or installed meets Standards for Insulating Material. Indicate type and include on CF -6R Form. §118(i): The thermal emittance and solar reflectance values of the cool roofing material meets the requirements of §118(i) when the installation of a Cool Roof is specified on the CF -1 R Form. *§150(a): Minimum R-19 insulation in wood -frame ceiling or equivalent U -factor. §150(b): Loose fill insulation shall conform with manufacturer's installed design labeled R -Value. *§150(c): Minimum R-13 insulation in wood -frame wall orequivalent U -factor. *§150(d): Minimum R-13 insulation in raised wood -frame floor or equivalent U -factor. 150(f): Air retarding wrap is tested, labeled, and installed according to ASTM E1677-95 2000 when specified on the CF -1 R Form. 150 : Mandatory Vapor barrier installed in Climate Zones 14 or 16. §150(1): Water absorption rate for slab edge insulation material alone without facings is no greater than 0.3%; water vapor permeance rate is no greater than 2.0perm/inch and shall be protected from physical damage and UV light deterioration. Fireplaces, Decorative Gas Appliances and Gas Log Measures: 150 e 1 A: Masonry or factory -built fireplaces have a closable metal or glass door covering the entire opening of the firebox. §150(e)1 B: Masonry or factory -built fireplaces have a combustion outside air intake, which is at least six square inches in area and is equipped with a with a readily accessible, operable, and tight -fitting damper and or a combustion -air control device. §150(e)2: Continuous burning pilot lights and the use of indoor air for cooling a firebox jacket, when that indoor air is vented to the outside of the building, are prohibited. Space Conditioning, Water Heating and Plumbing System Measures: §110-§113: HVAC equipment, water heaters, showerheads, faucets and all other regulated appliances are certified by the Energy Commission. §113(c)5: Water heating recirculation loops serving multiple dwelling units and High -Rise residential occupancies meet the air release valve, backflow prevention, pump isolation valve, and recirculation loop connection requirements of §113(c)5. §115: Continuously burning pilot lights are prohibited for natural gas: fan -type central furnaces, household cooking appliances (appliances with an electrical supply voltage connection with pilot lights that consume less than 150 Btu/hr are exempt), and pool and spa heaters. 150(h): Heating and/or cooling loads are calculated in accordance with ASHRAE, SMACNA or ACCA. 150(i): Heating systems are equipped with thermostats that meet the setback requirements of Section 112(c). §150(j)1A: Storage gas water heaters rated with an Energy Factor no greater than the federal minimal standard are externally wrapped with insulation having an installed thermal resistance of R-12 or greater. §150(j)1 B: Unfired storage tanks, such as storage tanks or backup tanks for solar water -heating system, or other indirect hot water tanks have R-12 external insulation or R-16 internal insulation where the internal insulation R -value is indicated on the exterior of the tank. §150(j)2: First 5 feet of hot and cold water pipes closest to water heater tank, non -recirculating systems, and entire length of recirculating sections of hot water pipes are insulated per Standards Table 150-13. §150(j)2: Cooling system piping (suction, chilled water, or brine lines),and piping insulated between heating source and indirect hot water tank shall be insulated to Table 150-B and Equation 150-A. §150(j)2: Pipe insulation for steam hydronic heating systems or hot water systems >15 psi, meets the requirements of Standards Table 123-A. 150 j 3A: Insulation is protected from damage, including that due to sunlight, moisture, equipment maintenance, and wind. §150(j)3A: Insulation for chilled water piping and refrigerant suction lines includes a vapor retardant or is enclosed entirely in conditioned space. 150(j)4: Solar water -heating systems and/or collectors are certified by the Solar Rating and Certification Corporation. EnergyPro 5.1 by EnergySoft User Number: 4066 RunCode: 2014-12-08T17:38:53 ID: 2014-21 Page 8 of 12 MANDATORY MEASURES SUMMARY: Residential (Page 2 of 3 MF -1 R Project Name Date A New Residence 12/8/2014 §150(m)1: All air -distribution system ducts and plenums installed, are sealed and insulated to meet the requirements of CMC Sections 601, 602, 603, 604, 605 and Standard 6-5; supply -air and return -air ducts and plenums are insulated to a minimum installed level of R- 4.2 or enclosed entirely in conditioned space. Openings shall be sealed with mastic, tape or other duct -closure system that meets the applicable requirements of UL 181, UL 181 A, or UL 181 B or aerosol sealant that meets the requirements of UL 723. If mastic or tape is used to seal openings reater than 1/4 inch, the combination of mastic and either mesh or tape shall be used §150(m)1: Building cavities, support platforms for air handlers, and plenums defined or constructed with materials other than sealed sheet metal, duct board or flexible duct shall not be used for conveying conditioned air. Building cavities and support platforms may contain ducts. Ducts installed in cavities and support platforms shall not be compressed to cause reductions in the cross-sectional area of the ducts. §150(m)2D: Joints and seams of duct systems and their components shall not be sealed with cloth back rubber adhesive duct tapes unless such tape is used in combination with mastic and draw bands. 150(m)7: Exhaust fans stems have back draft or automatic dampers. §150(m)8: Gravity ventilating systems serving conditioned space have either automatic or readily accessible, manually operated dampers. §150(m)9: Insulation shall be protected from damage, including that due to sunlight, moisture, equipment maintenance, and wind. Cellular foam insulation shall be protected as above or painted with a coating that is water retardant and provides shielding from solar radiation that can cause degradation of the material. 150 m 10: Flexible ducts cannot have porous inner cores. §150(o): All dwelling units shall meet the requirements of ANSI/ASHRAE Standard 62.2-2007 Ventilation and Acceptable Indoor Air Quality in Low -Rise Residential Buildings. Window operation is not a permissible method of providing the Whole Building Ventilation required in Section 4 of that Standard. Pool and Spa Heating Systems and Equipment Measures: §114(a): Any pool or spa heating system shall be certified to have: a thermal efficiency that complies with the Appliance Efficiency Regulations; an on-off switch mounted outside of the heater; a permanent weatherproof plate or card with operating instructions; and shall not use electric resistance heating ora pilot light. §114(b)1: Any pool or spa heating equipment shall be installed with at least 36" of pipe between filter and heater, or dedicated suction and return lines, or built-up connections for future solar heating. 114(b)2: Outdoor pools ors as that have a heat pump or gas heater shall have a cover. §114(b)3: Pools shall have directional inlets that adequately mix the pool water, and a time switch that will allow all pumps to be set or programmed to run only during off-peak electric demand periods. 150 : Residential pool systems orequipment meet the pump sizing, flow rate, piping, filters, and valve requirements of §150 Residential Lighting Measures: §150(k)1: High efficacy luminaires or LED Light Engine with Integral Heat Sink has an efficacy that is no lower than the efficacies contained in Table 150-C and is not a low efficacy luminaire asspecified by §150(k)2. 150(k)3: The wattage of permanently installed luminaires shall be determined asspecified by §130(d). §150(k)4: Ballasts for fluorescent lamps rated 13 Watts or greater shall be electronic and shall have an output frequency no less than 20 kHz. §150(k)5: Permanently installed night lights and night lights integral to a permanently installed luminaire or exhaust fan shall contain only high efficacy lamps meeting the minimum efficacies contained in Table 150-C and shall not contain a line -voltage socket or line - voltage lamp holder; OR shall be rated to consume no more than five watts of power as determined by §130(d), and shall not contain a medium screw -base socket. 150(k)6: Lighting integral to exhaust fans, in rooms other than kitchens, shall meet the applicable requirements of §150(k). 150(k)7: All switching devices and controls shall meet the requirements of §150(k)7. §150(k)8: A minimum of 50 percent of the total rated wattage of permanently installed lighting in kitchens shall be high efficacy. EXCEPTION: Up to 50 watts for dwelling units less than or equal to 2,500 ft2 or 100 watts for dwelling units larger than 2,500 ft2 may be exempt from the 50% high efficacy requirement when: all low efficacy luminaires in the kitchen are controlled by a manual on occupant sensor, dimmer, energy management system (EMCS), or a multi -scene programmable control system; and all permanently installed luminaries in garages, laundry rooms, closets greater than 70 square feet, and utility rooms are high efficacy and controlled by a manual -on occupant sensor. §150(k)9: Permanently installed lighting that is internal to cabinets shall use no more than 20 watts of power per linear foot of illuminated cabinet. EnergyPro 5.1 by EnergySoft User Number: 4066 RunCode: 2014-12-08T17:38:53 ID: 2014-21 Page 9 of 12 MANDATORY MEASURES SUMMARY: Residential (Page 3 of 3 MF -1 R Project Name Date A New Residence 12/8/2014 §150(k)10: Permanently installed luminaires in bathrooms, attached and detached garages, laundry rooms, closets and utility rooms shall be high efficacy. EXCEPTION 1: Permanently installed low efficacy luminaires shall be allowed provided that they are controlled by a manual -on occupant sensor certified to comply with the applicable requirements of §119. EXCEPTION 2: Permanently installed low efficacy luminaires in closets less than 70 square feet are not required to be controlled by a manual -on occupancy sensor. §150(k)11: Permanently installed luminaires located in rooms or areas other than in kitchens, bathrooms, garages, laundry rooms, closets, and utility rooms shall be high efficacy luimnaires. EXCEPTION 1: Permanently installed low efficacy luminaires shall be allowed provided they are controlled by either a dimmer switch that complies with the applicable requirements of §119, or by a manual - on occupant sensor that complies with the applicable requirements of §119. EXCEPTION 2: Lighting in detached storage building less than 1000 square feet located on a residential site is not required to comply with §150 k 11. §150(k)l2: Luminaires recessed into insulated ceilings shall be listed for zero clearance insulation contact (IC) by Underwriters Laboratories or other nationally recognized testing/rating laboratory; and have a label that certifies the lumiunaire is airtight with air leakage less then 2.0 CFM at 75 Pascals when tested in accordance with ASTM E283; and be sealed with a gasket or caulk between the luminaire housing and ceiling. §150(k)13: Luminaires providing outdoor lighting, including lighting for private patios in low-rise residential buildings with four or more dwelling units, entrances, balconies, and porches, which are permanently mounted to a residential building or to other buildings on the same lot shall be high efficacy. EXCEPTION 1: Permanently installed outdoor low efficacy luminaires shall be allowed provided that they are controlled by a manual on/off switch, a motion sensor not having an override or bypass switch that disables the motion sensor, and one of the following controls: a photocontrol not having an override or bypass switch that disables the photocontrol; OR an astronomical time clock not having an override or bypass switch that disables the astronomical time clock; OR an energy management control system (EMCS) not having an override or bypass switch that allows the luminaire to be always on EXCEPTION 2: Outdoor luminaires used to comply with Exceptionl to §150(k)l3 may be controlled by a temporary override switch which bypasses the motion sensing function provided that the motion sensor is automatically reactivated within six hours. EXCEPTION 3: Permanently installed luminaires in or around swimming pool, water features, or other location subject to Article 680 of the California Electric Code need not be high efficacy luminaires. §150(k)14: Internally illuminated address signs shall comply with Section 148; OR not contain a screw -base socket, and consume no more than five watts of power as determined according to §130(d). §150(k)15: Lighting for parking lots and carports with a total of for 8 or more vehicles per site shall comply with the applicable requirements in Sections 130, 132, 134, and 147. Lighting for parking garages for 8 or more vehicles shall comply with the applicable requirements of Sections 130, 131, 134, and 146. §150(k)l6: Permanently installed lighting in the enclosed, non -dwelling spaces of low-rise residential buildings with four or more dwelling units shall be high efficacy luminaires. EXCEPTION: Permanently installed low efficacy luminaires shall be allowed provided that they are controlled by an occupant sensors certified to comply with the applicable requirements of 119. EnergyPro 5.1 by EnergySoft User Number: 4066 Run Code: 2014-12-08T17:38:53 ID: 2014-21 Page 10 of 12 ENERGY USE AND COST SUMMARY ECON-1 Project Name A New Residence Date 12/8/2014 Rate: Electric Alameda H Fuel Type: Electricity STANDARD PROPOSED MARGIN Energy Use (kWh) Peak Demand (kW) Cost ($) Energy Use (kWh) Peak Demand (kW) Cost ($) Energy Use (kWh) Peak Demand Cost (kW) ($) Jan 125 1 18 110 1 16 15 0 2 Feb 81 3 13 69 1 12 12 2 1 Mar 64 2 12 56 2 11 8 0 1 Apr 76 3 13 71 3 12 6 0 1 May 34 4 9 55 5 11 -20 -1 -2 Jun 123 6 18 195 6 25 -72 0 -7 Jul 162 5 22 236 5 29 -75 0 -8 Aug 198 6 25 236 6 29 -38 0 -4 $ep 111 7 16 103 6 16 7 1 1 Oct 47 5 10 35 4 9 12 0 1 Nov 76 1 13 66 1 12 10 0 1 Dec 123 1 184lbs/yr 1 16 16 0 2 Year 1,220 7 185 6 198 -120 1 -12 CO2 982 lbs/yr -97 lbs/yr Rate: Gas PG&E P Fuel T pe: Natural Gas STANDARD PROPOSED MARGIN Energy Use (therms) Peak Demand (kBtu/hr) Cost ($) Energy Use (therms) Peak Demand (kBtu/hr) Cost ($) Energy Use (therms) Peak Demand Cost kBtu/hr) $ Jan 112 78 150 84 65 109 28 13 41 Feb 75 68 97 57 58 71 18 10 26 Mar 63 65 79 47 55 58 16 10 21 Apr 53 56 66 39 48 48 15 8 18 May 26 47 35 21 41 27 5 6 8 Jun 23 33 31 18 21 24 5 12 7 Jul 23 6 30 18 1 6 23 5 0 7 Aug 23 6 30 18 6 23 5 0 7 Sep 22 6 29 17 6 22 5 0 7 Oct 28 51 38 22 44 29 6 8 9 Nov 74 71 95 55 60 68 19 11 27 Dec 110 80 147 82 66 106 1 28 14 41 Year 631 80 826 477 66 609 154 14 217 CO2 7,387 lbs/yr 5,586 lbs/yr 1,801 lbs/yr Annual Totals Energy Demand Cost Cost/sqft Virtual Rate Electricity 1,340 kWh 6 kW $ 198 $ 0.08 /sgft $ 0.15 /kWh Natural Gas 477 therms 66 kBtu/hr $ 609 $ 0.25 lg ft $ 1.28 /therm Total $ 807 $ 0.33 /sgft Avoided CO2 Emissions: 1,704 lbs/yr EnergyPro 5.1 by EnergySoft User Number: 4066 RunCode: 2014-12-08T17:38:5 ID: 2014-21 Page 11 of 12 UTILITY INCENTIVE WORKSHEET UTIL-1 R Project Name Date A New Residence 12/8/2014 ANNUAL TDV ENERGY USE (kBtu/sqft-yr) PERCENT BELOW Mar in Standard TITLE 24 % Better' ENERGY COMPONENT Standard ProDosed Mar in Space Heating 22.67 16.25 6.42 7.81 / 50.36 = 15.5 Space Cooling 6.28 8.02 -1.75 Cooling Standard Heat Rejection 0.00 0.00 0.00 -1.75 / Indoor Fans 4.40 4.54 -0.14 Incentive Eligibility Yes No Domestic Hot Water 17.01 13.73 3.28 Owner Incentive (>=15%) m ❑ Pumps 0.00 0.00 0.00 NSHP Incentive (>=30%) ❑ ❑ Conditioned Floor Area = 2,441.0 ftz TOTALS: 50.36 42.55 7.81 Number of Bedrooms = 1 Energy Star V3 Target = 32 % - . ANNUAL SITE ENERGY USE Average 2pm - 5pm Standard Proposed Margin Single Orientation Peak Demand kW 3.E 1 4.2 1 -0.4 Standard Proposed Margin ENERGY COMPONENT Electricity Natural Gas Electricity Natural Gas Electricity Natural Gas (kWh) (therms) (kWh) (therms) (kWh) (therms) Space Heating 0.00 351.48 0.00 251.63 0.00 99.85 Space Cooling 520.53 0.00 669.89 0.00 -149.36 0.00 Heat Rejection 0.00 0.00 0.00 0.00 0.00 0.00 Indoor Fans 699.36 0.00 670.34 0.00 29.03 0.00 Domestic Hot Water 0.00 279.86 0.00 225.79 0.00 54.08 Pumps 0.00 0.00 0.00 0.00 0.00 0.00 TOTALS: 1,219.89 631.34 1,340.22 477.41 -120.33 153.93 POTENTIAL OWNER INCENTIVE CALCULATION tential incentives indicated ron % Better than Title -24` (from step 2) Incentive Savings Rate (from Ste 3) Subtotal this report are available Electricity (kWh) 15.5 % �� x 0.00 = $0 y through the California Advanced Homes Program for $/kW0.44 kWh new construction and are Electricity (kW) x 0.0 = $o NOT GUARANTEED. Projects $/kW kW must meet all other program Natural Gas 15.5 % �� 1.78 x 153.93 = $274 requirements to qualify. Potential incentives are $/therm therm subject to program limitations Base Incentive = $274 Pacific Gas and Energy Star Incentive n/a x 10% Electric Company ... __.... ____....... _.... ......... _._. Green Home Incentive n/a x 10% SOUMERN CALIFORNIA ED I SO N Compact Home Incentive n/a x 15% .,, UPSON r,ti°rt R,,'VArr0.N' V Company Photovoltaic Incentive $78 x 2.0 = $156 � SoG DC Rating kW A' Sempra Energy utility' 4•� N S H P gas AW california Total = $430 A 1^1 riscw}".,wM1y Better than in this equation is limited to 45% EnergyPro 5.1.7.3 by EnergySoft User Number: 4066 RunCode: 2014-12-08717:38:53 ID: 2014-21 Page 12 of 12