Loading...
20-114 Bear Electrical Solutions, Inc., Civic Center Conduit InstallationPublic Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 1 of 12 PUBLIC WORKS CONTRACT $60,000 OR LESS 1. PARTIES This public works contract (“Contract”) is made by and between the City of Cupertino (“City”), Bear Electrical Solutions, Inc., a Corporation (“Contractor”) for Civic Center Conduit Installation , and is effective on the last date signed below (“Effective Date”). 2. SCOPE OF WORK Contractor will perform and provide all labor, materials, equipment, supplies, transportation and any other items or work necessary to perform and complete the work required for the Project (“Work”), as required in the Scope of Work, attached here and incorporated as Exhibit A, and in accordance with the terms and conditions of this Contract. Contractor further agrees to carry out its work in compliance with the City’s Shelter In Place and Social Distancing Requirements, attached here and incorporated as Exhibit A-A. 3. TIME FOR COMPLETION 3.1 Term. This Contract begins on the Effective Date and ends on December 31, 2020 (“Contract Time”) unless terminated earlier as provided herein. Contractor’s Work shall begin on the date shown on a written Notice to Proceed (“NTP”) and must be fully completed within the Contract Time or on the date specifically provided in the Notice to Proceed. The City Engineer will not issue a NTP until the Contract is fully executed by both parties and City has received satisfactory proof of insurance and any performance and payment bonds that may be required. The Director of Public Works may authorize the extension of the Contract Time by up to sixty (60) calendar days through a written amendment to this Agreement, provided such extension does not include additional contract funds. 3.2 Time is of the essence for Contractor’s performance and completion of the Work. Contractor must have sufficient time, resources, and qualified staff to deliver the work on time. 3.3 Liquidated damages of $200.00 will be charged for each day of unexcused delay, or City may deduct the amount from Contractor’s payments. Liquidated damages are based on reasonably foreseeable consequences of delay and may include intangible losses which the Parties agree may be difficult to ascertain, such as loss of public confidence in City and its contractors, interference or loss of use of public facilities, and extended disruption to the public. 4. COMPENSATION 4.1 Maximum Compensation. City will pay Contractor for satisfactory performance of the Work an amount that will based on actual costs but that will be capped so as not to exceed $15,000.00 (“Contract Price”), for all of Contractor’s direct and indirect costs, including all labor, Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 2 of 12 materials, supplies, equipment, taxes, insurance, bonds, and all overhead costs. 4.2 Invoices and Payments. Contractor must submit an invoice on the first day of each month, describing the Work performed during the preceding month, itemizing labor, materials, equipment and any incidental costs incurred. Contractor will be paid ninety-five percent (95%) of the undisputed amounts billed within thirty (30) days after City receives a properly submitted invoice. Any retained amounts will be included with Contractor’s final payment within sixty (60) days of City’s acceptance of the Work as complete. 5. INDEPENDENT CONTRACTOR 5.1 Status. Contractor is an independent contractor and not an employee of City. Contractor is solely responsible for the means and methods of performing the Work and for the persons under this employment. Contractor is not entitled to worker’s compensation or any other City benefits. 5.2 Contractor’s Qualifications. Contractor warrants on behalf of itself and its subcontractors that they have the qualifications and skills to perform the Work in a competent and professional manner and according to the highest standards and best practices in the industry. 5.3 Permits and Licenses. Contractor warrants on behalf of itself and its subcontractors that they are properly licensed, registered, and/or certified to perform the Work as required by law, and have procured a City Business License, if required by the Cupertino Municipal Code. Contractor shall possess a California Contractor’s License in good standing for the following classification(s): C10, A, C31, C61/D31, which must remain valid for the entire Contract Time. 5.4 Subcontractors. Only Contractor’s employees are authorized to work under this Contract. Prior written approval from City is required for any subcontractor, and the terms and conditions of this Contract will apply to any approved subcontractor. 5.5 Tools, Materials, and Equipment. Contractor will supply all tools, materials and equipment required to perform the Work under this Contract. 5.6 Payment of Benefits and Taxes. Contractor is solely responsible for the payment of employment taxes incurred under this Agreement and any similar federal or state taxes. Contractor and any of its employees, agents, and subcontractors shall not have any claim under this Agreement or otherwise against City for seniority, vacation time, vacation pay, sick leave, personal time off, overtime, health insurance, medical care, hospital care, insurance benefits, social security, disability, unemployment, workers compensation or employee benefits of any kind. Contractor shall be solely liable for and obligated to pay directly all applicable taxes, fees, contributions, or charges applicable to Contractor’s business including, but not limited to, federal and state income taxes. City shall have no obligation whatsoever to pay or withhold any taxes or benefits on behalf of Contractor. Should any court, arbitrator, or administrative authority, including but not limited to the California Public Employees Retirement System (PERS), the Internal Revenue Service or the State Employment Development Division, determine that Contractor, or any of its employees, agents, or subcontractors, is an employee for any purpose, then Contractor agrees to a reduction in amounts payable under this Agreement, or to promptly remint to City any payments due by the City as a result of such determination, so that the City’s total expenses under this Agreement are not greater Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 3 of 12 than they would have been had the determination not been made. 6. CHANGE ORDERS Amendments and change orders must be in writing and signed by City and Contractor. Contractor’s request for a change order must specify the proposed changes in the Work, Contract Price, and Contract Time. Each request must include all the supporting documentation, including but not limited to plans/drawings, detailed cost estimates, and impacts on schedule and completion date. 7. ASSIGNMENTS; SUCCESSORS Contractor shall not assign, hypothecate, or transfer this Contract or any interest therein, directly or indirectly, by operation of law or otherwise, without prior written consent of City. Any attempt to do so will be null and void. Any changes related to the financial control or business nature of Contractor as a legal entity is considered an assignment of the Contract and subject to City approval, which shall not be unreasonably withheld. Control means fifty percent (50%) or more of the voting power of the business entity. This Contract is binding on Contractor, its heirs, successors, and permitted assigns. 8. PUBLICITY / SIGNS Any publicity generated by Contractor for the Project during the Contract Time, and for one (1) year thereafter must credit City contributions to the Project. The words “City of Cupertino” must be displayed in all pieces of publicity, flyers, press releases, posters, brochures, interviews, public service announcements, and newspaper articles. No signs may be posted or displayed on or about City property, except signage required by law or this Contract, without prior written approval from the City. 9. SUBCONTRACTORS 9.1 Contractor must perform all the Work with its own forces, except that Contractor may hire qualified subcontractors to perform up to 25% of the Work, provided that each subcontractor is required by contract to be bound by the provisions of this Contract. Contractor must provide City with written proof of compliance with this provision upon request. 9.2 City may reject any subcontractor of any tier and bar a subcontractor from performing Work on the Project, if City in its sole discretion determines that subcontractor’s Work falls short of the requirements of this Contract or constitutes grounds for rejection under the Public Contract Code. If City rejects a subcontractor, Contractor at its own expense must perform the subcontractor’s Work or hire a new subcontractor that is acceptable to City. A Notice of Completion must be recorded within fifteen (15) days after City accepts the Work if the Contract involves work by subcontractors. 10. RECORDS AND DAILY REPORTS 10.1 Contractor must maintain daily reports of the Work and submit them to City upon request and at completion of Project. The reports must describe the Work and specific tasks performed, the number of workers, the hours, the equipment, the weather conditions, and any circumstances affecting performance. City will have ownership of the reports, but Contractor will be permitted to retain copies. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 4 of 12 10.2 If applicable, Contractor must keep a separate set of as-built drawings showing changes and updates to the Scope of Work or the original drawings as changes occur. Actual locations to scale must be identified for all major components of the Work, including mechanical, electrical and plumbing work; HVAC systems; utilities and utility connections; and any other components City determines should be included in the final drawings of the Project. Deviations from the original drawings must be shown in detail, and the location of all main runs, piping, conduit, ductwork, and drain lines must be shown by dimension and elevation. 10.3 Contractor must maintain complete and accurate accounting records of its Work, in accordance with generally accepted accounting principles, which must be available for City review and audit, kept separate from other records, and maintained for four (4) years from the date of City’s final payment. 11. INDEMNIFICATION 11.1 To the fullest extent allowed by law, and except for losses caused by the sole and active negligence or willful misconduct of City personnel, Contractor shall indemnify, defend, and hold harmless City, its City Council, boards and commissions, officers, officials, employees, agents, servants, volunteers and consultants (“Indemnitees”), through legal counsel acceptable to City, from and against any and all liability, damages, claims, stop notices, actions, causes of action, demands, charges, losses and expenses (including attorney fees, legal costs, and expenses related to litigation and dispute resolution proceedings), of every nature arising directly or indirectly from this Contract or in any manner relating to any of the following: (a) Breach of contract, obligations, representations or warranties; (b) Performance or nonperformance of the Work or of any obligations under the Contract by Contractor, its employees, agents, servants, subcontractors or subcontractors; (c) Payment or nonpayment by Contractor or its subcontractors or sub-subcontractors for Work performed on or off the Project Site; and (d) Personal injury, property damage, or economic loss resulting from the work or performance of Contractor or its subcontractors or sub-subcontractors. 11.2 Contractor must pay the costs City incurs in enforcing this provision. Contractor must accept a tender of defense upon receiving notice from City of a third-party claim, in accordance with California Public Contract Code Section 9201. At City’s request, Contractor will assist City in the defense of a claim, dispute, or lawsuit arising out of this Contract. 11.3 Contractor’s duties under this entire Section 11 are not limited to Contract Price, Workers’ Compensation, or other employee benefits, or the insurance and bond coverage required in this Contract. Nothing in the Contract shall be construed to give rise to any implied right of indemnity in favor of Contractor against City or any other Indemnitee. 11.4 Contractor’s payments may be deducted or offset to cover any money the City lost due to a claim or counterclaim arising out of this Contract, a purchase order or other transaction. 11.5 Contractor agrees to obtain executed indemnity agreements with provisions identical to those set forth here in this Section 11 from each and every subcontractor, or any other person or entity involved by, for, with, or on behalf of Contractor in the performance of this Agreement. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 5 of 12 Failure of City to monitor compliance with these requirements imposes no additional obligations on City and will in no way act as a waiver of any rights hereunder. 11.6 This Section 11 shall survive termination of the Contract. 12. INSURANCE Contractor shall comply with the Insurance Requirements, attached and incorporated here as Exhibit B. Contractor must provide satisfactory proof of insurance and maintain it for the Contract Time or longer as required by City. City will not execute the Contract until City has approved receipt of satisfactory certificates of insurance and endorsements evidencing the type, amount, class of operations covered, and the effective and expiration dates of coverage. Failure to comply with this provision may result in City, at its sole discretion and without notice, purchasing insurance at Contractor’s expense, deducting the costs from Contractor’s compensation, or terminating the Contract. 13. COMPLIANCE WITH LAWS 13.1 General Laws. Contractor shall comply with all laws and regulations applicable to this Contract. Contractor will promptly notify City of changes in the law or other conditions that may affect the Project or Contractor’s ability to perform. Contractor is responsible for verifying the employment status of employees performing the Work, as required by the Immigration Reform and Control Act 13.2 Labor Laws. (a) The following provisions apply to contracts of $1,000 or more: (i) In General. For purposes of California labor law, this is a public works contract subject to the provisions of Part 7 of Division 2 of the California Labor Code (Sections 1720 et seq.). In accordance with Labor Code Section 1771, Contractor and all subcontractors shall pay not less than current prevailing wage rates as determined by the California Department of Industrial Relations (“DIR”) to all workers employed on this project. In accordance with Labor Code Section 1815, Contractor and all subcontractors shall pay all workers employed on this project 1 ½ the basic rate of pay for work performed in excess specified hour limitations. The work performed pursuant to this Contract is subject to compliance monitoring and enforcement by the Department of Industrial Relations. (ii) Registration. Contractor and all subcontractors shall not engage in the performance of any work under this Contract unless currently registered and qualified to perform public work pursuant to section 1725.5 of the California Labor Code. Contractor represents and warrants that it is registered and qualified to perform public work pursuant to section 1725.5 of the Labor Code and will provide its DIR registration number, along with the registration numbers of any subcontractors as required, to the City. (iii) Posting. Contractor shall post at the job site the determination of the DIR Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 6 of 12 director of the prevailing rate of per diem wages together with all job notices that are required by regulations of the DIR. (iv) Reporting. Contractor and any subcontractors shall keep accurate payroll records in accordance with Section 1776 of the Labor Code and shall furnish the payroll records directly to the Labor Commissioner in accordance with the law. (v) Report on Prevailing Rate of Wages. The City has obtained the general prevailing rate of per diem wages in the vicinity of the project for each type of worker needed, a copy of which is on file at the City of Cupertino City Hall, and shall be made available to any interested party upon request. (vi) Employment of Apprentices. Contractor’s attention is directed to the provisions in Sections 1777.5 and 1777.6 of the Labor Code concerning the employment of apprentices by the Contractor or any subcontractor. It shall be the responsibility of the Contractor to effectuate compliance on the part of itself and any subcontractors with the requirements of said sections in the employment of apprentices. Information relative to apprenticeship standards, wage schedules, and other requirements may be obtained from the Director of Industrial Relations, ex-officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. (vii) Penalties. Contractor’s attention is directed to provisions in Labor Code Sections 1775 and 1813. In accordance with Labor Code Section 1775, Contractor and subcontractors may be subject to penalties for Contractor’s and subcontractors’ failure to pay prevailing wage rates. In accordance with Labor Code Section 1813, Contractor or subcontractors may be subject to penalties for Contractor’s or subcontractors’ failure to pay overtime pay rates for hours worked by workers employed on this project in excess specified hour limitations. (b) Contractor must compensate workers who are paid less than prevailing wages or required to work more than a legal day’s work. Contractor will also be required to pay City a penalty of $200.00 per worker for each day of violation. (c) As required by Labor Code Section 1861, by signing this Contract Contractor certifies as follows: “I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers’ compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the work of this contract.” 13.3 Discrimination Laws. Contractor shall not discriminate on the basis of race, religious creed, color, ancestry, national origin, ethnicity, handicap, disability, marital status, pregnancy, age, sex, gender, sexual orientation, gender identity, Acquired-Immune Deficiency Syndrome (AIDS), or any other protected classification. Contractor shall comply with all anti-discrimination laws, including Government Code Sections 12900 and 11135, and Labor Code Sections 1735, 1777, and 3077.5. Consistent with City policy prohibiting harassment and discrimination, Contractor understands that harassment and discrimination directed toward a job applicant, an employee, a City employee, or any other person, by Contractor or Contractor's employees or sub-contractors will not be tolerated. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 7 of 12 13.4 Conflicts of Interest. Contractor, its employees, subcontractors, servants and agents, may not have, maintain or acquire a conflict of interest in relation to this Contract in violation of law, including Government Code section 1090 and Government Code section 81000 and their accompanying regulations. No officer, official, employee, consultant, or other agent of the City (“City Representative”) may have, maintain, or acquire a “financial interest” in the Contract, as that term is defined by state law, or in violation of a City ordinance or policy while serving as a City Representative or for one year thereafter. Contractor, its employees, subcontractors, servants, and agents warrant they are not employees of City nor do they have an y relationship with City officials, officers, or employees that creates a conflict of interest. Contractor may be required to file a conflict of interest form if it makes certain governmental decisions or serves in a staff capacity, as defined in Section 18700 of Title 2 of the California Code of Regulations. Contractor agrees to abide by City rules governing gifts to public officials and employees. 13.5 Remedies. Any violation of Section 13 constitutes a material breach and may result in City suspending payments, requiring reimbursement, or terminating the Contract. City reserves all rights and remedies under the law and this Contract, including seeking indemnification. 14. BONDS For contracts of $25,000 or more, Contractor must obtain a payment bond and a performance bond, each in the penal sum of 100% of the Contract Price, using the Bond Forms attached and incorporated here as Exhibit C. Each bond must be issued by a surety admitted in California, with a financial rating from A.M. Best Company of Class A- or higher, or as otherwise acceptable to City. If an issuing surety cancels a bond or becomes insolvent, Contractor must provide a substitute bond from a surety acceptable to City within seven (7) calendar days after written notice from City. If Contractor fails to do so, City may in its sole discretion and without prior notice, purchase bonds at Contractor’s expense, deduct the cost from payments due Contractor, or terminate the Contract. City will not execute the Contract nor issue the NTP until the required bonds are submitted. 15. UTILITIES, TRENCHING, AND EXCAVATION 15.1 Contractor must call the Underground Service Alert (“USA”) 811 hotline and request marking of utility locations before digging or commencing Work. For underground service alerts for street lighting and traffic signal conduits, City’s Service Center must be called at (408) 777-3269. Government Code Section 4215 requires Contractor to notify City and Utility in writing if it discovers utilities or utility facilities not identified in the Contract. 15.2 Pursuant to Government Code Section 7104, Contractor must stop work, notify City in writing, and wait for instructions if one of the conditions below is found at the worksite. City will work with Contractor to amend the Contract or issue a change order if the discovered conditions materially change the Work/Performance, Contract Time or Contract Price. (a) Material believed to be hazardous waste under Health and Safety Code Section 25117, and which requires removal to a Class I, Class II, or Class III disposal site pursuant to law; (b) Subsurface or latent physical conditions at the Project worksite differing from those indicated by information about the worksite made available to Contractor; and Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 8 of 12 (c) Unknown physical conditions at the Project worksite of any unusual nature, materially different from those ordinarily encountered and from those generally recognized as inherent in the character of the Work. 15.3 For contracts $25,000 or higher that require excavation or involve trenches five feet or more in depth, Contractor must submit a detailed plan for City approval, per Labor Code Section 6705, prior to commencing work. The plan must show the design of shoring, bracing, sloping, and other provisions for worker protection from caving ground and other hazards. The protective system must comply with all Construction Safety Orders. If the plan varies from shoring system standards, it must be prepared by a registered civil or structural engineer. 16. URBAN RUNOFF MANAGEMENT 16.1 All Work must fully comply with federal, state, and local laws and regulations concerning storm water management. Contractor must avoid creating excess dust when breaking asphalt or concrete and during excavation and grading. If water is used for dust control, Contractor will use only the amount of water necessary to dampen the dust. Contractor will take all steps necessary to keep wash water out of the streets, gutters, and storm drains. Prior to the start of the Work, Contractor will implement erosion and sediment controls to prevent pollution of storm drains, and must upgrade and maintain these controls based on weather conditions or as otherwise required by City. These controls must be in place during the entire Contract Time and must be removed at the end of construction and completion of the Work. Such controls must include, but will not be limited to, the following requirements: (a) Install storm drain inlet protection devices such as sand bag barriers, filter fabric fences, and block and gravel filters at all drain inlets impacted by construction. During the annual rainy season, October 15 through June 15, storm drain inlets impacted by construction work must be filter-protected from onsite de-watering activities and saw-cutting activities. Shovel or vacuum saw-cut slurry and remove from the Work site; (b) Cover exposed piles of soil or construction material with plastic sheeting. Store all construction materials in containers; (c) Sweep and remove all materials from paved surfaces that drain to streets, gutters and storm drains prior to rain and at the end of each work day. When the Work is completed, wash the streets, collect and dispose of the wash water offsite in lawful manner; (d) After breaking old pavement, remove debris to avoid contact with rainfall/runoff; (e) Maintain a clean work area by removing trash, litter, and debris at the end of each work day and when Work is completed. Clean up any leaks, drips, and other spills as they occur. 16.2 These requirements must be used in conjunction with the California Stormwater Quality Association and California Best Management Practices Municipal and Construction Handbooks, local program guidance materials from municipalities, and any other applicable documents on stormwater quality controls for construction. Contractor’s failure to comply with this Section will result in the issuance of noncompliance notices, citations, Work stop orders and regulatory fines. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 9 of 12 17. PROJECT COORDINATION City Project Manager. City assigns Brad Alexander as the City representative for all purposes under this Contract, with authority to require compliance with the Scope of Work. City may substitute Project Managers at any time and without prior notice to Contractor. Contractor Project Manager. Subject to City approval, Contractor assigns Robert Asuncion as its single representative for all purposes under this Contract, with the responsibility to ensure progress with the Work. Contractor’s Project Manager is responsible for coordinating and scheduling the Work and must regularly update the City Project Manager about the status and any delays with the Work, consistent with the Scope of Work. Any substitutions must be approved in writing by City. 18. ABANDONMENT AND TERMINATION 18.1 City may abandon or postpone the Project or parts therefor at any time. Contractor will be compensated for satisfactory Work performed through the date of abandonment and will be given reasonable time to close out the Work. With City’s pre-approval in writing, the time spent in closing out the Work will be compensated up to ten percent (10%) of the total time expended in performing the Work. 18.2 City may terminate the Contract for cause or without cause at any time. Contractor will be paid for satisfactory Work rendered through the termination date and will be given reasonable time to close out the Work. 18.3 Final payment will not be made until Contractor delivers the Work and provides records documenting the Work, products and deliverables completed. Nothing in the Section below is intended to delay, abridge or bar City’s right under this Section. 19. GOVERNING LAW, VENUE AND DISPUTE RESOLUTION This Contract is governed by the laws of State of California. Venue for any legal action shall be the Superior Court of the County of Santa Clara, California. The dispute resolution procedures of Public Contract Code Section 20104, et seq., incorporated here by reference, apply to this Contract and Contractor is required to continue the Work pending resolution of any dispute. Prior to filing a lawsuit, Contractor must comply with the claim filing requirements of the California Government Code. If the Parties elect arbitration, the arbitrator’s award must be supported by law and substantial evidence and include detailed written findings of law and fact. 20. ATTORNEY FEES If City initiates legal action, files a complaint or cross-complaint, or pursues arbitration, appeal, or other proceedings to enforce its rights or a judgment in connection with this Contract, the prevailing party will be entitled to reasonable attorney fees and costs. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 10 of 12 21. SIGNS/ADVERTISEMENT No signs may be displayed on or about City’s property, except signage which is required by law or by the Contract, without City’s prior written approval as to size, design and location. 22. THIRD PARTY BENEFICIARIES There are no intended third party beneficiaries of this Contract. 23. WAIVER Neither acceptance of the Work nor payment thereof shall constitute a waiver of any contract provision. City waiver of any breach shall not constitute waiver of another provision or breach. 24. WARRANTY Contractor warrants that materials and equipment used will be new, of good quality, and free from defective workmanship and materials, and that the Work will be free from material defects not intrinsic in the design or materials. All Work, materials and equipment should pass to City free of claims, liens or encumbrances. Contractor warrants the Work and materials for one year from the date of City’s acceptance of the Work as complete (“Warranty Period”), except when a longer guarantee is provided by a supplier, manufacturer or is required by this Contract. During the Warranty Period, Contractor will repair or replace any Work defects or materials, including damage that arises from Contractor’s Warranty Work, except any wear and tear or damage resulting from improper use or maintenance. 25. ENTIRE CONTRACT This Contract and the attachments, documents, and statutes attached, referenced, or expressly incorporated herein, including authorized amendments or change orders constitute the final and complete contract between City and Contractor with respect to the Work and the Project. No oral contract or implied covenant will be enforceable against City. If there is any inconsistency between any term, clause, or provision of the main Contract and any term, clause, or provision of the attachments or exhibits thereto, the terms of the main Contract shall prevail and be controlling. 26. SEVERABILITY/PARTIAL INVALIDITY If a court finds any term or provision of this Contract to be illegal, invalid, or unenforceable, the legal portion of said provision and all other contract provisions will remain in full force and effect. 27. SURVIVAL The contract provisions which by their nature should survive the Contract or Completion of Project, including without limitation all provisions regarding warranties, indemnities, payment obligations, insurance, and bonds, shall remain in full force and effect after the Work is completed or Contract ends. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 11 of 12 28. INSERTED PROVISIONS Each provision and clause required by law to be inserted in this Contract will be deemed to be included and will be inferred herein. Either party may request an amendment to cure mistaken insertions or omissions of required provisions. 29. CAPTIONS The captions, titles, and headings in this Contract are for convenience only and may not be used in the construction or interpretation of the Contract or for any other purpose. 30. COUNTERPARTS This Contract may be executed in counterparts, each of which is an original and all of which taken together shall form one single document. 31. NOTICES All notices, requests, and approvals must be sent in writing to the persons below and will be considered effective on the date of personal delivery, the date confirmed by a reputable overnight delivery service, on the fifth (5th) calendar day after deposit in the United States Mail, postage prepaid, registered or certified, or the next business day following electronic submission: To City of Cupertino: Office of the City Manager 10300 Torre Ave., Cupertino CA 95014 cc: Representative/Coordinator: Brad Alexander Email: brada@cupertino.org To Contractor: Bear Electrical Solutions, Inc. PO Box 924, 1341 Archer St Alviso, CA 95002 cc: Representative/Coordinator: Robert Asuncion Email: robert@bear-electrical.com 32. VALIDITY OF CONTRACT This Contract is valid and enforceable only if (a) it complies with the purchasing and contract provisions of Cupertino Municipal Code Chapters 3.22 and 3.23, (b) is signed by the City Manager or an authorized designee, and (c) is approved for form by the City Attorney’s Office. 33. EXECUTION The persons signing below warrant they have the authority to enter into this Contract and to legally bind their respective Parties. If Contractor is a corporation, signatures from two officers of the corporation are required pursuant to California Corporations Code Section 313. Public Works Project: Civic Center Conduit Installation Public Works Contract $60,000 / April 2020 Page 12 of 12 IN WITNESS WHEREOF, the parties have caused this Contract to be executed as of the Execution Date first above written. CITY OF CUPERTINO, a Municipal Corporation By: __________________________________ Title: _____________ Signature Date: _________________________ Bear Electrical Solutions, Inc. By: __________________________________ Title: ________________________________ Signature Date: _________________________ APPROVED AS TO FORM: By: HEATHER M. MINNER Cupertino City Attorney ATTEST: By: KIRSTEN SQUARCIA City Clerk Date: Vice President Sep 3, 2020 Heather M. Minner Carl Valdez Sep 4, 2020 Service Center Superintendent Sep 4, 2020 Revised: July 13, 2020 – Public Works Contracts 1 Exhibit A-A – SHELTER IN PLACE AND SOCIAL DISTANCING REQUIREMENTS A. Health Laws Acknowledged. It is acknowledged that Consultant’s/Contractor’s (“Contractor”) duty to comply with Laws, as defined in Section 13 of the Contract/Agreement (“Contract”), includes immediate compliance by Contractor and its subcontractors with the restrictions on travel and the Social Distancing Requirements set forth in the most recent health order issued by the County of Santa Clara Health Department in response to the COVID-19 pandemic, and any subsequent amendments or superseding orders thereto (the “Health Order”), and any other local, state, or federal laws that have been or may be enacted in response to the COVID-19 pandemic (collectively, “Health Laws”). B. Health Order Compliance. Contractor shall comply with any restrictions on travel and social distancing requirements in the Health Order when preforming work under this Contract. If a scope of work item, notice to proceed, or work order under this Contract specifies work that cannot be performed in compliance with the Health Order or other Health Laws, Contractor shall refrain from conducting the work and immediately inform the City. C. Individuals at High Risk of Severe Illness. Nothing in this Contract shall be interpreted to require any person at high risk of severe illness from COVID-19 to leave their residence to perform work under the Contract. Contractor will inform the City if other arrangements for the work must be made, and City will do so, with no penalty to Contractor, although Contractor will not be compensated for work performed by the City or third parties. Information from the Center for Disease Control ("CDC") on "high risk" categories is available at the CDC's website at: https://www.cdc.gov/coronavirus/2019-ncov/specific-groups/people-at-higher-risk.html. D. Health Order Requirements and Best Practices. Contractor will immediately undertake all appropriate measures to ensure compliance with the Social Distancing Requirements in the Health Order by all individuals on any project site or work area performing work under this Contract, including Contractor's or any subcontractor's workers, employees, representatives, vendors, or suppliers (collectively, "workers"), and shall maintain these measures for as long as required by the Health Order or other Health Laws. In particular, Contractor must comply with the provisions of the County’s Mandatory Directive for Construction Projects (attached hereto), as applicable. Further, as long as required by the operative Health Order or Mandatory Directive for Construction Projects, or other Health Laws, these measures shall include, but are not limited to, the following best practices: 1. Information. Inform all workers of the Social Distancing Requirements and these best practices, including any updates or modifications, and require compliance as a condition to being present on the project site or work area. Revised: July 13, 2020 – Public Works Contracts 2 2. Social Distancing Protocol. Fill out and submit the newest version of the Social Distancing Protocol to the County, using the County’s online form available at https://www.sccgov.org/sites/covid19/Pages/social-distancing-protocol.aspx. 3. Sick Workers. Prohibit any individuals who have been tentatively or conclusively diagnosed with COVID-19 or who have any symptoms of illness, including the following, from entering or remaining on the project site or work area: fever, cough, shortness of breath, sore throat, body aches, chills, sudden loss of smell or taste or other flu-like symptoms. Encourage sick workers to get immediate medical attention. 4. Signage/Posters. As required, post or distribute (1) the most updated version of the COVID-19 PREPARED Sign, and (2) a Social Distancing Protocol Visitor Information Sheet. 5. Face Coverings. Everyone at a job site must wear a face covering at all time, except children under the age of 2, people who are medically prevented from wearing a face covering, and for communication by or with people who are hearing impaired. 6. Sanitary Facilities. Ensure adequate handwashing and/or hand-sanitizing facilities are available at all times and encourage frequent handwashing and/or hand-sanitizing throughout the day as specified below. Portable sanitary facilities must be serviced and cleaned on a daily basis. Provide hand sanitizer in or around all toilet facilities and common areas, including project trailers. a. Handwashing. Wash hands using soap and water for at least 20 seconds. b. Hand-sanitizer. Use a hand sanitizer that contains at least 60-95% alcohol when handwashing is not immediately available. c. Paper Products. Ensure that toilet paper, tissues, and paper towels are available as appropriate, with designated receptacles for disposal. 7. Distancing. Prohibit workers from being less than six feet apart, unless and only to the extent that would compromise worker safety or violate safety Laws for specific operations. Prohibit handshaking or any physical contact among workers, with the sole and limited exception of any physical contact required for worker safety or to comply with safety Laws. Avoid sharing tools to the extent possible. Require workers to provide their own transportation where possible and to avoid having more than two workers in a vehicle. 8. Groups/Meetings/Site Access. Avoid any group gatherings of 10 or more people. Use electronic alternatives to in person meetings, e.g., conference calls, video-conferencing, etc., to the greatest extent possible. Limit access to the project site or any work area to workers who are necessary to perform the work at that time. Allow non-essential Revised: July 13, 2020 – Public Works Contracts 3 personnel to work from home to the extent possible. Avoid all non-essential travel. Do not stack trades if possible. 9. Frequent Cleaning. Provide for regular and appropriate cleaning of all high touch surfaces at a project site or work area, including, but not limited to, shared tools or equipment, doorknobs and handles, toolboxes, sanitary facilities, common break areas, keypads, touch screens, project trailer surfaces and equipment, light or power switches, workstations, countertops, break areas, and the like. Clean and/or disinfect any reusable items or equipment. Clean surfaces of shared vehicles, including steering wheels, gear shifts, handles, instrument panels, etc. Ensure that cleaning products are used correctly and safely, and avoid cleaning techniques, such as use of pressurized air or water sprays, that may generate bioaerosols. 10. Personal Protective Equipment. When workers cannot avoid close proximity or physical contact, e.g., based on applicable safety laws, or are otherwise at risk for exposure to COVID-19, ensure that the affected workers are provided with appropriate personal protective equipment ("PPE"), which may include disposable gloves and/or other PPE. Instruct workers to wash or sanitize hands after removing gloves or other PPE. Ensure that all personal protective equipment is disposed of properly. 11. Water and Food. Prohibit shared or communal food or common water coolers. Provide individual water bottles for workers or instruct workers to bring their own. 12. Enforcement. Immediately eject any worker who fails or refuses to comply with the Health Laws, Social Distancing Requirements, or these best practices from the project site until or unless the Project Manager issues a written authorization for the worker to return, subject to full compliance. F. Proof of Compliance. If Contractor is subject to the Mandatory Directive for Construction Projects, Contractor must provide to the City the name and contact information for its designated site-specific COVID-19 supervisor(s). E. Oversight. In other to ensure that all workers comply with the Social Distancing Requirements to the extent possible, Contractor shall designate a named individual to have primary responsibility for implementation and enforcement of the Social Distancing Requirements and these best practices, and to serve as the primary point of contact with the City in this regard. Contractor shall promptly inform the City of the name of this individual. F. Changed Requirements. It is understood and acknowledged that circumstances pertaining to the COVID-19 pandemic are evolving rapidly and that new local, state, or federal requirements may modify the requirements under this Exhibit. Contractor agrees to work cooperatively with the City to implement new or changed requirements as quickly as possible. Revised: July 13, 2020 – Public Works Contracts 4 G. Subcontracts. Contractor shall include the terms of this Exhibit in all subcontracts and require any agents, subcontractors, or subconsultants to comply with its provisions. Attachments to Exhibit A-A Santa Clara County Mandatory Directive for Construction Projects 1228578.5 County of Santa Clara Public Health Department Health Officer 976 Lenzen Avenue, 2nd Floor San José, CA 95126 408.792.5040 Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 1 of 12 Board of Supervisors: Mike Wasserman, Cindy Chavez, Dave Cortese, Susan Ellenberg, S. Joseph Simitian County Executive: Jeffrey V. Smith MANDATORY DIRECTIVE FOR CONSTRUCTION PROJECTS *Please confirm that your facility and/or construction project jobsite may open under the State Order. Where there is a difference between the local County Order and the State Order, the more restrictive order must be followed. The State also has specific guidance for certain facilities that must be followed in addition to this mandatory directive.* Issued: July 7, 2020 Information on the State’s Order and State guidance is available at covid19.ca.gov. While the construction industry is critical to ensuring a safe and sufficient supply of residential and commercial space, construction work can also pose significant risks to public health due to the COVID-19 pandemic. Because construction projects typically involve many workers actively working on a jobsite at the same time, often in close proximity to one another or sharing equipment, businesses and individuals performing and overseeing construction projects must take extra precautions to reduce the risk of COVID-19 transmission for workers, visitors, and others. This Directive applies to all construction projects, but the restrictions vary by the size of the project, as specified below. “Construction project” means any work (including a public works project) carried out in connection with the construction, alteration, conversion, fitting-out, remodel, renovation, refurbishment, demolition, decommissioning, or dismantling of a building or other structure; the preparation of a physical site for any such activity; and education or training at which any such activity is taught through onsite practice or experience. “Construction project” does not include architectural, design, financial, or administrative work related to a construction project, unless that work occurs at the construction jobsite. “Construction project” also does not include basic repair or maintenance work, which means a repair or maintenance job that requires no more than 2 workers and no more than 2 days and that is not architecturally, financially, or administratively associated with an active construction project. This Directive explains how construction projects may operate. This Directive is mandatory, and failure to follow it is a violation of the Health Officer’s Order issued on July 2, 2020 (“Order”). Construction projects must comply with the Order and all requirements of this Directive. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 2 of 12 The Order Issued July 2 The Order imposes several restrictions on all businesses and activities to ensure that the County stays as safe as possible, including but not limited to the following: The Social Distancing Protocol: All businesses must fill out and submit the newest version of the Social Distancing Protocol to the County using the online form, available here. The Protocol is submitted under penalty of perjury, meaning that everything written on the form must be truthful and accurate to the best of the signer’s knowledge, and submitting false information is a crime. The Protocol must be distributed to all workers, and it must be accessible to all officials who are enforcing the Order. Businesses are responsible for ensuring that workers understand and are trained on Protocol requirements in a language that they understand. For any business that only performs services for dispersed facilities or worksites that the business does not own or operate, the business must complete a Social Distancing Protocol for its operation as a whole. For any business that has a facility, but also provides services at dispersed facilities or worksites that the business does not own or operate, the business must complete a Social Distancing Protocol for its own facility and provide that Protocol to the owners or operators of any facility where it operates.  Example: A construction company serves as a subcontractor on various jobsites throughout the County and also operates a base facility within the County, where it maintains its vehicles and equipment. The subcontractor must complete a Social Distancing Protocol for its base facility. It must also distribute the Protocol to the owners or operators of the jobsites to which it sends its workers. The subcontractor’s workers must be given a copy of, be trained on, and comply with the measures in both the subcontractor’s Social Distancing Protocol and the Social Distancing Protocol for any jobsite at which they are performing work. • Signage: All businesses must print (1) an updated COVID-19 PREPARED Sign and (2) a Social Distancing Protocol Visitor Information Sheet, and both must be posted prominently at all facility entrances. These are available for printing after submission of the Social Distancing Protocol online.  Businesses do not need to post these documents if they do not have their own facility or worksite and only perform services for dispersed facilities or worksites that the business does not own or operate. • Face Coverings: Everyone at a business facility or worksite must wear a face covering at all times (except very young children, people for whom face coverings are medically inadvisable, or for communication by or with people who are hearing impaired). Face coverings must be worn even while working at a construction project. Workers do not need to wear face covering if it would create a risk to the person related to their work, in accordance with local, state, or federal workplace safety guidelines. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 3 of 12 • Density Limitation: All businesses must limit the number of people who may be inside the facility at the same time. For staff members, the limit is 1 person per 250 gross square feet of indoor facility space (this means total space, including areas open only to staff like storage rooms). For members of the public, the limit is 1 person per 150 square feet of space open to the public. The density requirements tell businesses how many people (staff or clients) they can let inside the facility before another person leaves. Children under 12 who are accompanying a parent or guardian do not count against the limit, but everyone age 12 and over does. This Directive describes a limited exception to the density limitation applicable only to construction project jobsites. See the Order and the FAQ page for more details. In addition to these general requirements applicable to all businesses under the Order, construction projects must comply with the following directives. Construction Projects on Own Residence Exempted This Directive does not apply to construction projects where a person is performing construction on their current residence alone or solely with members of their own household. Rules for Single-Worker Construction Projects This section lists the requirements for construction projects performed by only 1 worker, such as someone who is working alone on a kitchen remodel project. This section for single-worker projects does not apply to construction projects that involve multiple workers, even if only 1 worker is at the jobsite at any time; those projects must follow the Rules For All Construction Projects, which are listed in the next section. a. If the worker is working for a business, the worker must comply with the Social Distancing Protocol of that business. b. The worker must maintain 6 feet of social distance from all other people at all times, including when entering and leaving the work area or building. c. The worker must use and properly wear face coverings. In addition, the worker must wear other personal protective equipment (PPE) appropriate for use in construction, including gloves, goggles, and/or face shields. d. To the extent possible, the worker must seal off the work area so that there is a barrier between the worker and any other people in the building. For example, a worker performing construction in the hallway of a residence must install a barrier (such as plastic sheeting) between the area where the worker is working and the rest of the hallway. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 4 of 12 e. The worker must frequently wash hands with soap and water for at least 20 seconds or use hand sanitizer with at least 60% alcohol. f. The worker must not work or come to the jobsite if the worker has a fever, cough, or any other COVID-19 symptoms. g. The worker must maintain records of the dates and times the worker was at the jobsite and must make those records immediately available upon request to any County official. h. If the worker tests positive for COVID-19, the worker must notify the County Public Health Department within 4 hours of learning of the positive result by following the instructions at www.sccsafeworkplace.org. Rules for All Construction Projects (Except Single-Worker Construction Projects) This section lists requirements for all construction projects (other than single-worker construction projects). *Note: Large Construction Projects must also follow additional requirements, which are described beginning on page 9.* 1. Responsibilities of the General Contractor and Subcontractors a. The business with the responsibility to oversee a construction project, described in this Directive as the “General Contractor,” must complete and submit a Social Distancing Protocol specific to the construction project jobsite. (The General Contractor may also need to submit social distancing protocols for its base facility or for other jobsites subject to this Directive.) b. The General Contractor is responsible for ensuring that all work and operations at the construction jobsite is performed in compliance with the Order, this Directive, and the jobsite-specific Social Distancing Protocol. c. The General Contractor must train its workers to comply with the Order, this Directive, and the jobsite-specific Social Distancing Protocol. d. Subcontractors do not need to submit their own jobsite-specific Social Distancing Protocols for the same site, but the General Contractor must not allow any subcontractor onto the jobsite unless that subcontractor has given the General Contractor a signed certification that: i. the subcontractor has reviewed the Order and this Directive and will comply with them; Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 5 of 12 ii. the subcontractor has reviewed the General Contractor’s jobsite-specific Social Distancing Protocol and trained its workers on that Protocol; and iii. the subcontractor has completed and submitted its own Social Distancing Protocol covering its operations, and has provided a copy of that Protocol to the General Contractor. 2. General Contractors and Subcontractors Must Report COVID-19 Positive Cases a. Whenever the General Contractor learns that a person who has tested positive for COVID-19 was at the jobsite within 48 hours of the date they were tested or within 48 hours of becoming symptomatic, the General Contractor must immediately implement the jobsite-specific Social Distancing Protocol’s procedures for when a person tests positive for COVID-19. All positive cases must be reported by following the instructions at www.sccsafeworkplace.org. b. All subcontractors must immediately (within 1 hour, regardless of the time of day) alert the General Contractor as soon as they learn that an employee has tested positive who is currently at the jobsite, or who was at the jobsite within 48 hours of the date they were tested or within 48 hours of becoming symptomatic. This reporting requirement is in addition to the subcontractor’s own reporting requirements under the Order and the procedures in the subcontractor’s Social Distancing Protocol. 3. Cleaning After Positive Case Identified Upon learning of a confirmed positive case at the jobsite within the last 48 hours, any location where the infected worker was known to have been present must be immediately closed and sanitized. Work in these locations must cease until sanitization is complete. 4. General Contractor is Responsible for Ensuring the Jobsite is Operated Safely Following All Legal Requirements a. The General Contractor must ensure that everyone at the jobsite—including its own workers, the subcontractors’ workers, and visitors—complies with the Order, this Directive, the jobsite-specific Social Distancing Protocol, and any other laws and regulations that apply to the work (for example, OSHA and Cal-OSHA requirements). If there is a conflict in what different laws require, the strictest standard applies. b. The General Contractor’s responsibility for ensuring jobsite compliance under this paragraph 4 does not, however, relieve any subcontractors of their own responsibilities under the Order, their Social Distancing Protocol, this Directive, and all other applicable laws and regulations. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 6 of 12 c. Any worker, or any subcontractor, may file a complaint that the General Contractor has not complied with the Order, this Directive, or the jobsite-specific Social Distancing Protocol, or that the General Contractor has failed to require others to comply. Complaints may be filed through the County Office of Labor Standards Enforcement Advice Line (866-870-7725) or website (www.sccfairworkplace.org). 5. Designated COVID-19 Supervisor(s) a. The General Contractor must designate a site-specific COVID-19 Supervisor or Supervisors to enforce the jobsite-specific Social Distancing Protocol and this Directive. The designated COVID-19 Supervisor(s) must be present at the jobsite at all times during construction activities. The COVID-19 Supervisor may be an on-site worker who is designated to serve in this role. The General Contractor must prominently post a sign at all entrances to the jobsite clearly identifying the COVID-19 Supervisor(s) by name and providing their phone number and email address. b. The designated COVID-19 Supervisor(s) must review this Directive and the jobsite-specific Social Distancing Protocol with all workers and other persons at the jobsite. The General Contractor is responsible for making sure this occurs. c. The COVID-19 Supervisor must monitor and ensure implementation at the jobsite of all requirements in this Directive, the jobsite-specific Social Distancing Protocol, and the Order. 6. Seal Off Area of Construction Project from Other Parts of Occupied Sites Where construction work occurs within an occupied residential or commercial building, all of the following rules apply: a. Work areas must, to the extent feasible, be sealed off from the remainder of the building (and from the remainder of the unit, if work is performed within a residential unit) with physical barriers such as plastic sheeting or closed doors sealed with tape. b. If possible, workers must access the work area from entry/exit door(s) different from the entry/exit door(s) used by residents or occupants accessing the remainder of the building that is not under construction. c. Available windows and/or doors must be used to ventilate the work area during the workday and any other times work is performed. d. If residents or occupants have access to the work area between workdays, the Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 7 of 12 work area must be cleaned and sanitized at the beginning and at the end of workdays. e. Every effort must be taken to minimize contact between workers and residents or occupants, including maintaining a minimum of at least 6 feet of social distancing at all times. 7. Personal Protective Equipment (PPE) The General Contractor must obtain, provide at no cost to workers, and require that all workers use personal protective equipment (PPE) appropriate for use in construction, including gloves, goggles, face shields, and face coverings as appropriate for the activity being performed. Face coverings must be worn in compliance with the State’s mandatory Guidance for the Use of Face Coverings and any additional directives issued by the County Health Officer. At no time may medical-grade PPE be used at a construction site unless it is required due to the medical nature of the jobsite or local, state, or federal workplace safety requirements. 8. Social Distancing, Sanitizing, and other Measures a. The General Contractor must: i. Ensure compliance at the jobsite with the Order’s density limitations except to the extremely limited extent a higher density is temporarily necessary to safely carry out a specific job function. 1. The density limitations apply to all indoor areas where construction work is actively being performed. Density limitations do not apply to staging areas or lay-down areas that are separate from the area where construction work is actively being performed. ii. Stagger shifts, breaks, and trade-specific work as necessary to reduce density and allow for easy maintenance of minimum 6-foot distancing. Staggered shifts and breaks must comply with applicable wage and hour laws. 1. All persons must maintain minimum 6-foot distancing except to the extremely limited extent shorter distances are temporarily necessary to safely carry out a specific job function. iii. Eliminate or resolve “choke points” and “high-risk areas” where workers are unable to maintain 6-foot social distancing. The General Contractor must prohibit or limit use of these areas to ensure that 6-foot distance can easily be maintained between individuals. Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 8 of 12 iv. If possible, ensure workers eat their meals and take their breaks outdoors, and maintain social distancing during meals and breaks. v. Prohibit gatherings of any size on the jobsite (except for meetings required by this Directive), including gatherings for breaks or eating. Sharing of any food or beverage is strictly prohibited. vi. Cal-OSHA requires employers to provide water. Water must be provided in single-serve containers. vii. Prohibit use of microwaves, water coolers, and other similar shared equipment. b. Workers must: i. Unless strictly necessary to carry out a job function, maintain at all times at least 6-foot social distancing from fellow workers and all site visitors, including delivery workers, design professionals and other project consultants, government agency representatives (including building and fire inspectors), and residents at residential construction sites. ii. Not carpool to and from the jobsite except with others living within the same household unit, or if necessary because they have no alternative means of transportation. If workers from different households must carpool, they must wear face coverings while riding together in the same vehicle, sit at the greatest distance possible, and maintain ventilation by keeping windows open as feasible. 9. Notice for Workers and Visitors of Required Practices The General Contractor must prominently post a notice at all entrances to the jobsite visible to all workers and visitors instructing workers and visitors to do the following: a. Do not touch your face with unwashed hands or with gloves. b. If equipment is shared, it must be fully sanitized before and after each use. c. Wash your hands often with soap and water for at least 20 seconds each time, or use hand sanitizer with at least 60% alcohol. d. Clean and disinfect objects and surfaces you touch often, such as work stations, keyboards, telephones, handrails, machines, shared tools, elevator control buttons, and doorknobs. e. Cover your mouth and nose with a tissue or cloth when you cough or sneeze, or Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 9 of 12 cough or sneeze into your elbow/sleeve – never into your hands. f. Do not enter the jobsite if you have a fever, cough, or other COVID-19 symptoms. If you feel sick, or have been exposed to anyone who is sick, stay at home. g. Constantly make sure you are staying at least 6 feet away from co-workers at all times, unless it is absolutely necessary to get closer to complete a task for the construction project. h. Do not carpool to and from the jobsite with anyone except members of your own household, or if necessary because you have no alternative means of transportation. If you carpool with people from another household, you must wear a face covering while riding together in the same vehicle. i. Do not share phones or PPE. Posters conforming to this requirement are available for download at https://www.sccgov.org/sites/covid19/Pages/learn-what-to-do-flyers.aspx. 10. Cooperate with County’s Case Investigation and Contact Tracing Efforts The General Contractor must maintain a daily attendance log of all workers and visitors at the jobsite that includes contact information (including name, phone number, address, and email) and the date, time, and duration of each person’s presence at the jobsite. If someone on the jobsite tests positive for COVID-19, the General Contractor is legally required to assist the County Public Health Department in any case investigation and contact tracing efforts. 11. Monitor and Inform Supervisors and Subcontractors of Revised Requirements The General Contractor must regularly check for revisions to the Order, this Directive, relevant industry-specific guidance published by the California Department of Public Health, and other relevant rules or guidance. The General Contractor must inform all jobsite supervisors (including the designated COVID-19 Supervisor(s), all field supervisors, foremen, and safety directors) and all subcontractors of any revisions or additions to the requirements for construction projects. Additional Rules for Large Construction Projects This section describes additional requirements that apply only to Large Construction Projects. 12. What is a Large Construction Project? A “Large Construction Project” is a construction project that meets any of the following Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 10 of 12 specifications: a. For residential projects, any single-family, multi-family, senior, student, or other residential construction project consisting of 10 or more units; or b. For commercial projects, any construction project consisting of 20,000 or more square feet of floor area; or c. For mixed-use construction projects, any construction project that meets either of the specifications above in Subparagraphs (a) and (b); or d. Any infrastructure project that requires 20 or more workers at the jobsite at any one time. 13. COVID-19 Supervisor’s Additional Compliance, Monitoring, and Remediation Responsibilities a. The designated COVID-19 Supervisor must: i. Conduct daily briefings in person (with proper social distancing) or by teleconference that must cover the following topics: 1. New jobsite rules and pre-jobsite travel restrictions for the prevention of COVID-19 community spread. 2. Review of sanitizing and hygiene procedures. 3. Worker feedback on improving safety and sanitizing. 4. Coordination of construction site daily cleaning/sanitization requirements. 5. Any newly available information regarding COVID-19. 6. Emergency protocols in the event of an exposure or suspected exposure to COVID-19. ii. Each day, verify and record verification that each jobsite is compliant with this Directive. The General Contractor must collect each written verification, store them for at least 1 year, and make them immediately available upon request to any County official. iii. Conduct the following activities to make sure that the jobsite is ready to fix any violations of this Directive: Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 11 of 12 1. Develop a remediation plan; 2. If any non-compliance is identified, ensure that the remediation plan is implemented, and post the remediation plan at all entrances to the jobsite during the remediation period; 3. Stop any construction activity until the jobsite is back in compliance; and 4. Report repeated non-compliance with this Directive to the appropriate jobsite supervisors and the permitting agency for the local government where the project is located. b. The General Contractor is responsible for making sure the designated COVID-19 Supervisor takes all of these steps. 14. Jobsite Safety Accountability Supervisor (JSAS) The General Contractor must assign a COVID-19 Third-Party Jobsite Safety Accountability Supervisor (JSAS) for the jobsite. The JSAS may not be an employee of the General Contractor. The JSAS must at a minimum hold an OSHA-30 certificate and first-aid training, or equivalent credentials, from within the past 2 years. The JSAS must be trained in the requirements in this Directive and the jobsite-specific Social Distancing Protocol and must verify compliance with those requirements, including by visual inspection and random interviews with workers. The JSAS must inspect the jobsite as often as needed to ensure consistent compliance, but not less than once per week. The JSAS must inspect the jobsite during normal construction hours. a. The General Contractor must prominently post a sign at all entrances to the jobsite visible to all workers and visitors that clearly identifies the JSAS for the jobsite by name and providing their phone number and email address. b. Within 7 calendar days of each jobsite visit, the JSAS must complete a written assessment identifying any failure to comply with this Directive. The written assessment must be copied, stored, and, produced upon request to the County or local permitting agency. c. If the JSAS discovers that a jobsite is not in compliance with this Directive and the jobsite-specific Social Distancing Protocol, the JSAS must work with the designated COVID-19 Supervisor to develop and implement a remediation plan. d. The JSAS must coordinate with the designated COVID-19 Supervisor to prohibit continuation of any work activity not in compliance with this Directive or the jobsite-specific Social Distancing Protocol. The JSAS must make sure that the Mandatory Directive for Construction Projects (Order issued July 2, 2020) Page 12 of 12 work activity does not resume until the noncompliance is fixed and the continuing work is compliant with this Directive. e. The remediation plan must be sent to the local permitting agency and a designated County official within 5 calendar days of the JSAS’s discovery of the failure to comply. 15. Translation for Non-English-Speaking Workers The General Contractor must translate (and, where otherwise required, post) all of the following documents as necessary to ensure that all non-English-speaking workers are able to understand the documents: a. The Notice for Workers and Visitors of Required Practices described in Paragraph 9 (on page 8). b. The remediation plan described in Paragraph 13.a.iii.1 (on page 11). Stay Informed For answers to frequently asked questions about this industry and other topics, please see the FAQ page. Please note that this Directive may be updated. For up-to-date information on the Health Officer Order, visit the County Public Health Department’s website at www.sccgov.org/coronavirus. Insurance Requirements for Construction Contracts - $60,000 Version: Sept. 2019 1 Contractor shall procure and maintain for the duration of the contract, and for five years following the completion of the Project, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by Contractor, its agents, representatives, employees or subcontractors. MINIMUM SCOPE AND LIMIT OF INSURANCE Coverage shall be at least as broad as: 1.Commercial General Liability (“CGL”): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, written on a comprehensive general liability form, and must include coverage for liability arising from Contractor’s or Subcontractor’s acts or omissions, including Contractor’s protected coverage, blanket contractual, products and completed operations, vehicle coverage and employer’s non-ownership liability coverage, with limits of at least $2,000,000 per occurrence. The CGL policy must protect against any and all liability for personal injury, death, property damage or destruction, and personal and advertising injury. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit. a.It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be made available to the Additional Insured and shall be (1) the minimum coverage/limits specified in this agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy, whichever is greater. b.Additional Insured coverage under Contractor's policy shall be "primary and non-contributory," will not seek contribution from City’s insurance/self-insurance, and shall be at least as broad as ISO CG 20 01 04 13 c.The limits of insurance required may be satisfied by a combination of primary and umbrella or excess insurance, provided each policy complies with the requirements set forth in this Contract. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary basis for the benefit of City before the City’s own insurance or self-insurance shall be called upon to protect City as a named insured. 2.Automobile Liability: ISO Form CA 00 01 covering any auto (Code 1), or if Contractor has no owned autos, then hired autos (Code 8) and non-owned autos (Code 9), with limit no less than $1,000,000 per accident for bodily injury and property damage. 3.Workers’ Compensation: As required by the State of California, with Statutory Limits, and Employer’s Liability Insurance of no less than $1,000,000 per accident for bodily injury or disease, or as otherwise required by statute. If Contractor is self-insured, Contractor must provide a Certificate of Permission to Self-Insure, duly authorized by the DIR. N/A if box checked (Contractor provides written verification it has no employees). 4.Professional Liability with limits no less than $1,000,000 per occurrence or claim, and $2,000,000 aggregate. N/A if box checked (Contract is not design/build). 5.Builder’s Risk. Course of Construction insurance utilizing an “All Risk” (Special Perils) coverage form, with limits equal to the completed value of the project and no coinsurance penalty provisions. N/A if box checked (Project does not involve construction or improvements/installations to property). PUBLIC WORKS CONSTRUCTION CONTRACTS Small Projects - $60,000 Insurance Requirements: Exhibit B X X Insurance Requirements for Construction Contracts - $60,000 Version: Sept. 2019 2 6.Contractors’ Pollution Legal Liability and/or Asbestos Legal Liability and/or Errors and Omissions with limits no less than $1,000,000 per occurrence or claim, and $2,000,000 policy aggregate. N/A if box checked (Project does not involve environmental hazards). If Contractor maintains broader coverage and/or higher limits than the minimums shown above, City requires and shall be entitled to the broader coverage and/or higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. Self-Insured Retentions. Self-insured retentions must be declared to and approved by City. At City’s option, either: (1) Contractor shall cause the insurer to reduce or eliminate self-insured retentions as respects City, its officers, officials, employees, and volunteers; or (2) Contractor shall provide a financial guarantee satisfactory to City guaranteeing payment of losses and related investigations, claim administration, and defense expenses. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or the City. OTHER INSURANCE PROVISIONS The insurance policies are to contain, or be endorsed to contain, the following provisions: Additional Insured Status The City of Cupertino, its City Council, officers, officials, employees, agents, servants and volunteers are to be covered as additional insureds on the CGL and automobile liability policies with respect to liability arising out of the Services performed by or on behalf of Contractor including materials, parts, or equipment furnished. Endorsement of CGL coverage shall be at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used. Primary Coverage For any claims related to this Project, Contractor’s insurance coverage shall be “primary and non-contributory” and at least as broad as ISO CG 20 01 04 13 with respect to City, its officers, officials, employees and volunteers, and shall not seek contribution from City’s insurance. If the limits of insurance are satisfied in part by Umbrella/Excess Insurance, the Umbrella/Excess Insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a “primary and non-contributory” basis for the benefit of City. Notice of Cancellation Each insurance policy required shall provide that coverage shall not be canceled, except with notice to the City. Each certificate of insurance must state that the coverage afforded by the policy is in force and will not be reduced, cancelled or allowed to expire without at least 30 days advance written notice to City, unless due to non-payment of premiums, in which case ten days advance written notice must be provided to City. Such notice must be sent to City via certified mail and addressed to the attention of the City Manager. Builder’s Risk Contractor may submit Builder’s Risk insurance in the form of Course of Construction coverage, which shall name the City as a loss payee, as its interest may appear. The Builder’s Risk policy must be issued on an occurrence basis, for all-risk coverage on a 100% completed value basis on the insurable portion of the Project, with no coinsurance penalties, and for the benefit of City. If the Project does not involve new or major reconstruction, City may elect, acting in its sole discretion, to accept an Installation Floater policy instead of Builder’s Risk. For such projects, the Property Installation Floater shall include improvement, remodel, modification, alteration, conversion or adjustment to existing buildings, structures, processes, machinery and equipment, and shall provide property damage coverage for any building, structure, machinery or equipment damaged, impaired, broken, or destroyed during the performance of the Work, including during transit, installation, and testing at the City’s site. X Insurance Requirements for Construction Contracts - $60,000 Version: Sept. 2019 3 Waiver of Subrogation Each required policy must include an endorsement providing that the carrier agrees to waive any right of subrogation it may have against City. Contractor agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City for all work performed by the Contractor, its employees, agents and subcontractors. Acceptability of Insurers Insurance must be issued by insurers acceptable to City and licensed to do business in the State of California, and each insurer must have an A.M. Best’s financial strength rating of “A” or better and a financial size rating of “VII” or better. Verification of Coverage Contractor shall furnish the City with original certificates and amendatory endorsements, or copies of the applicable insurance language, effecting coverage required by this contract. All certificates and endorsements are to be received and approved by the City before work commences. The City reserves the right to require complete, certified copies of all required insurance policies, including endorsements, required by these specifications, at any time. Subcontractors Contractor shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Contractor shall ensure that City is an additional insured on insurance required from subcontractors. For CGL coverage subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13. Surety Bonds As required by Contract and described in the Contract Documents. The Payment and Performance Bonds shall be in a sum equal to the Contract Price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the Contract is for longer than one year a Maintenance Bond equal to 10% of the Contract Price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California. Special Risks or Circumstances City reserves the right to modify these requirements, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 8/7/2020 Woodruff-Sawyer & Co. 50 California Street, Floor 12 San Francisco CA 94111 415-391-2141 415-989-9923 Hartford Casualty Insurance Company 29424 BEARELE-01 Hartford Fire Insurance Company 19682Bear Electrical Solutions, Inc. 1341 Archer Street Alviso CA 95002 837683430 B X 1,000,000 X 300,000 10,000 1,000,000 2,000,000 X Y 57UEAFN9382 2/1/2020 2/1/2021 2,000,000 A 1,000,000 X X X 57UEAFN9268 2/1/2020 2/1/2021 A X X 5,000,00057RHAFN93502/1/2020Y 2/1/2021 5,000,000 RE: All Agreements. The City of Cupertino, it's City Council, officers, officials, employees, agents servants and volunteers and all public agencies from whom permits will be obtained and their officers, officials, employees, agents, servants and volunteers are additional insured per the attached endorsements, wherein coverage is primary and non-contributory. Policies contain a 30 day notice of cancellation and a 10 day notice of cancellation for non-payment of premium. City of Cupertino 10300 Torre Avenue Cupertino CA 95014 A+, XV A+, XV ABCDEFGHIJ THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. AMENDMENT OF OTHER INSURANCE CONDITION - PRIMARY OR PRIMARY AND NON-CONTRIBUTORY WHEN REQUIRED BY WRITTEN CONTRACT OR WRITTEN AGREEMENT This endorsement modifies insurance provided under the following: UMBRELLA LIABILITY POLICY I. B.2 III – Who Is An G. Other InsuranceParagraph of Section Insured is replaced by the following:1.This policy shall apply in excess of all 2.Any person or organization with whom you "underlying insurance" whether or not agreed, because of a written contract, written valid and collectible. It shall also apply in agreement or because of a permit issued by a excess of other valid and collectible state or political subdivision, to provide insurance (except other insurance insurance such as is afforded under this policy, purchased specifically to a pply in but only with respect to your operations, "your excess of this insurance) which also work" or facilities owned or used by you. applies to any loss for which insurance is provided by this policy.This provision does not apply: These excess provisions apply, whethera.Unless the written contract or written such other insurance is stated to be:agreement has been executed, or the a.permit has been issued prior to the Primary; "bodily injury", "property damage", or b.Contributing;"personal and advertising injury"; and c.Excess; orb.Unless the limits of liability specified in d.Contingent.such written contract, written agreement 2.However, the following provisions applyor permit are greater than the limits to other insurance available to anyshown for "underlying insurance"; or person or organization qualifying as anc.Beyond the period of time required by B.2.additional insured under Paragraphthe written contract or written III – Who Is An Insuredof Section , asagreement.I.amended by Item of this endorsementIn no event shall any coverage afforded to and who is also an additional insuredany such person or organization apply to any under the Commercial General Liabilityclaim or "suit" to which "underlying insurance"Coverage Part scheduled in thedoes not apply. Coverage provided by this "underlying insurance":policy for any such additional insured will a. Primary Insurance Whenfollow the provisions, exclusions and Required By Contractlimitations of the "underlying insurance".If you have agreed in a writtenII.Solely as respects the insurance afforded to any contract, written agreement orperson or organization qualifying as an permit to provide primary insuranceI.additional insured under Paragraph above, the to the additional insured, then, afterOther Insurance VI –condition in Section the "underlying insurance" isConditionsis replaced by the following: Form XL 24 37 09 11 Page 1 of 2 © 2011, The Hartford (Includes copyrighted material of Insurance Services Office, Inc., with its permission.) Policy #57RHAFN9350 III. Section IV – Limits Of exhausted, this insurance will be The following is added to Insuranceprimary. If other insurance is also : primary, we will share with all that H. How Limits Apply To Additional Insuredsother insurance by the method If you have agreed in a written contract,3.described in Paragraph below.written agreement or permit that another b. Primary And Non-Contributory To person or organization be added as anOther Insurance When Required additional insured on the CommercialBy Contract General Liability Coverage Part scheduled in If you have agreed in a written the "underlying insurance" and such person contract, written agreement, or or organization also qualifies as an permit to provide insurance to the additional insured under this policy, the most additional insured that is primary we will pay on behalf of such insured is the and non-contributory, then, after the lesser of: "underlying insurance" is exhausted, a.The limits of insurance specified in thethis insurance will be primary and written contract, written agreement orwe will not seek contribution from permit, less any amounts payable bythe additional insured’s own any "underlying insurance"; orinsurance.b.The Limits of Insurance shown in thea. b.Paragraphs and do not apply to Umbrella Liability Policy Declarations.other insurance on which the additional Such amount shall be a part of and not ininsured qualifies as an additional addition to the Limits of Insurance shown ininsured pursuant to the terms of that the Umbrella Liability Policy Declarations policy or has been added as an and described in other provisions of thisadditional insured by endorsement.Section.3. Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. Page 2 of 2 Form XL 24 37 09 11  qtYkLtZa‹ o qto‡ZPR koMYbZ‹ o qRskLlRla‹ Lƒ‚LNXRPRr…ZqkRmoSXRSobboˆYlW‹qR€(   NokqtR€€ot€  q…kq€ LlP WRlRsLos€ YmNa…PZmW €qtL‹ZmW ˆRcPYlW M…YbPZmW NbRLmZmW WRoqX‹€ZNLbRŠqaosLYolbZWXYmW LlPˆRaa€Rt‡ZNYmWRr…YqkRl-os 6XRtt‹qZN`Rt€LmP€ZkZaLtPR‡YNR€…€RPo tLZ€RotaoˆRtˆot`Rt€. JRXZNaR€moPR€NsZMRPYm   os LMo‡R kLYmLZmRPqtYkLtZb‹Spsq…sqo€R€oXRsXLl XRtLl€qosLYomoSqRs€ol€osNLsWo :oˆR‡Rt€RcSqsoqRbbRP ‡RXYNbR€ˆYX XR SoaboˆZlW‹qR€ oSqRskLlRlb‹ LLNXRP Rr…YqkRlLtRlokoMYbRRr…YqkRlM…ˆYbb MRNom€YPRsRPL…o€)  8r…YqkRmPR€ZWlRPqsZkLtYd‹Sos* EloˆtRko‡Lc/ DoLPkLZlRlLmNRM…lo Nom€s…NYomotsR€…tSLNZlW-ot  EsRRNaRLmYlW0 6XRss‹ qZN`Rt€ LlP€YkYbLt PR‡ZNR€ ko…lRP ol L…okoMZbR ou s…N` NXL€€Y€ LmP…€RPosLY€RotboˆRsˆos`Rv€0LmP # 5YtNokqtR€€ot€q…kq€LlPWRlRsLos€ YmNa…PYmW €qtL‹YlW ˆRbPYlW M…YbPYlW NbRLlYmW WRoqX‹€YNLaRŠqcosLYol bYWXYlW LmPˆRab€R}YNYlWRr…YqkRl ;oˆR‡Rt koMZaRRr…YqkRm PoR€ lo YlNb…PR Lm‹aLlP‡RXZNaRXLZ€€…M^RNoLNokq…b€ot‹ ot SYmLmNYLb sR€qom€YMYbY‹bLˆ osoXRskoot ‡RXZNaR Ym€…tLlNRaLˆˆXRsR [ Y€bYNRm€RP os qtZmNZqLbb‹WLtLWRP>LmP‡RXZNbR€€…M^RN o L Nokq…b€oosVlLlNZLbtR€qom€YMYbY‹aLˆotoXRs koot‡RXZNbR Zl€…tLlNR bLˆLsRNol€YPRtRP L…o€ 2.))&2 kRLm€ LlLNNYPRlZlNj…PYlW NolZm…o…€ottRqRLRPRŠqo€…tRo€…M€LlYLbc‹ XR€LkRWRmRtLaXLtkS…aNolPZYol€ 2),'&"2 &2 /+,&2 &!.*02 kRLl€ Zm_…t‹YlNa…PZmW Nom€Rr…RlZLcMoPYb‹Yl_†s‹ LtZ€ZmW o… oS omR otkotR oSXRSodcoˆYmW oSURm€R€+ 9La€RLstR€PRRmYomotYkqtZ€olkRl0 ?LaZNZo…€qto€RN…Yom1 O FXR ˆtolWS…a R‡YNYom Stok ˆsolWS…b Rms‹ Zlo ot Zm‡L€Zom oS XR sYWX oS qsY‡LR oNN…qLmN‹ oS L took PˆRbbYmW ot qsRkZ€R€ XL LqRt€om ototWLmYŒLYom oNN…qYR€ NokkZ„RP M‹ ot om MRXLbS oS Y€ oˆlRs eLlPaotPosfR€€ot2 Q AtLa‰tZRl otRaRNtomZNq…MgYNLYom ZmLl‹ kLmmRt oSkLRtZLaXL€bLlPRs€ot bYMRc€L qRt€om os otWLmZŒLZom os PY€qLsLWR€ L qRt€ol€ototWLmZŒLYol€WooP€qsoP…N€os €R|ZNR€3 2 2'2 2 AsLc ˆtYRlosRaRNsomYN q…MbYNLYom YlLm‹ kLllRs oS kLRsZLb XL ‡YobLR€ L qRs€ol€ tYWXoSqsY‡LN‹4 6oq‹YlW Yl‹o…sLP‡RsY€RkRl LqRs€ol€ ososWLlYŒLYol €LP‡RsY€YlWZPRLos€‹bRoS LP‡RyY€RkRl.os <lSsYlWRkRl oT Noq‹tYWX €boWLl os ZbR oS Ll‹ bYRtLt‹ os Lx[€[N ˆot` Zl ‹o…s LP‡RzY€RkRm  2'$#.-&-,2 kRLlLm‹€obYP bYr…YP WL€Ro…€os XRskLbYssYLlouNolLkYlLl YlNa…PYlW€ko`R ‡Lqot€ooS…kR€LNYP€Lb`LbY€NXRkYNLb€LlP ˆL€RKL€RYlNb†PR€ kLRsYLb€oMRtRN‹NbRP uRNolPZZolRPossRNbLZkRP  2*'.-,'%(#-2 '(*-'&,21* =lNb…PR€ LbdMoP[b‹ [l^…s‹LmP qsoqRs‹ PLkLWR oNN…ss\lWLˆL‹Stok qtRkY€R€ ‹o… oˆloutRlLlPLsY€]lWo…oS‹o…sqtoP…N os‹o†sˆos`RŠNRq, CsoP…N€ XL LsR €Ybb Yl ‹o…t qX‹€YNLb qo€€R€€Yol.os Kos`XLXL€lo‹RMRRlNokqhRRP os LMLlPolRP ;oˆR‡Rs ‹o…sˆos`ˆYbbMR PRRkRP NokqbRRP L XRRLsbYR€ oS XR SobcoˆYlWYkR€( KXRlLbboSXRˆos`NLdbRPSosYl‹o…t NolsLNXL€MRRlNokqdRRP KXRlLbboSXRˆos`oMRPolRLXR ^oM €YR XL€MRRl NokqbRRPYS‹o…s NolsLN NLbj€Sotˆos` L kosR XLl olR^oM€YR  KXRl XLqL{oS XRˆos`PolR L L ^oM €YRXL€MRRlq… oY€[lRlPRP …€R M‹ Ll‹ qRs€ol os osWLlYŒLYol oXRt XLlLloXRtNomsLNos os €…MNoltLNosˆos`YnW olXR€LkR qto^RN Kot` XL kL‹lRRP €Rs‡YNR kLZlRlLlNR NottRNYolsRqLYt ot uRqiLNRkRlM…ˆXYNX Y€oXR~Y€R NokqcRRˆYbbMRsRLRPL€NokqbRRP  7oR€ mo YlNb…PR MoPYb‹ Yl_…s‹ os qsoqRx‹ PLkLWRLtY€ZlWo…oS, GXRsLl€qozLZoloSqsoqRw‹ …lbR€€XR Yl^…t‹osPLkLWRLsY€R€o…oSLNolPYYom YmotolL‡RXZNbRlooˆlRPotoqRsLRP M‹‹o…LmPXLNolPZ‚ZolˆL€NsRLRPM‹ XRboLPYlWos…lboLPZlW oS XL ‡RXYNbR M‹Ll‹Ym€…tRP0 HXR RŠY€RlNR oS ooa€ …lYl€LbbRP Rr…[qkRl os LMLmPolRP ot …m…€RP kLRsYLb€0ot CsoP…N€ ot oqRsLZol€SpsˆXYNX XR NbL€€YSZNLYolbY€RPZmXR7RNbLsLZol€ot YlLqobYN‹ENXRP…bR€LR€XLqtoP…N€ 2 2 2  2 (3)Any manager, if you or the additional (3) Tenant Liability insured is a limited liability company;That is insurance purchased by you to (4)Any "executive officer" or insurance cover your liability as a tenant for manager, if you or the additional insured is "property damage" to premises rented to a corporation;you or temporarily occupied by you with permission ofthe owner;(5)Any trustee, if you or the additional (4) Aircraft, Auto Or Watercraftinsured is a trust; or (6)Any elected or appointed official, if you or If the loss arises out of the maintenance or the additional insured is a political use of aircraft, "autos" or watercraft to the subdivision or public entity. extent not subject to Exclusion g. of Section I - Coverage A - Bodily Injury AndThis duty applies separately to you and any Property Damage Liability;additional insured. (5) Property Damage To Borrowed3. Legal Action Against Us Equipment Or Use Of ElevatorsNo person or organization has a right under this If the loss arises out of "property damage"Coverage Part:to borrowed equipment or the use ofa.To join us as a party or otherwise bring us elevators to the extent not subject tointo a "suit" asking for damages from an Exclusion j.of Section I - Coverage A -insured; or Bodily Injury And Property Damage b.To sue us on this Coverage Part unless all of Liability; its terms have been fully complied with.(6) When You Are Added As An Additional A person or organization may sue us to recover Insured To Other Insurance on an agreed settlement or on a final judgment Any other insurance available to youagainst an insured; but we will not be liable for covering liability for damages arising outdamages that are not payable under the terms of of the premises or operations, or productsthis Coverage Part or that are in excess of the and completed operations, for which youapplicable limit of insurance. An agreed have been added as an additional insuredsettlement means a settlement and release of by that insurance; orliability signed by us, the insured and the (7) When You Add Others As Anclaimant or the claimant's legal representative. Additional Insured To This Insurance4. Other Insurance Any other insurance available to anIf other valid and collectible insurance is additional insured.available to the insured for a loss we cover under However, the following provisions apply toCoveragesAorBof this Coverage Part, our other insurance available to any person orobligations are limited as follows:organization who is an additional insureda. Primary Insurance under this coverage part. This insurance is primary except when b.(a) Primary Insurance When Requiredbelow applies. If other insurance is also By Contractprimary, we will share with all that other This insurance is primary if you haveinsurance by the method described in c.agreed in a written contract or writtenbelow.agreement that this insurance beb. Excess Insurance primary. If other insurance is also This insurance is excess over any of the other primary, we will share with all that insurance, whether primary, excess,other insurance by the method contingent or on any other basis:described in c.below. (1) Your Work (b)Primary And Non-Contributory To Other Insurance When Required ByThat is Fire, Extended Coverage, Builder's ContractRisk, Installation Risk or similar coverage for "your work";If you have agreed in a written contract, written agreement, or permit(2) Premises Rented To You that this insurance is primary and non-That is fire, lightning or explosion contributory with the additionalinsurance for premises rented to you or insured's own insurance, this insurancetemporarily occupied by you with is primary and we will not seekpermission ofthe owner;contribution from that other insurance. Page 16 of 21 HG 00 01 09 16 Policy No. 57UEAFN9382 CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) 1/30/2020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGRATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Willis Towers Watson 12980 Metcalf Ave Suite 500 Overland Park KS 66213 CONTACT NAME: San Jose PHONE (A/C, No Ext): (408) 321-9901 FAX (A/C, NO): (360) 828-0699 EMAIL ADDRESS: Jerry.Sparks@bbsihq.com INSURER(S) AFFORDING COVERAGE NAIC # INSURER A:ACE American Insurance Company 22667 INSURED Barrett Business Services, Inc. L/C/F BEAR ELECTRICAL SOLUTIONS, INC. 1341 ARCHER STREET SAN JOSE, CA 95131 INSURER B: INSURER C: INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUES OR MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSR SUBR WVD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PROJ- ECT LOC EACH OCCURRENCE $ DAMAGE TO RENTED PREMISES (Ea occurence)$ MED EXP (Any one person)$ PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ PRODUCTS - COMP/OP AGG $ $ AUTOMOBILE LIABILITY ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS NON-OWNED AUTOS COMBINED SINGLE LIMIT (Ea accident)$ BODILY INJURY (Per person)$ BODILY INJURY (Per accident)$ PROPERTY DAMAGE (Per accident) $ $ UMBRELLA LIAB OCCUR EXCESS LIAB OCCUR DED RETENTION $ EACH OCCURRENCE $ AGGREGATE $ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y/N ANY PROPRIETOR/PARTNER/ EXECUTIVE OFFICER/MEMBER EXCLUDED? Y (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below N / A X C66386909 Covered states: CA 02/01/20 02/01/2021 9 WC STATU- TORY LIMITS OTH- ER E.L. EACH ACCIDENT $2,000,000 E.L. DISEASE - EA EMPLOYEE $2,000,000 E.L. DISEASE - POLICY LIMIT $2,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required) In the event of any payment under this policy for a Loss for which the named insured has waived the right of recovery in a written contract entered into prior to the Loss, insurer hereby agrees to also waive our right of recovery but only with respect to such Loss. CERTIFICATE HOLDER CANCELLATION City of Cupertino SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATA THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 10300 Torre Avenue AUTHORIZED REPRESENTATIVE Cupertino CA 95014 Authorized Rep c) 1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05)The ACORD name and logo are registered marks of ACORD. A++, XV AGENCY CUSTOMER ID: _____________________________________ LOC: #:______________________________________ ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY Lockton Affinity POLICY NUMBER C66386909 CARRIER NAIC CODE ACE American Insurance Company 22667 NAMED INSURED: Barrett Business Services, Inc. L/C/F BEAR ELECTRICAL SOLUTIONS, INC. 1341 ARCHER STREET SAN JOSE, CA 95131 EFFECTIVE DATE:02/01/20 ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability (01/14) CERTIFICATE HOLDER:City of Cupertino ADDRESS:10300 Torre Avenue Cupertino CA 95014 RE: All Agreements. ACORD 101 (2008/01)c) 1988-2010 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD. Workers' Compensation and Employers' Liability Policy Named Insured Endorsement Number Policy Number Symbol: Number: Policy Period TO Effective Date of Endorsement Issued By (Name of the Insurance Company) Insert the policy number. The remainder of the information is to be completed only when this endorsement is issued subsequent to the preparation of the policy. CALIFORNIA WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement applies only to the insurance provided by the policy because California is shown in Item 3.A. of the Information Page. We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule, but this waiver applies only with respect to bodily injury arising out of the operations described in the Schedule, where you are required by a written contract to obtain this waiver from us. You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. Schedule 1.( ) Specific Waiver Name of person or organization: ( ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. 2.Operations: 3. Premium: The premium charge for this endorsement shall be percent of the California premium developed on payroll in connection with work performed for the above person(s) or organization(s) arising out of the operations described. 4.Minimum Premium: _______________________________________ Authorized Agent WC 99 03 22 Barrett Business Services, Inc. L/C/F BEAR ELECTRICAL SOLUTIONS, INC. 1341 ARCHER STREET SAN JOSE, CA 95131 C66386909 2/1/2020 2/1/2021 2/1/2020 Ace American Insurance Co. X INCLUDED INCLUDED