97-083 Jensen Corp. Landscape contractors, renovation of Quinlin landscape renovations - Project 97-108(:its• of,
Cupertino
November 17, 1997
Jensen Corporation Landscape Contractors
10950 North Blaney Avenue
Cupertino, California 95014
CONTRACT FOR PUBLIC WORKS
City Hall
10300 Torre Avenue
Cupertino, CA 95014-3255
Telephone: (408) 777-3223
FAX: (408) 777-3366
OFFICE OF THE CITY CLERK
Enclosed is a contract by and between the City of Cupertino and Jensen Corporation Landscape
Contractors, which has been fully executed by city officials. Your bid bond is also enclosed.
If you have any questions or need additional information, please contact the Department of Public
Works.
Sincerely,
U
KIMBERLY SMITH, CMC
CITY CLERK
KS/cs
Enclosure
cc: Department of Public Works
Pnnharl no Rrvvrlrrl Pnnnr
CONTRACT FOR PUBLIC WORKS
This CONTRACT made on OCTOBER 29, 1997 by the CITY OF CUPERTINO, a
municipal corporation of the State of California, hereinafter called CITY, and JENSEN CORPORATION
LANDSCAPE CONTRACTORS hereinafter called CONTRACTOR.
IT IS HEREBY AGREED by CITY and CONTRACTOR as follows:
1. THE CONTRACT DOCUMENTS. The complete contract consists of the following contract
documents:
a. Notice to Contractors, Proposal, Time of Completion, Estimated Quantities, Noncollusion Affidavit,
Bidder Qualification Form, Subcontractors Form and Signature Form.
b. Standard Specifications, General Provisions and Special Provisions.
c. Plans and Specifications for LANDSCAPE RENOVATIONATROBERT W. QUINLAN
COMMUNITY CENTER, PROJECT 97-108
d. Faithful Performance Bond and Materials Bond.
e. Insurance Agreement, Certificate of Insurance, Endorsement of Primary Insurance, Additional Insured
Endorsement, Endorsement of Aggregate Limits of Insurance per Project, Waiver of Subrogation
Endorsement Worker's Compensation Insurance and Notice of Policy Cancellation Endorsement.
f. This Contract for Public Works.
All of the above documents are intended to cooperate so that any work called for in one and not mentioned
in the other, or vice versa, is to be executed the same as if mentioned in all of said documents. The
documents comprising the complete contract are sometimes hereinafter referred to as the Contract
Documents. In case of conflict between the Plans and the Specifications on the one hand, and this Contract
on the other, the Plans and Specifications shall prevail.
2. THE WORK. CONTRACTOR agrees to furnish all of the tools, equipment, apparatus,
facilities, labor, transportation and materials necessary to perform and complete in a good and working
order, the work of LANDSCAPE RENOVATION, as called for, and in the manner designated in, and in
strict conformity with, the Plans and Specifications prepared by the Engineer and adopted by CITY, which
Plans and Specifications are entitled, respectively, LANDSCAPE RENOVATION AT ROBERT W.
QUINLAN COMMUNITY CENTER, PROJECT 97-108 and which Plans and Specifications are
identified by the signatures of the parties to this Contract. It is understood and agreed that said tools,
equipment, apparatus, facilities, labor, transportation and materials shall be furnished, and that said work
shall be performed and completed as required in said Plans and Specifications under the sole direction of
CONTRACTOR, but subject to the inspection and approval of CITY, or its representative.
CITY hereby designates as its representative for the purpose of this Contract the Engineer, Mr. Bert J.
Viskovich.
Contract Page 1 of 6
3. CONTRACT PRICE. CITY agrees to pay, and CONTRACTOR agrees to accept, in full
payment for the work above agreed to be done, the sum of $43,768. 00 (FORTY THREE
THOUSAND SEVEN HUNDRED SIXTY EIGHT DOLLARS AND NO CENTS) subject to
additions and/or deductions as provided in the Contract Documents, per Exhibit A attached
hereto.
4. DISPUTES PERTAINING TO PAYMENT FOR WORK. Should any dispute arise
respecting the true value of the work done, or any work omitted, or any extra work which
CONTRACTOR may be required to do, or respecting the size of any payment to
CONTRACTOR during the performance of this Contract, said dispute shall be determined either
by reference to the Unit Prices bid, if applicable, or in accordance with agreement of prices, if
applicable, or in accordance with the agreement of the parties, or in accordance with Section 6,
paragraph "f' of the General Provisions.
5. PERMITS, COMPLIANCE WITH LAW. CONTRACTOR shall obtain and bear all
expense for all necessary permits, licenses and easements for the construction of the project, give
all necessary notices, pay all fees required by law, and comply with the laws, ordinances and
regulations relating to the work and to the preservation of the public health and safety.
6. INSPECTION BY THE CITY. CONTRACTOR shall at all times maintain proper
facilities and provide safe access for inspection by CITY to all parts of the work, and to the shops
wherein the work is in preparation. Where the Specifications require work to be specially tested
or approved, it shall not be tested or covered up without timely notice to CITY of its readiness
for inspection and without the approval thereof or consent thereto by CITY. Should any such
work be covered up without such notice, approval, or consent, it must, if required by CITY, be
uncovered for examination at CONTRACTOR'S expense.
7. EXTRA OR ADDITIONAL WORK AND CHANGES. Should CITY at any time
during the progress of the work require any alterations, deviations, additions or omissions from
the Plans and Specifications or the Contract Documents, CITY shall have the right to do so, and
the same shall in no way affect or make void the Contract, but the cost or value thereof will be
added to, or deducted from, the amount of the Contract price, as the case may be, by a fair and
reasonable valuation, which shall be determined either by reference to the Unit Prices bid, if
applicable, the Standard Specifications, or in accordance with the agreement of the parties. No
extra work shall be performed or change be made except by a written order from CITY, duly
authorized by resolution of the City Council, and by all agencies whose approval is required by
law, stating that the extra work or change is authorized, and no claim for an addition to the
Contract sum shall be valid unless so ordered.
8. CHANGES TO MEET ENVIRONMENTAL REQUIREMENTS. CITY shall have the
right to make changes in this Contract during the course of construction to bring the completed
improvements into compliance with environmental requirements or standards established by State
and Federal statutes and regulations after the Contract has been awarded or entered into.
CONTRACTOR shall be paid for such changes either by reference to the Unit Prices bid, if
applicable, or in accordance with the agreement of the parties.
Contract Page 2 of 6
9. TERMINATION, AMENDMENT OR MODIFICATION. This Contract may be
terminated, amended or modified, with the mutual consent of the parties. The compensation payable, if
any, for such termination, amendment or modification, shall be determined either by reference to the Unit
Price bid, if applicable, the Standard Specifications, or in accordance with the agreement of the parties.
10. TIME FOR COMPLETION. All work under this Contract shall be completed in accordance
with the Time for Completion section in the Proposal and the Specifications of this project. If
CONTRACTOR shall be delayed in the work by the acts or neglect of CITY, or its employees, or those
under it by contract or otherwise, or by changes ordered in the work, or by strikes, lockouts by others, fire,
unusual delay in transportation, unavoidable casualties or any causes beyond CONTRACTOR'S control,
or by delay authorized by CITY, or by any cause which CITY shall determine justifies the delay, then the
time of completion shall be extended accordingly. This paragraph does not exclude the recovery of
damages for delay by either party under other provisions in the Contract Documents.
11. INSPECTION AND TESTING OF MATERIALS. CONTRACTOR shall notify CITY a
sufficient time in advance of the manufacture, production or testing of materials to be supplied under this
Contract, in order that CITY may arrange for mill, factory or laboratory inspection and testing of same.
12. TERMINATION FOR BREACH OR INSOLVENCY. If CONTRACTOR should be adjudged
a bankrupt, or should make a general assignment for the benefit of creditors, or if a receiver should be
appointed on account of insolvency, or if CONTRACTOR or any subcontractor should violate any of the
provisions of the Contract, CITY may serve written notice upon CONTRACTOR and CONTRACTOR'S
surety of its intention to terminate the Contract. Such notice shall contain the reasons for CITY'S intention
to terminate the Contract, and unless within ten (10) days after serving of such notice, such violation shall
cease and satisfactory arrangements for corrections thereof be made, the Contract shall, upon the expiration
of said ten (10) days, cease and terminate. In the event of any such termination, CITY shall immediately
serve notice thereof upon CONTRACTOR'S surety and CONTRACTOR, and the surety shall have the
right to take over and perform the Contract; provided, however, that, if the surety within fifteen (15) days
after the serving upon it of notice of termination does not give CITY written notice of its intention to take
over and perform the Contract, or does not commence performance thereof within thirty (30) days from the
date of the serving of such notice, CITY may take over the work and prosecute the same to completion by
contract, or by any other method it may deem advisable, for the account and at the expense of
CONTRACTOR, and CONTRACTOR AND CONTRACTOR'S surety shall be liable to CITY for any
excess cost occasioned by CITY thereby, and in such event CITY may, without liability for so doing, take
possession of, and utilize in completing the work, such materials, appliances, plant and other property
belonging to CONTRACTOR as may be on the site of the work and necessary therefor.
13. THE CITY'S RIGHT TO WITHHOLD CERTAIN AMOUNTS AND MAKE APPLICATION
THEREOF. In addition to amounts which CITY may retain under other provisions of the Specifications
until final completion and acceptance of all work covered by the Contract, CITY may withhold from
payment to CONTRACTOR such an amount or amounts as in its judgment may be necessary to pay just
claims against CONTRACTOR or subcontractors for labor and services rendered and materials furnished
in and about the work.
City may apply such withheld amount or amounts to the payment of such claims in its discretion.
In doing so, CITY shall be deemed the agent of CONTRACTOR, and any payment so made by
CITY shall be considered as a payment made under the Contract by CITY to CONTRACTOR,
and CITY shall not be liable to CONTRACTOR for any payment made in good faith. Such
payment may be made without prior judicial determination of the claim or claims.
Contract Page 3 of 6
With respect to any retention of payment by CITY to ensure performance of the Contract,
CONTRACTOR will be entitled to substitute securities as provided in Section 4590 of the
California Government Code as more fully described in CITY'S Notice to Contractors.
14. NOTICE AND SERVICE THEREOF. Any notice from one party to the other under
this Contract shall be in writing, and shall be dated and signed either by the party giving such
notice, or by a duly authorized representative of such party. Any such notice shall not be effective
for any purpose whatsoever unless served in the following manner: (a) if the notice is given to
CITY, either by personal delivery thereof to the Engineer of CITY, or by depositing same in the
United States mails, enclosed in a sealed envelope, addressed to CITY OF CUPERTINO; 10300
TORRE AVENUE; CUPERTINO, CA 95014; postage prepaid and certified; (b) if the notice is
given to CONTRACTOR, either by personal delivery thereof to CONTRACTOR, or to
CONTRACTOR'S duly authorized representative at the site of the project, or by depositing same
in the United States mails enclosed in a sealed envelope, addressed to, 10950 NO. BLANEY
AVE, CUPERTINO, CA 95014 postage prepaid and certified; and (c) if notice is given to
CONTRACTOR'S surety or any other person, either by personal delivery thereof to
CONTRACTOR'S surety or other person, or by depositing same in the United States mails,
enclosed in a sealed envelope, addressed to CONTRACTOR'S surety or person, as the case may
be, at the address of CONTRACTOR'S surety or the address of the person last communicated by
such person to the party giving the notice, postage prepaid and certified.
15. ASSIGNMENT OF CONTRACT. Neither the Contract, nor any part thereof, nor
moneys due or to become due thereunder, shall be assigned by CONTRACTOR without the prior
written approval of CITY.
16. COMPLIANCE WITH SPECIFICATIONS OF MATERIALS. Whenever in the
Specifications, any material or process is indicated or specified by patent or proprietary name, or
by name of manufacturer, such Specifications must be met by CONTRACTOR, unless CITY
agrees in writing to some other material, process or article offered by CONTRACTOR which is
equal in all respects to the one specified. It shall be CONTRACTOR'S responsibility to prove
equality of any such material, process or article offered as a substitution to the one(s) specified.
17. WORKER'S COMPENSATION INSURANCE AND EMPLOYER'S LIABILITY
INSURANCE. CONTRACTOR shall take out and maintain during the life of this Contract
Worker's Compensation Insurance and Employer's Liability Insurance for all of
CONTRACTOR'S employees employed at the site of the project. In case any work is sublet,
CONTRACTOR shall require any and all subcontractors similarly to provide Worker's
Compensation and Employer's Liability Insurance for all of the latter's employees unless such
employees are covered by the protection afforded to the CONTRACTOR.
In signing this Contract CONTRACTOR makes the following certification, required by Section
1861 of the Labor Code: "I am aware of the provisions of Section 3700 of the Labor Code which
requires every employer to be insured against liability for worker's compensation or to undertake
self insurance in accordance with the provisions of the Labor Code, and I will comply with such
provisions before commencing the performance of the work of this Contract."
Contract Page 4 of 6
18. ACCIDENT PREVENTION. Precaution shall be exercised at all times for the protection
of persons (including employees) and property. The safety provisions of applicable laws, building
codes and construction codes shall be observed. Machinery, equipment and other hazards shall be
guarded or eliminated in accordance with the safety provisions of the Construction and Safety
Orders issued by the Industrial Accident Commission of the State of California.
19. CONTRACTOR'S RESPONSIBILITY FOR THE WORK. CONTRACTOR shall
not be responsible for the cost of repairing or restoring damage to the work caused by Acts of
God. NEVERTHELESS, CONTRACTOR shall, if the insurance premium is a separate bid item,
obtain the insurance to indemnify CITY for any damage to the work caused by Acts of God.
"Acts of God" shall include only the following occurrences or conditions and effects: earthquakes
and tidal waves, when such occurrences or conditions and effects have been proclaimed a disaster
or state of emergency by the President of the United States or by the Governor of the State of
California, or were of a magnitude at the site of the work sufficient to have caused a proclamation
of disaster or state of emergency having occurred in a populated area. Subject to the foregoing,
CITY shall not, in any way or manner, be answerable or suffer loss, damage, expense or liability
for any loss or damage that may happen to said building, work, or equipment or any part thereof,
or in, on, or about the same during its construction and before acceptance.
20. CONTRACTOR'S GUARANTEE. CONTRACTOR unqualifiedly guarantees the
first-class quality of all work and of all materials, apparatus and equipment used or installed by
CONTRACTOR or by any subcontractor or supplier in the project which is the subject of this
Contract, unless a lesser quality is expressly authorized in the Plans and Specifications, in which
event CONTRACTOR unqualifiedly guarantees such lesser quality; and that the work as
performed by CONTRACTOR will conform with the Plans and Specifications or any written
authorized deviations therefrom. In case of any defect in the work, materials, apparatus or
equipment, whether latent or patent, revealed to CITY within one (1) year of the date of
acceptance of completion of this Contract by CITY, CONTRACTOR will forthwith remedy such
defects without cost to CITY.
Contract Page 5 of 6
P.O. No.
21. DEFERRED ALTERNATE SELECTION. The City reserves the right for the term of
the Contract, the deferred selection of none, any or all alternate bid items at the bid price. The
alternates chosen would be for any sites currently under construction or to be constructed in the
future.
IN WITNESS WHEREOF, the parties have executed this Contract, in duplicate, the day and
year first hereinabove written.
CITY OF CUPERTINO:
By:
_ ri
ity anager
Attest: ,
City rk
Date: '170-0 13 , 19 q?
City Clerk
CONTRACTOR:
Jensen Corporation
John Vla , Vice President
By:
Notary ac owledgm nt is required. If a
corporatio , corporate seal and corporate
notary acknowledgment and Federal Tax
I.D. are required. If not a corporation a
Social Security No. is required.
94-1689681
Social Security # Federal Tax I.D. #
APPROVED AS TO FORM:
Contractor's License No. 259540
City Attorn
Project Name & Number: Landscape Renovation at Robert W. Quinlan
Community Center, Project 97-108
Contractor's Name & Address: Jensen Corporation Landscape Contractors
10950 No. Blaney Avenue
Cupertino, CA 95014
Contract Amount: $43,768.00
Account Number: 110-8303-943
File No: 92,008.13C
Contract Page 6 of 6
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
State of (1� /, �r-n I Q
County of a 4,1 (2 (�4
On ► T° 9
DATE
personally appeared
before me, '&114 L) _ :?�, '" _P11L11 e
NAME, TITLE OF OFFIC�G., "JANE DOE, NQfARY PUBLIC'
1-1
OF SIGNER(S)
personally known to me - OR - ❑ proved to me on the basis of satisfactory evidence
to be the person(s) whose name(s) is/are
subscribed to the within instrument and ac-
knowledged to me that he/she/they executed
the same in his/her/their authorized
'ounlrrtnuutYnuntntR#Isaaarayllwr/uu capacity (i e s) , and that by his/her/their
g DAVID W. PERRY 5 signature(s) on the instrument the person(s),
COMM. # 1008437 s
NOTARY PUBUC_CALIFORIRA or the entity upon behalf of which the
COUNTY Of SANrA CLARA
s
Comm. Eva. Nov, Q, 1997 person(s) acted, executed the instrument.
Ott/ItU/1#1/6Rte!!#!!#;rHtef°#!t•#rt1!!tt!!tlltit�
WITNESS hand and official seal.
SIGNATURE OF NOTARY
OPTIONAL
No. 5907
Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent
fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ INDIVIDUAL
❑ CORPORATE OFFICER
TITLE(S)
❑ PARTNER(S) ❑ LIMITED
❑ GENERAL
❑ ATTORNEY-IN-FACT
❑ TRUSTEE(S)
❑ GUARDIAN/CONSERVATOR
❑ OTHER:
SIGNER IS REPRESENTING:
NAME OF PERSON(S) OR ENTITY(IES)
DESCRIPTION OF ATTACHED DOCUMENT
TITLE OR TYPE OF DOCUMENT
NUMBER OF PAGES
DATE OF DOCUMENT
SIGNER(S) OTHER THAN NAMED ABOVE
01993 NATIONAL NOTARY ASSOCIATION • 8236 Remmet Ave., P.O. Box 7184 • Canoga Park, CA 91309-7184
Jensen Corporation
I, the undersigned, agree that if this proposal is accepted, I will enter into a contract with the City
of Cupertino to provide all necessary machinery, tools, apparatus, and other means of
construction and to do all the work specified in the contract in the manner and time specified.
I, the undersigned, declare that this bid is made without connection with any person, firm, or
corporation making a bid for the same work, and is in all respects fair, and without collusion or
fraud.
I, the undersigned, recognize that the Director of Public Works of the City of Cupertino will
reserve the right to establish the priority of one job over another and each starting date where
conflict of construction schedules occur.
Attached hereto is the required certified check or id bon in the amount of $ . 10 % , as
required by law and the Notice to Bidders. (10% of bid amount)
BID PROPOSAL PAGE 3 OF 8
Jensen Corporation
NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY
BIDDER AND SUBMITTED WITH BID
I, the undersigned, being first duly sworn, depose and say that I am L Vl�,�
John 'ia,�
Vice President of Jensen Corpora ion
(Business Title) (Business N e)
the party making the foregoing bid, that the bid is not made in the interest of, or on behalf c� sny
undisclosed person, partnership, company, association, organization, or corporation. The '--Id M
genuine and not collusive or sham. The bidder has not directly or indirectly induced or soy c ted
any other bidder to put in a false or sham bid, and has not directly or indirectly coD.:ck:d,
conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that = r:nc
shall refrain from bidding. The bidder has not in any manner, directly or indirectly, sougi:i 7y
agreement, communication, or conference with anyone to fix the bid price of the bidder cr any
other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that cf my
other bidder, or to secure any advantage against the public body awarding the contract of =i":nr.
interested in the proposed contract. All statements contained in the bid are true and, further_ ric
bidder has not, directly or indirectly, submitted the bid price or any breakdown there --f- (-)r
contents thereof, or divulged information or data relative thereto, or paid, and will not pa4. 3rry
fee to any corporation, partnership, company, association, organization, bid depository, or :c Liy
member or agent thereof to effectuate a collusive or sham bid.
BID PROPOSAL PAGE 4 OF 8
Jensen Corporation
BIDDER QUALIFICATION FORM
i�p
In further compliance with the specifications furnished, I; the undersigned, submit the following
statements as to my experience and qualifications to perform this work as a part of this proposal.
We have been in business under the present name for 28 years.
Our experience in work comparable with that required by the proposal contract is 28.
years operating under the following different name(s). "
Jensen Corporation Landscape Contractors
My California Contractor's License Number is
259540
The classification of my Contractor's License is A C-27
The expiration date for my Contractor's License is 4/30/98
(This Section for City use only)
The above information has been verified by �Qln !�
on
Contractors State License Board (800) 321-2752 or (408) 277-1244.
******************************************************************************
Where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder
to be licensed in accordance with the laws of the State of California, however, at the time the
contract is awarded the contractor shall be properly licensed.
BID PROPOSAL PAGE 5 OF 8
Jensen Corporation
BIDDER HISTORY OF WORK
The following is an example of work similar in character to that required in the proposed contract
which our organization or personnel in our organization has completed within the past three (3)
years.
For Whom Contact
Year Location Type of Work Performed Phone No. Amount
Please see attached list
BID PROPOSAL PAGE 6 OF 8
EXHIBIT A
Parks and Athletic Fields
Plata Arroyo Park, San Jose
............................................................................ $492,000.00
Landscape Architect:
City of San Jose
General Contractor:
Jensen Corporation
Mountain View Sports Complex, Mountain View ............................................. $134,000.00
Landscape Architect:
Sigimura Associates
General Contractor:
Blach Construction
Cupertino Nine School Fields, Cupertino........................................................ $3,434,000.00
Landscape Architect: Beals Landscape Architecture
General Contractor: Jensen Corporation
Vintage Lake, Foster City............................................................................. $865,430.00
Landscape Architect: KenKay Associates
General Contractor: Jensen Corporation
Centrum Linear Park, Redwood City.............................................................. $1,354,000.00
Landscape Architect: Amphion
General Contractor: Jensen Corporation
Stanford Stadium World Cup Installation, Stanford ...................................... $170,077.00
Landscape Architect: World Cup
General Contractor: Jensen Corporation
Milpitas Sports Center, Milpitas.................................................................. $185,347.00
Landscape Architect: Dillingham Associates
General Contractor: G. Swanson Construction
Columbia School, Sunnyvale......................................................................... $266,222.00
Landscape Architect: Beals Landscape Architecture
General Contractor: Jensen Corporation
Franklin School Ballfield, Burlingame......................................................... $167,906.00
Landscape Architect: Callander Associates
General Contractor: Jensen Corporation
Fremont Park, Menlo Park.............................................................................. S165,404.00
Landscape Architect: Ciardella Associates
General Contractor: Jensen Corporation
Jensen Corporation
SUBCONTRACTOR'S FORM
The subcontractor(s), as defined in the General Provisions and in Section 7026 of the California
Business and Professions Code, that I propose to hire to perform any of the work for this project
in an amount in excess of one-half of one percent (0.5%) of the total bid are listed below. Only
those listed below shall perform work on this project and each of them has been provided with a
full and complete set of plans and specifications for this project by the bidder.
1.
Name
Address
Work to be Performed
2.
Name
Address
Work to be Performed
3.
Name
Address
Work to be Performed
4.
Name
Address
Work to be Performed.
5.
Name
Address
Work to be Performed
6.
Name
Address
Work to be Performed
NONE
BID PROPOSAL PAGE 7 OF 8
Jensen Corporation
BIDDER'S SIGNATURE FORM
IF YOU ARE AN INDIVIDUAL, SO STATE. IF YOU ARE A COMPANY OR A CO-
PARTNERSHIP, STATE THE COMPANY NAME AND LIST THE NAMES OF ALL
INDIVIDUAL CO-PARTNERS COMPOSING THE COMPANY. IF YOU ARE A
CORPORATION, STATE THE LEGAL NAME OF THE CORPORATION AND THE
NAMES OF THE PRESIDENT, SECRETARY -TREASURER, AND MANAGER. THE
CORPORATE SEAL MUST BE AFFIXED TO THIS FORM. ENTER THE NAME OF YOUR
BUSINESS ON THE LINE OPPOSITE THE APPROPRIATE BUSINESS TYPE.
TYPE OF
BUSINESS Corporation
CORPORATION: X
CO -PARTNERSHIP:
INDIVIDUAL:
JOINT VENTURE:
Name and Signature of Bidder:
Date: 9/9/97
NAME OF
BUSINESS Jensen Corporation Landscape
Contractors
(Describe)
ortypename) John Vlay, Vice President
Address (mailing & location): 10950 IN. Blaney Ave.
Telephone Number: (40g 446-1118
Acknowledgment of all addenda received is required by circling each addendum number.
2 3 4 5 6 7 8 9 10
Mandatory Pre -Bid Meeting Attendance
Mike D a 1 ke
Name of Attendee
BID PROPOSAL PAGE 8 OF 8
RECORDING REQUESTED BY
City of Cupertino
WHEN RECORDED MAIL TO
City of Cupertino
10300 Torre Avenue
Cupertino, CA 95014
N0 FEE IN ACCORDANCE
WITH 60V CODE 61®3
DOCUMENT: 14096476 Titles:1 / Pages: 3
Fees....* No Fees
Taxes...
11111111111111111111111111111111 Copies..
A0014096476A AMT PAID
BRENDA DAVIS RDE # 006
SANTA CLARA COUNTY RECORDER 3/16/1998
Recorded at the request of 4:23 PM
City
%%-og3
(SPACE ABOVE THIS LINE FOR RECORDER'S USE)
CERTIFICATE OF COMPLETION AND NOTICE OF ACCEPTANCE OF COMPLETION
LANDSCAPE RENOVATION AT ROBERT W. QUINLAN COMMUNITY CENTER,
PROJECT NO. 97-108
ORG[ltlL
SEPARATE PAGE PURSUANT TO GOVT. CODE 27316.6
City of
Cupertino
City Hall
10300 Torre Avenue
Cupertino, CA 95014-3255
(408) 777-3354
FAX (408) 777-3333
PUBLIC WORKS DEPARTMENT
CERTIFICATE OF COMPLETION
I�Mil
NOTICE OF ACCEPTANCE OF COMPLETION
LANDSCAPE RENOVATION AT ROBERT W. QUINLAN COMMUNITY
CENTER, PROJECT NO. 97-108
NOTICE IS HEREBY GIVEN THAT I, Bert J. Viskovich, Director of Public Works and City
Engineer of the City of Cupertino, California, do hereby certify that the work and improvements
hereinafter described, the contract for doing which was entered into by and between the City of
Cupertino and Jensen Corporation Landscape Contractors on October 29, 1997, in accordance with the
plans and specifications for said work, have been completed to my satisfaction and acceptance is made
as of March 6, 1998.
That said work and improvements consisted of furnishing all labor, materials, tools, and
equipment required to complete said project, all as more particularly described in the plans and
specifications for said project.
Date: March 6, 1998
Printed on Recycled Paper
o`f Pulfiic Works and
ineer f the City of Cupertino
VERIFICATION
I have reviewed this Certificate of Completion and to the best of my lalowledge, the
information contained herein is true and complete.
I verify under penalty of perjury under the laws of the State of California, that the
foregoing is true and correct.
Executed on the 1 Ith day of March 1998 at Cupertino, California.
r�
Deputy City Clerk
City of Cupertino