Loading...
17-180 Griffin Painting, Inc., Creekside Building PaintingCITY OF II PUBLIC WORKS CONTRACT $45,000 OR LESS CUPERTINO 1. PARTIES This public works contract ("Contract") is made and entered into on December 18. 2017 ("Effective Date") by and between the City of Cupertino, a municipa l corporation ("City"), and Griffin Painting Inc. , a corporation ( corporation, partnership, limited liability company, and sole proprietorship/individual} ("Contractor") for Creekside Build ing Painting [identify project, work] ("Project"). 2. SCOPE OF WORK Contractor will perform and provide a ll labor, materia ls, equipment, supplies, transportation and any other items or work necessary to perform and complete the work required for the Project ("Work"), as required in the Scope of Work, attached here and incorporated as Exhibit A, and in accordance with the terms and conditions of this Contract. 3. TIME FOR COMPLETION 3.1 Term. This Contract begins on the Effective Date and ends on March 31, 2010 ("Contract Time") unless terminated earlier as provided herein. Contractor's Work shall begin on the date shown on a written Notice to Proceed (''NTP") and must be fully completed within the Contract Time or on the date specifically provided in the Notice to Proceed. The City Engineer will not issue a NTP until the Contract is fully executed by both parties and City has _ received satisfactory proof of insurance and any performance and payment bonds that may be required. 3.2 Time is of the essence for Contractor's performance and completion of the Work. Contractor must have sufficient time, resources, and qualified staff to deliver the work on time . 3.3 Liquidated damages of$ 200.00 will be charged for each day of unexcused delay, or City may deduct the amount from Contractor's payments. Liquidated damages are based on reasonab ly foreseeable consequences of delay and may include intangib le losses which the Parties agree may be difficult to ascertain, such as loss of public confidence in City and its contractors, interference or loss of use of public facilities, and extended disruption to the public. 4. COMPENSATION 4.1 Maximum Compensation. City will pay Contractor for satisfactory performance of the Work an amount that will based on actual costs but that will be capped so as not to exceed$ 13,400 .00 ("Contract Price"), for all of Contractor's direct and indirect costs, including all labor, materials, supplies, equipment, taxes, insurance, bonds and all overhead costs . 4.2 Invoices and Payments. Contractor must submit an invoice on the first day of each month, describing the Work performed during the preceding month, itemizing labor, materials, equipment and Public Works Project Creekside Building Painting Public Works Contract $45,000 /Rev. Nov 3, 2017 Pagel of 10 any incidental costs incurred. Contractor will be paid 95% of the undisputed amounts billed within 30 days after City receives a properly submitted invoice. Any retained amounts will be included with Contractor's final payment within 60 days of City 's acceptance of the Work as complete. 5. INDEPENDENT CONTRACTOR 5.1 Status. Contractor is an independent contractor and not an employee of City. Contractor is solely responsible for the means and methods of performing the Work and for the persons under this employment. Contractor is not entitled to worker's compensation or any other City benefits. 5.2 Contractor's Qualifications. Contractor warrants on behalf of itself and its subcontractors that they have the qualifications and skills to perform the Work in a competent and professional manner and according to the highest standards and best practices in the industry. 5.3 Permits and Licenses. Contractor warrants on behalf of itself and its subcontractors that they are properly licensed, registered, and/or certified to perform the Work as required by law , and have procured a City Business License. Contractor shall possess a California Contractor's License in good standing for the following classification(s): C-33 , which must remain valid for the entire Contract Time. 5.4 Subcontractors. Only Contractor's employees are authorized to work under this Contract. Prior written approval from City is required for any subcontractor, and the terms and conditions of this Contract will apply to any approved subcontractor. 5.5 Tools, Materials and Equipment. Contractor will supply all tools, materials and equipment required to perform the Work under this Contract. 5.6 Payment of Taxes. Contractor must pay income taxes on the money earned under this Contract. Upon City 's request, Contractor will provide proof of payment and will indemnify City for violations pursuant to the indemnification provision of this Contract. 6. CHANGE ORDERS Amendments and change orders must be in writing and signed by City and Contractor. Contractor's request for a change order must specify the proposed changes in the Work, Contract Price, and Contract Time. Each request must include all the supporting documentation, including but not limited to plans/drawings, detailed cost estimates, and impacts on schedule and completion date. 7. ASSIGNMENTS; SUCCESSORS Contractor shall not assign, hypothecate, or transfer this Contract or any interest therein , directly or indirectly, by operation oflaw or otherwise, without prior written consent of City. Any attempt to do so will be null and void. Any changes related to the financial control or business nature of Contractor as a legal entity is considered an assignment of the Contract and subject to City approval, which shall not be unreasonably withheld. Control means fifty percent (50%) or more of the voting power of the business entity . This Contract is binding on Contractor, its heirs , successors and permitted assigns Public Works Project Cree kside Bu ll dl n9 Pa inti ng Public Works Contract $45,000 /Rev. Nov 3, 2017 Page 2 of JO 8. PUBLICITY/ SIGNS Any publicity generated by Contractor for the Project during the Contract Time, and for one year thereafter must credit City contributions to the Project. The words "City of Cupertino" must be displayed in all pieces of publicity, flyers, press releases, posters, brochures, interviews, public service announcements and newspaper articles. No signs may be posted or displayed on or about City property, except signage required by law or this Contract, without prior written approval from the City. 9. SUBCONTRACTORS 9.1 Contractor must perform all the Work with its own forces, except that Contractor may hire qualified subcontractors to perform up to30 % of the Work, provided that each subcontractor is required by contract to be bound by the provisions of this Contract. Contractor must provide City with written proof of compliance with this provision upon request. 9.2 City may reject any subcontractor of any tier and bar a subcontractor from performing Work on the Project, if City in its sole discretion determines that subcontractor's Work falls short of the requirements of this Contract or constitutes grounds for rejection under Public Contract Code Section 4107. If City rejects a subcontractor, Contractor at its own expense must perform the subcontractor's Work or hire a new subcontractor that is acceptable to City. A Notice of Completion must be recorded within 15 days after City accepts the Work if the Contract involves work by subcontractors. 10. RECORDS AND DAILY REPORTS 10.1 Contractor must maintain daily reports of the Work and submit them to City upon request and at completion of Project. The reports must describe the Work and specific tasks performed, the number of workers, the hours, the equipment, the weather conditions, and any circumstances affecting performance. City will have ownership of the reports, but Contractor will be permitted to retain copies. 10.2 If applicable, Contractor must keep a separate set of as-built drawings showing changes and updates to the Scope of Work or the original drawings as changes occur. Actual locations to scale must be identified for all major components of the Work, including mechanical, electrical and plumbing work; HY AC systems; utilities and utility connections; and any other components City determines should be included in the final drawings of the Project. Deviations from the original drawings must be shown in detail, and the location of all main runs, piping, conduit, ductwork, and drain lines must be shown by dimension and elevation. 10.3 Contractor must maintain complete and accurate accounting records of its Work, in accordance with generally accepted accounting principles, which must be available for City review and audit, kept separate from other records, and maintained for four years from the date of City's final payment. 11. INDEMNIFICATION 11.1 To the fullest extent allowed by law, and except for losses caused by the sole and active negligence or willful misconduct of City personnel, Contractor shall indemnify, defend, and hold harmless City, its City Council, boards and commissions, officers, officials, employees, agents, servants, volunteers and consultants ("Indemnitees"), through legal counsel acceptable to City, from and against any and all liability , damages, claims, stop notices , actions, causes of action , demands , Public Works Project Creekside Building Paintjng . Public Works Contract $45,000 !Rev. Nov 3, 2017 Page 3 of 10 charges, losses and expenses (including attorney fees , legal costs and expenses related to litigation and dispute resolution proceedings), of every nature arising directly or indirectly from this Contract or in any manner relating to any of the following: (a) Breach of contract, obligations, representations or warranties ; (b) Performance or nonperformance of the Work or of any obligations under the Contract by Contractor, its employees, agents, servants, subcontractors or subcontractors; (c) Payment or nonpayment by Contractor or its subcontractors or sub-subcontractors for Work performed on or off the Project Site; and (d) Personal injury, property damage, or economic loss resulting from the work or performance of Contractor or its subcontractors or sub-subcontractors. 11.2 Contractor must pay the costs City incurs in enforcing this provision . Contractor must accept a tender of defense upon receiving notice from City of a third-party claim, in accordance with California Public Contract Code Section 9201. At City's request, Contractor will assist City in the defense of a claim , dispute or lawsuit arising out of this Contract. 11.3 Contractor's duties under this entire Section are not limited to Contract Price, Workers ' Compensation or other employee benefits , or the insurance and bond coverage required in this Contract. Nothing in the Contract shall be construed to give rise to any implied right of indemnity in favor of Contractor against City or any other lndemnitee . 11 .4 Contractor's payments may be deducted or offset to cover any money the City Jost due to a claim or counterclaim arising out of this Contract, a purchase order or other transaction . 12. INSURANCE Contractor shall comply with the Insurance Requirements, attached and incorporated here as Ex hibit B. Contractor must provide satisfactory proof of insurance and maintain it for the Contract Time or longer as required by City. City will not execute the Contract until City has approved receipt of satisfactory certificates of insurance and endorsements evidencing the type, amount, class of operations covered, and the effective and expiration dates of coverage . Failure to comply with this provision may result in City, at its sole discretion and without notice, purchasing insurance at Contractor 's expense, deducting the costs from Contractor's compensation, or terminating the Contract. 13. COMPLIANCE WITH LAWS 13 .1 General Laws. Contractor shall comply with all laws and regulations applicable to this Contract. Contractor will promptly notify City of changes in the Jaw or other conditions that may affect the Project or Contractor's ability to perform. Contractor is responsible for verifying the employment status of employees performing the Work, as required by the Immigration Reform and Control Act Public Works Project Creekside Building Painting Public Works Contract $45,000 /Rev. Nov 3, 2017 Page 4 of IO 13.2 Labor Laws. (a) Contracts of$1,000 or more are subject to the requirements of the California Labor Code, including but not limited to: (i) Prevailing wage laws under Labor Code Section 1775, which require Contractor to pay prevailing wages applicable in Santa Clara County for each craft, classification, or type of worker needed to perform the Work, including health, pension and vacation. The prevailing wage rates are on file with the City Engineer's office and are available online at http://www.dir.ca.gov/DLSR; (ii) Apprenticeship requirements under Labor Code Section 1777.5 for Contacts $30,000 or more; (iii) Maintain certified payroll records in accordance with Labor Code Sections 1776 and 1812, and electronically submit them to the Labor Commissioner as required by the regulations of California, Department of Industrial Relations ("DIR"); (iv) Comply with DIR Monitoring, Enforcement and Registration requirements of Labor Code Section 1725 .5. (b) Contractor must compensate workers who are paid less than prevailing wages or required to work more than a legal day's work. Contractor will also be required to pay City a penalty of $ 200.00 per worker for each day of violation. (c) As required by Labor Code Section 1861, by signing this Contract Contractor certifies as follows: "I am aware of Labor Code Section 3700 which requires every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the Work on this Contract." 13.3 Discrimination Laws. Contractor shall not discriminate on the basis of race, religious creed, color, ancestry, national origin, ethnicity, handicap, disability, marital status, pregnancy, age, sex, gender, sexual orientation, gender identity, Acquired-Immune Deficiency Syndrome (AIDS) or any other protected classification. Contractor shall comply with all anti-discrimination laws, including Government Code Sections 12900 and 11135, and Labor Code Sections 1735, 1777 and 3077.5. Consistent with City policy prohibiting harassment and discrimination, Contractor understands that harassment and discrimination directed toward a job applicant, an employee, a City employee, or any other person, by Contractor or Contractor's employees or sub-contractors will not be tolerated. 13.4 Conflicts of Interest. Contractor, its employees, subcontractors, servants and agents, may not have, maintain or acquire a conflict of interest in relation to this Contract in violation of law, including Government Code section 1090 and Government Code section 81000 and their accompanying regulations. No officer, official, employee, consultant, or other agent of the City ("City Representative") may have, maintain, or acquire a "financial interest" in the Contract, as that term is defined by state law, or in violation of a City ordinance or policy while serving as a City Representative or for one year thereafter. Contractor, its employees, subcontractors, servants and agents warrant they are not employees of City or have any relationship with City officials, officers or employees that creates a conflict of interest. Contractor may be required to file a conflict of interest form if it makes certain governmental decisions or serves in a staff capacity, as defined in section Public Works Project Creeksid11 Building Painting Public Works Contract $45,000 /Rev. Nov 3, 2017 Page 5 of 10 18700 of the California Code of Regulations. Contractor agrees to abide by City rules governing gifts to public officials and employees. 13.5 Remedies. Any violation of Section 13 constitutes a material breach and may result in City suspending payments, requiring reimbursement, or terminating the Contract. City reserves all rights and remedies under the law and this Contract, including seeking indemnification. 14. BONDS For contracts of $25,000 or more, Contractor must obtain a payment bond and a performance bond, each in the penal sum of 100% of the Contract Price, using the Bond Forms attached and incorporated here as Exhibit C. Each bond must be issued by a surety admitted in California, with a financial rating from A.M. Best Company of Class A-or higher, or as otherwise acceptable to City. If an issuing surety cancels a bond or becomes insolvent, Contractor must provide a substitute bond from a surety acceptable to City within seven calendar days after written notice from City. If Contractor fails to do so, City may in its sole discretion and without prior notice, purchase bonds at Contractor's expense, deduct the cost from payments due Contractor, or terminate the Contract. City will not execute the Contract nor issue the NTP until the required bonds are submitted . 15. UTILITIES, TRENCHING AND EXCAVATION 15.1 Contractor must call the Underground Service Alert ("USA") 811 hotline and request marking of utility locations before digging or commencing Work. For underground service alerts for street lighting and traffic signal conduits, City's Service Center must be called at (408) 777-3269. Government Code Section 4215 requires Contractor to notify City and Utility in writing if it discovers utilities or utility facilities not identified in the Contract. 15.2 Pursuant to Government Code Section 7104, Contractor must stop work, notify City in writing, and wait for instructions if one of the conditions below is found at the worksite. City will work with Contractor to amend the Contract or issue a change order if the discovered conditions materially change the Work/Performance, Contract Time or Contract Price. (a) Material believed to be hazardous waste under Health and Safety Code Section 25 I 17, and which requires removal to a Class I, Class II, or Class III disposal site pursuant to law; (b) Subsurface or latent physical conditions at the Project worksite differing from those indicated by information about the worksite made available to Contractor; and (c) Unknown physical conditions at the Project worksite of any unusual nature, materially different from those ordinarily encountered and from those generally recognized as inherent in the character of the Work. 15.3 For contracts $25,000 or higher that require excavation or involve trenches five feet or more in depth, Contractor must submit a detailed plan for City approval, per Labor Code Section 6705 prior to commencing work. The plan must show the design of shoring, bracing, sloping and other provisions for worker protection from caving ground and other hazards. The protective system must comply with all Construction Safety Orders. If the plan varies from shoring system standards, it must be prepared by a registered civil or structural engineer. Public Works Project Creekside Building Painting Public Works Contract $45,000 !Rev. Nov 3, 2017 Page 6 of 10 16. URBAN RUNOFF MANAGEMENT 16.1 All Work must fully comply with federal, state and local laws and regulations concerning storm water management. Contractor must avoid creating excess dust when breaking asphalt or concrete and during excavation and grading. If water is used for dust control, Contractor will use only the amount of water necessary to dampen the dust. Contractor will take all steps necessary to keep wash water out of the streets, gutters and storm drains. Prior to the start of the Work, Contractor will implement erosion and sediment controls to prevent pollution of storm drains, and must upgrade and maintain these controls based on weather conditions or as otherwise required by City. These controls must be in place during the entire Contract Time and must be removed at the end of construction and completion of the Work. Such controls must include, but will not be limited to, the following requirements: (a) Install storm drain inlet protection devices such as sand bag barriers, filter fabric fences, and block and gravel filters at all drain inlets impacted by construction. During the annual rainy season, October 15 through June 15, storm drain inlets impacted by construction work must be filter-protected from onsite de-watering activities and saw-cutting activities. Shovel or vacuum saw-cut slurry and remove from the Work site; (b) Cover exposed piles of soil or construction material with plastic sheeting. Store all construction materials in containers; ( c) Sweep and remove all materials from paved surfaces that drain to streets, gutters and storm drains prior to rain and at the end of each work day. When the Work is completed, wash the streets, collect and dispose of the wash water offsite in lawful manner; ( d) After breaking old pavement, remove debris to avoid contact with rainfall/runoff; ( e) Maintain a clean work area by removing trash, litter, and debris at the end of each work day and when Work is completed. Clean up any leaks, drips, and other spills as they occur. 16.2 These requirements must be used in conjunction with the California Stormwater Quality Association and California Best Management Practices Municipal and Construction Handbooks, local program guidance materials from municipalities, and any other applicable documents on stormwater quality controls for construction. Contractor's failure to comply with this Section will result in the issuance of noncompliance notices, citations, Work stop orders and regulatory fines. 17. PROJECT COORDINATION City Project Manager. City assigns Ken Tanase as the City representative for all purposes under this Contract, with authority to require compliance with the Scope of Work. City may substitute Project Managers at any time and without prior notice to Contractor. Contractor Project Manager. Subject to City approval, Contractor assigns _M_ar_kG_r_iffi_n _____ _ as its single representative for all purposes under this Contract, with the responsibility to ensure progress with the Work. Contractor's Project Manager is responsible for coordinating and scheduling the Work and must regularly update the City Project Manager about the status and any delays with the Work, consistent with the Scope of Work. Any substitutions must be approved in writing by City. Public Works Project Creekside Building Painting Public Works Contract $45,000/Rev. Nov 3, 2017 Page 7 of IO 18. ABANDONMENT AND TERMINATION 18.1 City may abandon or postpone the Project or parts therefor at any time. Contractor will be compensated for satisfactory Work performed through the date of abandonment and will be given reasonable time to close out the Work. With City's pre-approval in writing, the time spent in closing out the Work will be compensated up to 10% of the total time expended in performing the Work. 18.2 City may terminate the Contract for cause or without cause at any time. Contractor will be paid for satisfactory Work rendered through the termination date and will be given reasonable time to close out the Work. 18.3 Final payment will not be made until Contractor delivers the Work and provides records documenting the Work, products and deliverables completed. Nothing in the Section below is intended to delay, abridge or bar City's right under this Section. 19. GOVERNING LAW, VENUE AND DISPUTE RESOLUTION This Contract is governed by the laws of State of California. Venue for any legal action shall be the Superior Court of the County of Santa Clara, California. The dispute resolution procedures of Public Contract Code Section 20104, incorporated here by reference, apply to this Contract and Contractor is required to continue the Work pending resolution of any dispute. Prior to filing a lawsuit, Contractor must comply with the claim filing requirements of the California Government Code. If the Parties elect arbitration, the arbitrator's award must be supported by law and substantial evidence and include detailed written findings of law and fact. 20. ATTORNEY FEES If City initiates legal action, files a complaint or cross-complaint, or pursues arbitration, appeal, or other proceedings to enforce its rights or a judgment in connection with this Contract, the prevailing party will be entitled to reasonable attorney fees and costs. 21. SIGNS/ADVERTISEMENT No signs may be displayed on or about City's property, except signage which is required by law or by the Contract, without City's prior written approval as to size, design and location. 22. THIRD PARTY BENEFICIARIES There are no intended third party beneficiaries of this Contract. 23. WAIVER Neither acceptance of the Work nor payment thereof shall constitute a waiver of any contract provision. City waiver of any breach shall not constitute waiver of another provision or breach. Public Works Project Creekside Building .painting Pub lic Works Contract $45,000 /Rev. Nov 3, 2017 Page 8 of 10 26. WARRANTY Contractor warrants that materials and equipment used will be new, of good quality, and free from defective workmanship and materials, and that the Work will be free from material defects not intrinsic in the design or materials. All Work, materials and equipment should pass to City free ofclaims, liens or encumbrances. Contractor waiTants the Work and materials for one year from the date of City's acceptance of the Work as complete ("Warranty Period"), except when a longer guarantee is provided by a supplier, manufacturer or is required by this Contract. During the Warranty Period, Contractor wi ll repair or replace any Work defects or materials, including damage that arises from Contractor's Warranty Work, except any wear and tear or damage resulting from improper use or maintenance. 27. ENTIRE CONTRACT This Contract and the attachments, documents, and statutes attached, referenced, or expressly incorporated herein, including authorized amendments or change orders constitute the final and complete contract between City and Contractor with respect to the Work and the Project. No oral contract or implied covenant will be enforceable against City. If any attachment or incorporated provisions conflict or are inconsistent with the terms of this Contract, the Contract terms will control. 28. SEVERABILITY IP ARTIAL INVALIDITY If a court finds any term or provision of this Contract to be illegal, invalid or unenforceable, the legal portion of said provision and all other contract provisions will remain in full force and effect. 28. SURVIVAL The contract provisions which by their nature should survive the Contract or Completion of Project, including without limitation all warranties, indemnities, payment obligations, insurance and bonds, shall remain in full force and effect after the Work is completed or Contract ends. 29. INSERTED PROVISIONS Each provision and clause required by law to be inserted in this Contract will be deemed to be included and will be inferred herein. Either party may request an amendment to cure mistaken insertions or omissions of required provisions. 30. CAPTIONS The captions, t itles , and headings in this Contract are for convenience only and may not be used in the construction or interpretation of the Contract or for any other purpose. 31 . COUNTERPARTS This Contract may be executed in counterparts, each of which is an original and all of which taken together shall form one single document. Public Works Project Creekside Building Painting Pub lic Works Contract $45,000 /Rev. Nov 3, 2017 Page9 of IO 20. NOTICES All notices, requests, and approvals must be sent in writing to the persons below and will be considered effective on the date of personal delivery, the date confirmed by a reputable overnight delivery service, on the fifth calendar day after deposit in the United States Mail, postage prepaid, registered or certified, or the next business day following electronic submission: To City of Cupertino: 10300 Torre A venue, Cupertino CA 95014 Attention: Ken Tanase -------------Copy to: Jonathen Ferrante Emai 1: kent@cupertino.org 30. VALIDITY OF CONTRACT To Contractor: Griffin Pa inting Inc. Attention: Mark Griffin ------------Copy to: ____________ _ Emai I: mark@griffinpainting.com This Contract is valid and enforceable only if (a) it complies with the purchasing and contract provisions of Cupertino Municipal Code Chapters 3.22 and 3.23, (b) is signed by the City Manager or an authorized designee, and (c) is approved for form by the City Attorney's Office. 32. EXECUTION The persons signing below warrant they have the authority to enter into this Contract and to legally bind their respective Parties. If Contractor is a corporation, signatures from two officers of the corporation are required pursuant to California Corporations Code Section 313. IN WITNESS WHEREOF, the parties have caused this Contract to be executed as of the Execution Date first above written. CONTRACTOR _G_nm_in_P_ain_un_g_1n_c. ______ , CITY OF CUPERTINO, 'a/or~vzuaw~ ;y~~~orati ~ [Name] fTb-,rl;,r ~"\ -~--,m---m_B_o~r-d~en __________ _ Title: Owner Title: Director of Public Works Signature Date: / / / a-8 /; 7 Signature Date: I ( f 1 'fj 6 7 r I -\,.._..,_!~_.,"-+-------~ APPROVED AS TO FORM: ,J3y'.' ~u rrr0/ RAO LPH STEVENSON HOM W' Cupertino City Attorney ATTEST: ~ By: e~ /2---2 (-(J GRACE SCHMIDT, City Clerk Public Works Project Creekside Building Painting Page IOoflO p~ /1J I f,, ~ '5 (}-e_(_j-IP I ff1J -i 1. tf' -31 C) t1V . '1 10 Public Works Contract $45,000 !Rev. Nov 3, 2017 Griffin Painting Inc. 3580 Haven Ave. #2 Redwood City, CA 94063 CA Lie# 599026 (650) 368-3190 Fax (650) 368-3192 Proposal PROPOSAL: 003541 DATE: 10/05/17 Creekside Exterior Building EXH I B !T "A" CLIENT: COCUP City Of Cupertino PROJECT: 023503 Creekside Exterior Building 10300 Torre Ave. Cupertino, CA 95014-3202 Contractor agrees to furnish all equipment, materials, supplies, services and labor in accordance with all applicable labor, building and Building Plans and Specifications and to complete the following work: Proposal Scope of Work: Attn: Ty Pressure wash building. Prime new plywood at roof infill. Paint new work with 2 coats of finish. Paint entire building with 1 coat of finish to match existing. Enamel restroom doors on 2 sid es, all other exterior side only. Signed: _________________ _ Dated: ________ _ Title: TOTAL BID: $13,400.00 EXHIBIT B -INSURANCE REQUIREMENTS A. Required Policies and Limits. The following insurance policies and limits are required for this Contract, unless otherwise specified in Exhibit A: (I) Commercial General Liability ("CGL ') Insurance: The CGL policy must be issued on an occurrence basis, written on a comprehensive general liability form, and must include coverage for liability arising from Contractor's or its subcontractor's acts or omissions in the performance of the Work, including contractor's protected coverage, blanket contractual, completed operations, vehicle coverage and employer's non-ownership liability coverage, with limits of at least $2,000,000 per occurrence and $4,000,000 in the aggregate. The CGL policy must protect against any and all liability for personal injury, death, or property damage or destruction arising directly or indirectly in the performance of the Contract. The CGL coverage may be arranged under a single policy for the full limits required or by a combination of underlying policies with the balance provided by excess or umbrella policies, provided each such policy complies with the requirements set forth in this Contract. a. It will be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits will be made available to the Additional Insured and will be (I) the minimum coverage and limits specified in this agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy, whichever is greater. b. The Additional Insured coverage under the Contractor's policy will be "primary and non-contributory" and will not seek contribution from the City 's insurance or self-insurance and will be at least as broad as CG 20 0 I 04 12. c. The limits of Insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess Insurance . Any umbrella or excess Insurance will contain or be endorsed to contain a provision that such coverage will also apply on a primary and non-contributory basis for the benefit of City (if agreed to in a written contract or agreement) before the City's own insurance or self-insurance will be called upon to protect it as a named insured. Contractor will maintain insurance as required by this contract to the fullest amount allowed by law and will maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by the contractor. (2) Comprehensive Automobile Liability Insurance: The automobile liability policy must be issued on an occurrence basis, with limits of at least $1,000,000 per occurrence for bodily injury and $1,000,000 per occurrence for property damage, or combined single limit of $1 ,000 ,000 per occurrence, covering owned , non-owned and hired automobiles. (3) Workers' Compensation Insurance and Employer's Liability Insurance: The workers' compensation and employer's liability policy or policies must comply with the requirements of the California Workers' Compensation Insurance and Safety Act, providing coverage of at least $ I ,000,000 or as otherwise required by the statute. If Contractor is self- insured , Contractor must provide its Certificate of Permission to Self-Insure, duly authorized by the DIR. B. Builder's Risk Insurance. Contractor must provide builder's risk insurance only if the box below is checked. D Builder's Risk coverage is required for this Contact. The builder's risk policy must be issued for course of construction on an occurrence basis, for all-risk coverage on a 100% completed value basis on the insurable portion of the Project for the benefit of City, and name the City as a loss payee as its interest may appear. If the Project does not involve new or major reconstruction, the City may elect, acting in its sole discretion, to accept an installation floater policy instead of builder's risk. The installation floater policy must provide property damage coverage for any building, structure, machinery, or equipment damaged, impaired , broken, or destroyed during the performance of the Work, including during transit, installation, and testing at the City's site. C. Additional Insureds. City, including its City Council, boards and commissions, officers, officials, agents, employees, consultants and volunteers, must be named as additional insureds under Contractor's insurance policies required under this section, except under the worker's compensation policy. The naming of an additional insured will not affect any recovery to which the additional insured would be entitled to under the policy if not named as an additional insured. An additional insured will not be held liable for any premium, deductible portion of any loss, or expense of any nature under the policy or any extension thereof. Any other insurance held by an additional insured will not be required to contribute anything toward any loss or expense covered by Contractor's insurance. D. Notice. Each certificate of insurance must state that the coverage afforded by the policy or policies is in force and will not be reduced, cancelled or allowed to expire without at least 30 days advance written notice to City, unless due to non-payment of premiums, in which case ten days advance written notice must be provided to City. Such notice must be sent to City via certified mail and addressed to the attention of the City Manager. E. Waiver of Subrogation. Each required policy must include an endorsement providing that the carrier agrees to waive any right of subrogation it may have against City. F . Required Endorsements. The CGL policy, the automobile liability policy and the builder's risk or installation floater policy, if required, must include the following endorsements: (1) The inclusion of more than one insured will not operate to impair the rights of one insured against another, and the coverages afforded will apply as though separate policies have been issued to each insured. (2) The insurance provided is primary and no insurance held or owned by City may be called upon to contribute to a loss. (3) This policy does not exclude explosion , collapse , underground excavation hazard , or removal of lateral support. G. Forms of Certificates of Insurance and Endorsements. Each certificate of insurance and endorsement must provide the name and policy number of each carrier and policy , using a form and format acceptable to City. H. Subcontractors. Contractor must ensure that each subcontractor maintains the same insurance coverage required under this section with respect to its performance of Work on the Project, including those requirements related to the naming of additional insureds and waivers of subrogation. END OF EXHIBIT B ACORD® CERTIFICATE OF LIABILITY INSURANCE I DATE (MM/DDIYYYYI ~ 11 /?1 /?()17 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may requ i re an endorsement. A statement on this certificate does not confer rights to the certificate holder in l i eu of such endorsement(s). PRODUCER ~2:~~cT Arlene Huerta Insurance Management Corporation r.~~N,t ~-••· ( 925) 673-2200 I FAX IA/C Nol: (925) 673-2212 P.O. Box 1217 ~~~~~.arlene@imcinsurance.com License# OC54731 INSURER(Sl AFFORDING COVERAGE NAIC# Clayton CA 94517 INSURER A :AmTrus t. In terna tionalUnderwri ters INSURED INSURER B :Financial Ind~mni h, Comnanv Griffin Painting, Inc. INSURER c :National Union Fire Ins Co of PA 3580 Haven Ave INSURER D :Insurance Company of the West Suite #2 INSURER E :Axis Surolus Lines Ins Co Redwood Citv CA 94063 INSURER F: COVERAGES CERTIFICATE NUMBER:CL141202323 REVISION NUMBER: TH IS IS I u CERTIFY l HAT THE POLICIES OF INSURANCE LISTED tsELOw HAVE BEt:N 1S:sUED TO THE INSUKED NAMcu AtsOVE t-OR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ·~· ,:a~g~, 1POUCYEXP LTR TYPE OF INSURANCE 1,.,~n ,, ... ~ POLICY NUMBER MM/DD/YYYYJ LIMITS GENERAL LIABILITY ~ EACH OCCURRENCE $ 1,000,000 d. COMMERCIAL GENERAL LIABILITY DA,.~~~ I U ~~" , ~u $ 100,000 PREMISES /Ea occurrence' A D CLAIMS-MADE [iJ OCCUR X X EN102473702 ll/1/2017 1/1/2018 MED EXP (Any one person) $ 5 000 .___ .___ PERSONAL & ADV INJURY $ 1,000,000 .___ GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIM IT APPLIES PER : PRODUCTS -COMP/OP AGG $ 2,000,000 n POLICY 1x1 ~[}R.;. n LOC $ AUTOMOBILE LIABILITY COMBINED S1NGLE LIMIT ~ 1 000 000 ~ /Ea accident} X ANY AUTO BODILY INJURY (Per person) $ B '---SCHEDULED 14128734 11/1/2017 1/1/2018 ALL OWNED BODILY INJURY (Per accident) $ ~ AUTOS '--AUTOS X X NON-OWNED PROPERTY DAMAGE $ HIRED AUTOS AUTOS I Per accident\ .___ -Hired/borrowed $ UMBRELLA LIAB H OCCUR EACH OCCURRENCE $ 5,000,000 .___ C X EXCESS LIAB CLAIMS-MADE AGGREGATE $ 5,000,000 OED I I RETENTION $ ~BU 088086657 P./1/2017 1/1/2018 $ D WORKERS COMPENSATION x I T~~JitJ,~s I 10~- AND EMPLOYERS' LIABILITY Y/N ANY PROPRIETOR/PARTNER/EXECUTIVE D N/A X E.L. EACH ACCIDENT $ 1 000 000 OFFICER/MEMBER EXCLUDED? 1/1/2017 1/1/2018 (Mandatory in NHI wSA5035369 E.L. DISEASE -EA EMPLOYEE $ 1 000 000 If yes, describe under E.L. DISEASE -POLICY LIMIT $ 1 000 000 DESCRIPTION OF OPERATIONS below E Contractors Pollution Each Cla im 1,000,000 Liability CPoo2387-01-2017 5/11/2017 5/11/2018 Policy Aggreagate 2,000,000 DESCRIPTION OF OPERATIONS/ LOCATIONS/ VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space is requiredl The City of Cupertino, including its City Council, boards and commissions, officers, officials, agents, employees, consultants and volunteers shall be named as additional insured with respects to the General Liability. Insurance shall be primary and non-contributory. Waiver of subrogation shall be applied to the General Liability and Workers Comp. CERTIFICATE HOLDER CANCELLATION 10 Dav Notice of Cancellation for Non Pa"""'nt of Premiwn. City of Cupertino SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 10300 Torre Avenue ACCORDANCE WITH THE POLICY PROVISIONS. Cupettino CA 95014-3202 AUTHORIZED REPRESENTATIVE c::,;:-> Arlene Huerta/ARLENE -'-.....-'--'7 ~ © 1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05) INS025 (201oos1.01 The ACORD name and logo are registered marks of ACORD POLICY NUMBER: EN l 02 4 73 7 02 COMMERCIAL GENERAL LIABILITY NX GL 189 05 11 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSUREDS - OWNERS, LESSEES OR CONTRACTORS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART Policy Number: EN102473702 Endorsement Effective: 01 /01 /17 12 :01 a .m. Named Insured : Counter Signed By: GRIFFIN PAINTING INC -~~ /'· ~ . .. ... '.\,.,,,<'.\ S,.,i;.~ ':\:,\l; SCHEDULE Name of Person or Organization: Any person or organization that the named i nsured is obligated by virtue of a written contract or Agreement to provide insurance such as is afforded by this policy. Location: (If no entry appears above, information requ ired to complete th is endorsement will be shown in the Declarations as applicable to this endorsement.) A. Section II -Who Is An Insured is amended to include as an insured the person or organization shown in the Schedule, but only to the extent that the person or organization shown in the Schedule is held liable for your acts or omissions arising out of your ongoing operations performed for that insured. B. With respect to the insurance afforded to these additional ins ureds, the following exclusion is added: 2. Exclusions This insurance does not apply to "bodi ly injury" or "property damage" occurring after: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than services, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the site of the covered operations has been completed: or (2) That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or s ubcontractor engaged in performing operations for a principal as a part of the same project. C. The words "you " and "you r" refer to the Named Insured shown in the Declarations . NX GL 189 05 11 Page 1 of 2 Includes copyrig hted material of Insurance Services Office, Inc ., with its permission COMMERCIAL GENERAL LIABILITY NX GL 189 0511 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. D. The following are added to SECTION V -DEFINITIONS : "Your work" means work or operations performed by you or on your behalf; and mate rials, parts or equipment furnished in connection with such work or operations. E. The following additional provisions apply to any entity that is an insured by the terms of this endorsement 1. Primary Wording With respect to the Third Party sl1own above, this insurance is primary and non-contributing. Any and all other valid and collectable insurance available to such Third Party in respect of work performed by you underwritten contractual agreements with said Third Party for loss covered by this policy, shall in no instance be considered as primary, co-insurance, or contributing insurance . Rather, any such other insurance shall be considered excess over and above the insurance provided by this policy. 2 . Waiver of Subrogation If required by written contract or agreement: We waive any right of recovery we may have against an entity that is an additional insured per the terms of this endorsement because of payments we make for injury or damage arising out of "you work" done under a contract with that person or organization . NX GL 189 05 11 Page 2 of 2 Includes copyrighted material of I nsurance SeNices Office, Inc., with its permission WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC0403 06 WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT - CALIFORNIA We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be 2% of the California workers' compensation premium otherwise due on such remuneration. SCHEDULE PERSON OR ORGANIZATION ANY PERSON OR ORGANIZATION FOR WHOM THE NAMED INSURED HAS AGREED BY WRITTEN CONTRACT TO FURNISH THIS WAIVER JOB DESCRIPTION BLANKET W AIYER OF SUBROGATION This endorsement changes the policy to which it is attached and is effective on the date issued unless othe1wise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: 01/01/2017 Insured: Griffin Painting, Inc. Policy No. WSA5035369 Insurance Company: ICW GROUP Insurance Company Endorsement No . 001 Premium $ INCL. ) ~-~;l-..£R,: Countersigned By:--------------------------- -1998 by the Workers' Compensation Insurance Rating Bureau of California. All rights reserved. From the WCIRB's California Workers' Compensation Insurance Forms Manual -1999. 6 Kemper Specialty Financial Indemnity Company POLICY NUMBER: 4128734 Griffin Painting Inc. 01/01/2017 -01/01/2018 BUSINESS AUTOMOBILE LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY DESIGNATED INSURED ENDORSEMENT (CA 20 48) Name of Person(s) or Organization(s) The City of Cupertino BUSINESS AUTO COVERAGE Each person or organization indicated above is an "insured" for Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in SECTION II of the Coverage Fonn. CA20 48 07 87