Loading...
21-046 Tucker Construction Inc, On-Call Abatement ServicesOn call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 1 of 12 ON-CALL PUBLIC WORKS CONTRACT WITH TUCKER CONSTRUCTION INC 1. PARTIES This On-Call Public Works Contract (“Contract”) is made by and between the City of Cupertino, a municipal corporation (“City”), and Tucker Construction Inc (“Contractor”) a Corporation for On call abatement services, and is effective on the last date signed below (“Effective Date”). 2. SCOPE OF WORK 2.1 Scope of Work. Contractor will perform and provide all labor, materials, equipment, supplies, transportation and any other items or work necessary to perform and complete the work described in the Scope of Work (“Work”), attached and incorporated here as Exhibit A, on an as- needed basis. The Work must comply with this Contract and with each Service Order issued by the City’s Project Manager or his/her designee, in accordance with the following procedures, unless otherwise specified in Exhibit A. Contractor further agrees to carry out its work in compliance with the City’s Shelter In Place and Social Distancing Requirements, attached here and incorporated as Exhibit A-A. 2.2 Service Orders. Before issuing a Service Order, the City Project Manager will request that Work be done in writing and hold a meeting with Contractor to discuss the Service Order. Contractor will submit a written proposal that includes a specific Scope of Work, Schedule of Performance, and Compensation, which the Parties will discuss. Thereafter, City will execute a Service Order Form for the Work, attached and incorporated here as Exhibit B. The Service Order will specify the Scope of Work, Schedule of Performance, Compensation, and any other conditions applicable to the Service Order. Issuance of a Purchase Order is discretionary. The City Project Manager is authorized to streamline these procedures based on the City’s best interests. Contractor will not be compensated for Work performed without a duly authorized and executed Service Order. 3. TIME OF PERFORMANCE 3.1 Term. This Contract begins on the Effective Date and ends on June 30, 2022 (“Contract Time”), unless terminated earlier as provided herein. The City’s appropriate department head or City Manager may extend the Contract Time through a written amendment to this Contract, provided such extension does not include additional contract funds. Extensions requiring additional contract funds are subject to the City’s purchasing policy. 3.2 Schedule of Performance. Contractor must complete the Work within the time specified in each Service Order, and under no circumstances should the Work go beyond the Contract Time. 3.3 Time is of the essence for the performance of all the Work required in this Contract and in each Service Order. Contractor must have sufficient time, resources, and qualified staff to deliver the Work on time. Contractor must respond promptly to each Service Order request. On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 2 of 12 4. COMPENSATION 4.1 Maximum Compensation. City will pay Contractor for satisfactory performance of the Work a total amount that will based upon actual costs but that will be capped so as not to exceed $12,500.00 (“Contract Price”), based upon the Scope of Work in Exhibit A and the budget and rates included. The maximum compensation includes all expenses and reimbursements and will remain in place even if Contractor’s actual costs exceed the capped amount. 4.2 Per Service Order. Compensation for Work provided under a Service Order will be based on the rates set forth in the Service Order, which shall not exceed the capped amount specified in the Service Order. 4.3 Invoices and Payments. Contractor must submit an invoice on the first day of each month, describing the Work performed during the preceding month, itemizing labor, materials, equipment, and any incidental costs incurred. Contractor will be paid ninety-five percent (95%) of the undisputed amounts billed within thirty (30) days after City receives a properly submi tted invoice. Any retained amounts will be included with Contractor’s final payment within sixty (60) days of City’s acceptance of the Work pursuant to a specific Service Order as complete. 5. INDEPENDENT CONTRACTOR 5.1 Status. Contractor is an independent contractor and not an employee, partner, or joint venture of City. Contractor is solely responsible for the means and methods of performing the Work and for the persons hired to work under this Contract. Contractor is not entitled to health benefits, worker’s compensation, or other benefits from the City. 5.2 Contractor’s Qualifications. Contractor warrants on behalf of itself and its subcontractors that they have the qualifications and skills to perform the Work in a competent and professional manner and according to the highest standards and best practices in the industry. 5.3 Permits and Licenses. Contractor warrants on behalf of itself and its subcontractors that they are properly licensed, registered, and/or certified to perform the Work as required by law and have procured a City Business License, if required by the Cupertino Municipal Code. Contractor shall possess a California Contractor’s License in good standing for the following classification(s): , which must remain valid for the entire Contract Time. 5.4 Subcontractors. Only Contractor’s employees are authorized to work under this Contract. Prior written approval from City is required for any subcontractor, and the terms and conditions of this Contract will apply to any approved subcontractor. 5.5 Tools, Materials, and Equipment. Contractor will supply all tools, materials, and equipment required to perform the Work under this Contract. 5.6 Payment of Benefits and Taxes. Contractor is solely responsible for the payment of employment taxes incurred under this Contract and any similar federal or state taxes. Contractor and any of its employees, agents, and subcontractors shall not have any claim under this Contract or otherwise against City for seniority, vacation time, vacation pay, sick leave, personal time off, overtime, health insurance, medical care, hospital care, insurance benefits, social security, disability, On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 3 of 12 unemployment, workers compensation or employee benefits of any kind. Contractor shall be solely liable for and obligated to pay directly all applicable taxes, fees, contributions, or charges applicable to Contractor’s business including, but not limited to, federal and state income taxes. City shall have no obligation whatsoever to pay or withhold any taxes or benefits on behalf of Contractor. Should any court, arbitrator, or administrative authority, including but not limited to the California Public Employees Retirement System (PERS), the Internal Revenue Service or the State Employment Development Division, determine that Contractor, or any of its employees, agents, or subcontractors, is an employee for any purpose, then Contractor agrees to a reduction in amounts payable under this Contract, or to promptly remint to City any payments due by the City as a result of such determination, so that the City’s total expenses under this Contract are not greater than they would have been had the determination not been made. 6. CHANGE ORDERS Amendments and change orders must be in writing and signed by City and Contractor. Contractor’s request for a change order must specify the proposed changes in the Work, Contract Price, and Contract Time. Each request must include all the supporting documentation, including but not limited to plans/drawings, detailed cost estimates, and impacts on schedule and completion date. 7. ASSIGNMENTS; SUCCESSORS Contractor shall not assign, hypothecate, or transfer this Contract or any interest therein, directly or indirectly, by operation of law or otherwise, without prior written consent of City. Any attempt to do so will be null and void. Any changes related to the financial control or business nature of Contractor as a legal entity is considered an assignment of the Contract and subject to City approval, which shall not be unreasonably withheld. Control means fifty percent (50%) or more of the voting power of the business entity. This Contract is binding on Contractor, its heirs, successors, and permitted assigns. 8. PUBLICITY / SIGNS Any publicity generated by Contractor for the Project during the Contract Time, and for one (1) year thereafter must credit City contributions to the Project. The words “City of Cupertino” must be displayed in all pieces of publicity, flyers, press releases, posters, brochures, interviews, public service announcements, and newspaper articles. No signs may be posted or displayed on or about City property, except signage required by law or this Contract, without prior written approval from the City. 9. SUBCONTRACTORS 9.1 Contractor must perform all the Work with its own forces, except that Contractor may hire qualified subcontractors to perform up to % of the Work under any give Service Order, provided that each subcontractor is required by contract to be bound by the provisions of this Contract and any applicable Service Order. Contractor must provide City with written proof of compliance with this provision upon request. 9.2 City may reject any subcontractor of any tier and bar a subcontractor from performing Work on the Project, if City in its sole discretion determines that subcontractor’s Work falls short of the On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 4 of 12 requirements of this Contract or constitutes grounds for rejection under the Public Contract Code. If City rejects a subcontractor, Contractor at its own expense must perform the subcontractor’s Work or hire a new subcontractor that is acceptable to City. A Notice of Completion must be recorded within fifteen (15) days after City accepts the Work under a particular Service Order if the Work involves work by subcontractors. 10. RECORDS AND DAILY REPORTS 10.1 Contractor must maintain daily reports of the Work and submit them to City upon request and at completion of Work pursuant to a Service Order. The reports must describe the Work and specific tasks performed, the number of workers, the hours, the equipment, the weather conditions, and any circumstances affecting performance. City will have ownership of the reports, but Contractor will be permitted to retain copies. 10.2 If applicable, Contractor must keep a separate set of as-built drawings showing changes and updates to the Scope of Work or the original drawings as changes occur. Actual locations to scale must be identified for all major components of the Work, including mechanical, electrical and plumbing work; HVAC systems; utilities and utility connections; and any other components City determines should be included in the final drawings of the Project. Deviations from the original drawings must be shown in detail, and the location of all main runs, piping, conduit, ductwork, and drain lines must be shown by dimension and elevation. 10.3 Contractor must maintain complete and accurate accounting records of its Work, in accordance with generally accepted accounting principles, which must be available for City review and audit, kept separate from other records, and maintained for four (4) years from the date of City’s final payment. 11. INDEMNIFICATION 11.1 To the fullest extent allowed by law, and except for losses caused by the sole and active negligence or willful misconduct of City personnel, Contractor shall indemnify, defend, and hold harmless City, its City Council, boards and commissions, officers, officials, employees, agents, servants, volunteers, and Contractors (“Indemnitees”), through legal counsel acceptable to City, from and against any and all liability, damages, claims, actions, causes of action, demands, charges, losses, costs, and expenses (including attorney fees, legal costs, and expenses related to litigation and dispute resolution proceedings), of every nature, arising directly or indirectly from this Contract or in any manner relating to any of the following: (a) Breach of contract, obligations, representations or warranties; (b) Performance or nonperformance of the Work or of any obligations under the Contract by Contractor, its employees, agents, servants, or subcontractors; (c) Payment or nonpayment by Contractor or its subcontractors or sub-subcontractors for Work performed on or off the Project Site; and (d) Personal injury, property damage, or economic loss resulting from the work or performance of Contractor or its subcontractors or sub-subcontractors. 11.2 Contractor must pay the costs City incurs in enforcing this provision. Contractor must accept On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 5 of 12 a tender of defense upon receiving notice from City of a third-party claim, in accordance with California Public Contract Code Section 9201. At City’s request, Co ntractor will assist City in the defense of a claim, dispute, or lawsuit arising out of this Contract. 11.3 Contractor’s duties under this entire Section 11 are not limited to Contract Price, Workers’ Compensation, or other employee benefits, or the insurance and bond coverage required in this Contract. Nothing in the Contract shall be construed to give rise to any implied right of indemnity in favor of Contractor against City or any other Indemnitee. 11.4 Contractor’s payments may be deducted or offset to cover any money the City lost due to a claim or counterclaim arising out of this Contract, a purchase order or other transaction. 11.5 Contractor agrees to obtain executed indemnity agreements with provisions identical to those set forth here in this Section 11 from each and every subcontractor, or any other person or entity involved by, for, with, or on behalf of Contractor in the performance of this Contract. Failure of City to monitor compliance with these requirements imposes no additional obligations on City and will in no way act as a waiver of any rights hereunder. 11.6 This Section 11 shall survive termination of the Contract. 12. INSURANCE Contractor shall comply with the Insurance Requirements, attached and incorporated here as Exhibit C, and must maintain the insurance for the Contract Time, or longer as required by City. City will not execute the Contract until City approves receipt of satisfactory certificates of insurance and endorsements evidencing the type, amount, class of operations covered, and the effective and expiration dates of coverage. Failure to comply with this provision may result in City, at its sole discretion and without notice, purchasing insurance for Contractor and deducting the costs from Contractor’s compensation or terminating the Contract. 13. COMPLIANCE WITH LAWS 13.1 General Laws. Contractor shall comply with all local, state, and federal laws and regulations applicable to this Contract. Contractor will promptly notify City of changes in the law or other conditions that may affect the Project or Contractor’s ability to perform. Contractor is responsible for verifying the employment authorization of employees performing the Work, as required by the Immigration Reform and Control Act. 13.2 Labor Laws. a. The following provisions apply to any Service Order of $1,000 or more: i. In General. For purposes of California labor law, this is a public works contract subject to the provisions of Part 7 of Division 2 of the California Labor Code (Sections 1720 et seq.). In accordance with Labor Code Section 1771, Contractor and all subcontractors shall pay not less than current prevailing wage rates as determined by the California Department of Industrial Relations (“DIR”) to all workers employed on this project. In accordance with Labor Code Section 1815, Contractor and all subcontractors shall pay all workers employed on this project 1 ½ the basic rate of pay for work On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 6 of 12 performed in excess specified hour limitations. The work performed pursuant to this Contract is subject to compliance monitoring and enforcement by the Department of Industrial Relations. ii. Registration. Contractor and all subcontractors shall not engage in the performance of any work under this Contract unless currently registered and qualified to perform public work pursuant to section 1725.5 of the California Labor Code. Contractor represents and warrants that it is registered and qualified to perform public work pursuant to section 1725.5 of the Labor Code and will provide its DIR registration number, along with the registration numbers of any subcontractors as required, to the City. iii. Posting. Contractor shall post at the job site the determination of the DIR director of the prevailing rate of per diem wages together with all job notices that are required by regulations of the DIR. iv. Reporting. Contractor and any subcontractors shall keep accurate payroll records in accordance with Section 1776 of the Labor Code and shall furnish the payroll records directly to the Labor Commissioner in accordance with the law. v. Report on Prevailing Rate of Wages. The City has obtained the general prevailing rate of per diem wages in the vicinity of the project for each type of worker needed, a copy of which is on file at the City of Cupertino City Hall, and shall be made available to any interested party upon request. vi. Employment of Apprentices. Contractor’s attention is directed to the provisions in Sections 1777.5 and 1777.6 of the Labor Code concerning the employment of apprentices by the Contractor or any subcontractor. It shall be the responsibility of the Contractor to effectuate compliance on the part of itself and any subcontractors with the requirements of said sections in the employment of apprentices. Information relative to apprenticeship standards, wage schedules, and other requirements may be obtained from the Director of Industrial Relations, ex-officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. vii. Penalties. Contractor’s attention is directed to provisions in Labor Code Sections 1775 and 1813. In accordance with Labor Code Section 1775, Contractor and subcontractors may be subject to penalties for Contractor’s and subcontractors’ failure to pay prevailing wage rates. In accordance with Labor Code Section 181 3, Contractor or subcontractors may be subject to penalties for Contractor’s or subcontractors’ failure to pay overtime pay rates for hours worked by workers employed on this project in excess specified hour limitations. b. Contractor must compensate workers who are paid less than prevailing wages or required to work more than a legal day’s work. Contractor will also be required to pay City a penalty of $ per worker for each day of violation. c. As required by Labor Code Section 1861, by signing this Contract Contractor certifies as follows: “I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers’ compensation or to undertake self - insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the work of this contract.” 13.3 Discrimination Laws. Contractor shall not discriminate on the basis of race, religious creed, color, ancestry, national origin, ethnicity, handicap, disability, marital status, pregnancy, age, sex, gender, sexual orientation, gender identity, Acquired-Immune Deficiency Syndrome (AIDS), or any On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 7 of 12 other protected classification. Contractor shall comply with all anti -discrimination laws, including Government Code Sections 12900 and 11135, and Labor Code Sections 1735, 1777, and 3077.5. Consistent with City policy prohibiting harassment and discrimination, Contractor understands that harassment and discrimination directed toward a job applicant, an employee, a City employee, or any other person, by Contractor or Contractor’s employees or subcontractors will not be tolerated. Contractor agrees to provide records and documentation to the City on request necessary to monitor compliance with this provision. 13.4 Conflicts of Interest. Contractor, its employees, subcontractors, servants, and agents, may not have, maintain, or acquire a conflict of interest in relation to this Contract in violation of law, including Government Code section 1090 and Government Code section 81000 and their accompanying regulations. No officer, official, employee, consultant, or other agent of the City (“City Representative”) may have, maintain, or acquire a “financial interest” in the Contract, as that term is defined by state law, or in violation of a City ordinance or policy while serving as a City Representative or for one year thereafter. Contractor, its employees, subcontractors, servants, and agents warrant they are not employees of City nor do they have any relationship with City officials, officers, or employees that creates a conflict of interest. Contractor may be required to file a conflict of interest form if it makes certain governmental decisions or serves in a staff capacity, as defined in Section 18700 of Title 2 of the California Code of Regulations. Contractor agrees to abide by City rules governing gifts to public officials and employees. 13.5 Remedies. Any violation of this Section 13 constitutes a material breach and may result in City suspending payments, requiring reimbursements, or terminating this Contract. City reserves all other rights and remedies available under the law and this Contract, including the right to seek indemnification under Section 11 of this Contract. 14. BONDS For any Service Order of $25,000 or more, Contractor must obtain a payment bond and a performance bond, each in the penal sum of 100% of the compensation pursuant to the Service Order, using the Bond Forms attached and incorporated here as Exhibit D. Each bond must be issued by a surety admitted in California, with a financial rating from A.M. Best Company of Class A- or higher, or as otherwise acceptable to City. If an issuing surety cancels a bond or becomes insolvent, Contractor must provide a substitute bond from a surety acceptable to City within seven (7) calendar days after written notice from City. If Contractor fails to do so, City may in its sole discretion and without prior notice, purchase bonds at Contractor’s expense, deduct the cost from payments due Contractor, or terminate the Service Order or Contract. City will not authorize work under a Service Order until the required bonds are submitted. 15. UTILITIES, TRENCHING, AND EXCAVATION 15.1 Contractor must call the Underground Service Alert (“USA”) 811 hotline and request marking of utility locations before digging or commencing Work. For underground service alerts for street lighting and traffic signal conduits, City’s Service Center must be called at (408) 777 - 3269. Government Code Section 4215 requires Contractor to notify City and Utility in writing if it discovers utilities or utility facilities not identified in the Contract. 15.2 Pursuant to Government Code Section 7104, Contractor must stop work, notify City in On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 8 of 12 writing, and wait for instructions if one of the conditions below is found at the worksite. City will work with Contractor to amend the Contract or issue a change order if the discovered conditions materially change the Work/Performance, Contract Time or Contract Price. (a) Material believed to be hazardous waste under Health and Safety Code Section 25117, and which requires removal to a Class I, Class II, or Class III disposal site pursuant to law; (b) Subsurface or latent physical conditions at the Project worksite differing from those indicated by information about the worksite made available to Contractor; and (c) Unknown physical conditions at the Project worksite of any unusual nature, materially different from those ordinarily encountered and from those generally recognized as inherent in the character of the Work. 15.3 For Service Orders where compensation is $25,000 or higher that require excavation or involve trenches five feet or more in depth, Contractor must submit a detailed plan for City approval, per Labor Code Section 6705, prior to commencing work. The plan must show the design of shoring, bracing, sloping, and other provisions for worker protection from caving ground and other hazards. The protective system must comply with all Construction Safety Orders. If the plan varies from shoring system standards, it must be prepared by a registered civil or structural engineer. 16. URBAN RUNOFF MANAGEMENT 16.1 All Work must fully comply with federal, state, and local laws and regulations concerning storm water management. Contractor must avoid creating excess dust when breaking asphalt or concrete and during excavation and grading. If water is used for dust control, Contractor will use only the amount of water necessary to dampen the dust. Contractor will take all steps necessary to keep wash water out of the streets, gutters, and storm drains. Prior to the start of the Work, Contractor will implement erosion and sediment controls to prevent pollution of storm drains, and must upgrade and maintain these controls based on weather conditions or as otherwise required by City. These controls must be in place during the entire Contract Time and must be removed at the end of construction and completion of the Work. Such controls must include, but will not be limited to, the following requirements: (a) Install storm drain inlet protection devices such as sand bag barriers, filter fabric fences, and block and gravel filters at all drain inlets impacted by construction. During the annual rainy season, October 15 through June 15, storm drain inlets impacted by construction work must be filter-protected from onsite de-watering activities and saw-cutting activities. Shovel or vacuum saw-cut slurry and remove from the Work site; (b) Cover exposed piles of soil or construction material with plastic sheeting. Store all construction materials in containers; (c) Sweep and remove all materials from paved surfaces that drain to streets, gutters and storm drains prior to rain and at the end of each work day. When the Work is completed, wash the streets, collect and dispose of the wash water offsite in lawful manner; (d) After breaking old pavement, remove debris to avoid contact with rainfall/runoff; (e) Maintain a clean work area by removing trash, litter, and debris at the end of each work day and when Work is completed. Clean up any leaks, drips, and other spills as they occur. These requirements must be used in conjunction with the California Stormwater Quality Association and California Best Management Practices Municipal and Construction Handbooks, local program guidance materials from municipalities, and any other applicable documents on stormwater quality On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 9 of 12 controls for construction. Contractor’s failure to comply with this Section will result in the issuance of noncompliance notices, citations, Work stop orders and regulatory fines. 17. PROJECT COORDINATION City Project Manager. The City assigns Albert Salvador as the City’s representative for all purposes under this Contract, with authority to oversee the progress and performance of the Scope of Work. City reserves the right to substitute another Project manager at any time, and without prior notice to Contractor. Contractor Project Manager. Subject to City approval, Contractor assigns Penny Bitcon as its single Representative for all purposes under this Contract, with authority to oversee the progress and performance of the Work. Contractor’s Project manager is responsible for coordinating and scheduling the Work in accordance with City instructions, service orders, and the Schedule of Performance. Contractor must regularly update the City’s project manager about the status, progress and any delays with the work. City’s written approval is required prior to Contractor substituting a new Representative which shall result in no additional costs to City. 18. ABANDONMENT AND TERMINATION 18.1 City may abandon or postpone the Work or parts thereof at any time. Contractor will be compensated for satisfactory Work performed through the date of abandonment and will be given reasonable time to close out Work under a Service Order. With City’s pre-approval in writing, the time spent in closing out Work under a Service Order will be compensated up to ten percent (10%) of the total time expended in performing the Work. 18.2 City may terminate the Contract for cause or without cause at any time. Contractor will be paid for satisfactory Work rendered through the termination date and will be given reasonable time to close out the Work. 18.3 Final payment will not be made until Contractor delivers the Work and provides records documenting the Work, products, and deliverables completed. 19. GOVERNING LAW, VENUE, AND DISPUTE RESOLUTION This Contract is governed by the laws of State of California. Venue for any legal action shall be the Superior Court of the County of Santa Clara, California. The dispute resolution procedures of Public Contract Code Section 20104, et seq., incorporated here by reference, apply to this Contract and Contractor is required to continue the Work pending resolution of any dispute. Prior to filing a lawsuit, Contractor must comply with the claim filing requirements of the California Government Code. If the Parties elect arbitration, the arbitrator’s award must be supported by law and substantial evidence and include detailed written findings of law and fact. 20. ATTORNEY FEES If City initiates legal action, files a complaint or cross-complaint, or pursues arbitration, appeal, or other proceedings to enforce its rights or a judgment in connection with this Contract, the prevailing party will be entitled to reasonable attorney fees and costs. On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 10 of 12 21. SIGNS/ADVERTISEMENTS No signs may be displayed on or about City’s property, except signage which is required by law or by the Contract, without City’s prior written approval as to size, design and location. 22. THIRD PARTY BENEFICIARIES There are no intended third party beneficiaries of this Contract. 23. WAIVER Neither acceptance of the Work nor payment thereof shall constitute a waiver of any contract provision. City’s waiver of a breach shall not constitute waiver of another provision or breach. 24. WARRANTY Contractor warrants that materials and equipment used will be new, of good quality, and free from defective workmanship and materials, and that the Work will be free from material defects not intrinsic in the design or materials. All Work, materials, and equipment should pass to City free of claims, liens, or encumbrances. Contractor warrants the Work and materials for one year from the date of City’s acceptance of the Work as complete (“Warranty Period”), except when a longer guarantee is provided by a supplier, manufacturer or is required by this Cont ract. During the Warranty Period, Contractor will repair or replace any Work defects or materials, including damage that arises from Contractor’s Warranty Work, except any wear and tear or damage resulting from improper use or maintenance. 25. ENTIRE AGREEMENT This Contract and the attachments, documents, and statutes attached, referenced, or expressly incorporated herein, including authorized amendments or change orders constitute the final and complete contract between City and Contractor with respect to the Work and the Project. No oral contract or implied covenant will be enforceable against City. If there is any inconsistency between any term, clause, or provision of the main Contract and any term, clause, or provision of the attachments or exhibits thereto, the terms of the main Contract shall prevail and be controlling. 26. SEVERABILITY/PARTIAL INVALIDITY If a court finds any term or provision of this Contract to be illegal, invalid, or unenforceable, the legal portion of said provision and all other contract provisions will remain in full force and effect. 27. SURVIVAL The contract provisions which by their nature should survive the Contract or Completion of Project, including without limitation all provisions regarding warranties, indemnities, pa yment obligations, insurance, and bonds, shall remain in full force and effect after the Work is completed or Contract ends. On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 11 of 12 28. INSERTED PROVISIONS Each provision and clause required by law for this Contract is deemed to be included and will be inferred herein. Either party may request an amendment to cure mistaken insertions or omissions of required provisions. The Parties will collaborate to implement this Section, as appropriate. 29. HEADINGS The headings in this Contract are for convenience only, are not a part of the Contract and in no way affect, limit, or amplify the terms or provisions of this Contract. 30. COUNTERPARTS This Contract may be executed in counterparts, each of which is an original and all of which taken together shall form one single document. 31. NOTICES All notices, requests and approvals must be sent in writing to the persons below, which will be considered effective on the date of personal delivery or the date confirmed by a reputable overnight delivery service, on the fifth (5th) calendar day after deposit in the United States Mail, postage prepaid, registered or certified, or the next business day following electronic submission: To City of Cupertino Office of the City Manager 10300 Torre Ave. Cupertino, CA 95014 Attention: Albert Salvador Email: alberts@cupertino.org To Contractor: Tucker Construction Inc 1725-D Little Orchard St. San Jose, CA 95125 Attention: Penny Bitcon Email: penny@tuckercon.com 32. VALIDITY OF CONTRACT This Contract is valid and enforceable only if (a) it complies with the purchasing and contract provisions of Cupertino Municipal Code Chapters 3.22 and 3.23, as amended from time to time, (b) is signed by the City Manager or an authorized designee, and (c) is approved for form by the City Attorney’s Office. 33. EXECUTION The persons signing below warrant they have the authority to enter into this Contract and to legally bind their respective Parties. If Contractor is a corporation, signatures from two officers of the corporation are required pursuant to California Corporations Code Section 313. This Contract may be executed in counterparts, each one of which is deemed an original and all of which, taken together, constitute a single binding instrument. On call abatement services On-Call Public Works Contract/ Rev. Jan. 2021 Page 12 of 12 IN WITNESS WHEREOF, the parties have caused the Contract to be executed. CITY OF CUPERTINO A Municipal Corporation By Name Title Date TUCKER CONSTRUCTION INC By Name Title Date APPROVED AS TO FORM: HEATHER M. MINNER Cupertino City Attorney ATTEST: KIRSTEN SQUARCIA City Clerk Date Mark Tucker President Apr 5, 2021 Mark Tucker Heather M. Minner Director of Community Development Benjamin Fu Apr 5, 2021 Apr 6, 2021 February 5, 2021 Jeffrey Trybus Senior Code Enforcement Officer Code Enforcement City of Cupertino Re: List of Services Provided by Tucker Construction Jeffrey: We are a General contractor with a B and C-13 fencing license. We have been in business for 40 years and have done many jobs that municipalities have had difficulty find contractors to do. In the area of Code or Law Enforcement we have been and currently have Open Purchase Orders for boarding up buildings or points of access on an emergency or scheduled arrangement. We have Open Purchase orders for weed abatement and blight clean-up of nonconforming properties. We have cleaned up hoarder house and drug house. It is often hard to find someone to do this work and be able to comply with the City’s requirements. Look at some of the cost guidelines we currently are using and if they don’t included the work you need we can discuss what pricing could be used. I think Cupertino requires wages to be Prevailing Wage rates so I have listed as such. Building Board-ups Laborer 110.00/hr Materials, plywood, 2x4s, hardware at cost + 20% Rubbish and weed abatement Laborer 80.00/hr Haz Mat handler, Bio-waste 144.00/hr PPE included Operator engineer, Skid Steer driver 110.00 Dumpster Cost plus 20% Equipment Rental Cost plus 20% Additional items see HEC Price Sheet Exhibit A Other Trades Fencing Iron Worker/Welder Carpentry Concrete/Masonry Carpentry Minor Plumbing and Electric Painting Certified Traffic Flaggers Hope this gives you more information. Please let me know if you have any questions. If you would like me to prepare an estimate for the 7573 Prospect Road property let me know. Thank-you, Mark Tucker Mark Tucker Revised: July 13, 2020 – Public Works Contracts 1 Exhibit A-A – SHELTER IN PLACE AND SOCIAL DISTANCING REQUIREMENTS A. Health Laws Acknowledged. It is acknowledged that Consultant’s/Contractor’s (“Contractor”) duty to comply with Laws, as defined in Section 13 of the Contract/Agreement (“Contract”), includes immediate compliance by Contractor and its subcontractors with the restrictions on travel and the Social Distancing Requirements set forth in the most recent health order issued by the County of Santa Clara Health Department in response to the COVID-19 pandemic, and any subsequent amendments or superseding orders thereto (the “Health Order”), and any other local, state, or federal laws that have been or may be enacted in response to the COVID-19 pandemic (collectively, “Health Laws”). B. Health Order Compliance. Contractor shall comply with any restrictions on travel and social distancing requirements in the Health Order when preforming work under this Contract. If a scope of work item, notice to proceed, or work order under this Contract specifies work that cannot be performed in compliance with the Health Order or other Health Laws, Contractor shall refrain from conducting the work and immediately inform the City. C. Individuals at High Risk of Severe Illness. Nothing in this Contract shall be interpreted to require any person at high risk of severe illness from COVID-19 to leave their residence to perform work under the Contract. Contractor will inform the City if other arrangements for the work must be made, and City will do so, with no penalty to Contractor, although Contractor will not be compensated for work performed by the City or third parties. Information from the Center for Disease Control ("CDC") on "high risk" categories is available at the CDC's website at: https://www.cdc.gov/coronavirus/2019-ncov/specific-groups/people-at-higher-risk.html. D. Health Order Requirements and Best Practices. Contractor will immediately undertake all appropriate measures to ensure compliance with the Social Distancing Requirements in the Health Order by all individuals on any project site or work area performing work under this Contract, including Contractor's or any subcontractor's workers, employees, representatives, vendors, or suppliers (collectively, "workers"), and shall maintain these measures for as long as required by the Health Order or other Health Laws. In particular, Contractor must comply with the provisions of the County’s Mandatory Directive for Construction Projects (attached hereto), as applicable. Further, as long as required by the operative Health Order or Mandatory Directive for Construction Projects, or other Health Laws, these measures shall include, but are not limited to, the following best practices: 1. Information. Inform all workers of the Social Distancing Requirements and these best practices, including any updates or modifications, and require compliance as a condition to being present on the project site or work area. Revised: July 13, 2020 – Public Works Contracts 2 2. Social Distancing Protocol. Fill out and submit the newest version of the Social Distancing Protocol to the County, using the County’s online form available at https://www.sccgov.org/sites/covid19/Pages/social-distancing-protocol.aspx. 3. Sick Workers. Prohibit any individuals who have been tentatively or conclusively diagnosed with COVID-19 or who have any symptoms of illness, including the following, from entering or remaining on the project site or work area: fever, cough, shortness of breath, sore throat, body aches, chills, sudden loss of smell or taste or other flu-like symptoms. Encourage sick workers to get immediate medical attention. 4. Signage/Posters. As required, post or distribute (1) the most updated version of the COVID-19 PREPARED Sign, and (2) a Social Distancing Protocol Visitor Information Sheet. 5. Face Coverings. Everyone at a job site must wear a face covering at all time, except children under the age of 2, people who are medically prevented from wearing a face covering, and for communication by or with people who are hearing impaired. 6. Sanitary Facilities. Ensure adequate handwashing and/or hand-sanitizing facilities are available at all times and encourage frequent handwashing and/or hand-sanitizing throughout the day as specified below. Portable sanitary facilities must be serviced and cleaned on a daily basis. Provide hand sanitizer in or around all toilet facilities and common areas, including project trailers. a. Handwashing. Wash hands using soap and water for at least 20 seconds. b. Hand-sanitizer. Use a hand sanitizer that contains at least 60-95% alcohol when handwashing is not immediately available. c. Paper Products. Ensure that toilet paper, tissues, and paper towels are available as appropriate, with designated receptacles for disposal. 7. Distancing. Prohibit workers from being less than six feet apart, unless and only to the extent that would compromise worker safety or violate safety Laws for specific operations. Prohibit handshaking or any physical contact among workers, with the sole and limited exception of any physical contact required for worker safety or to comply with safety Laws. Avoid sharing tools to the extent possible. Require workers to provide their own transportation where possible and to avoid having more than two workers in a vehicle. 8. Groups/Meetings/Site Access. Avoid any group gatherings of 10 or more people. Use electronic alternatives to in person meetings, e.g., conference calls, video-conferencing, etc., to the greatest extent possible. Limit access to the project site or any work area to workers who are necessary to perform the work at that time. Allow non-essential Revised: July 13, 2020 – Public Works Contracts 3 personnel to work from home to the extent possible. Avoid all non-essential travel. Do not stack trades if possible. 9. Frequent Cleaning. Provide for regular and appropriate cleaning of all high touch surfaces at a project site or work area, including, but not limited to, shared tools or equipment, doorknobs and handles, toolboxes, sanitary facilities, common break areas, keypads, touch screens, project trailer surfaces and equipment, light or power switches, workstations, countertops, break areas, and the like. Clean and/or disinfect any reusable items or equipment. Clean surfaces of shared vehicles, including steering wheels, gear shifts, handles, instrument panels, etc. Ensure that cleaning products are used correctly and safely, and avoid cleaning techniques, such as use of pressurized air or water sprays, that may generate bioaerosols. 10. Personal Protective Equipment. When workers cannot avoid close proximity or physical contact, e.g., based on applicable safety laws, or are otherwise at risk for exposure to COVID-19, ensure that the affected workers are provided with appropriate personal protective equipment ("PPE"), which may include disposable gloves and/or other PPE. Instruct workers to wash or sanitize hands after removing gloves or other PPE. Ensure that all personal protective equipment is disposed of properly. 11. Water and Food. Prohibit shared or communal food or common water coolers. Provide individual water bottles for workers or instruct workers to bring their own. 12. Enforcement. Immediately eject any worker who fails or refuses to comply with the Health Laws, Social Distancing Requirements, or these best practices from the project site until or unless the Project Manager issues a written authorization for the worker to return, subject to full compliance. F. Proof of Compliance. If Contractor is subject to the Mandatory Directive for Construction Projects, Contractor must provide to the City the name and contact information for its designated site-specific COVID-19 supervisor(s). E. Oversight. In other to ensure that all workers comply with the Social Distancing Requirements to the extent possible, Contractor shall designate a named individual to have primary responsibility for implementation and enforcement of the Social Distancing Requirements and these best practices, and to serve as the primary point of contact with the City in this regard. Contractor shall promptly inform the City of the name of this individual. F. Changed Requirements. It is understood and acknowledged that circumstances pertaining to the COVID-19 pandemic are evolving rapidly and that new local, state, or federal requirements may modify the requirements under this Exhibit. Contractor agrees to work cooperatively with the City to implement new or changed requirements as quickly as possible. Revised: July 13, 2020 – Public Works Contracts 4 G. Subcontracts. Contractor shall include the terms of this Exhibit in all subcontracts and require any agents, subcontractors, or subconsultants to comply with its provisions. Attachments to Exhibit A-A Santa Clara County Mandatory Directive for Construction Projects 1228578.5 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 1/20 Mandator y Directive for Construction Projects Mandatory Directive for Construction Projects – PDF: English  | Spanish  | Vietnamese  | Chinese  | Tagalog  | *Please confirm that your facility and/or construction project jobsite may open under the State Order. Where there is a dierence between the local County Order and the State Order, the more restrictive order must be followed. The State also has specific guidance for certain facilities that must be followed in addition to this mandatory directive.* Information on the State’s Order and State guidance is available at covid19.ca.gov. Issued: July 7, 2020 Revised: October 13, 2020 If you think you are sick County Services During COVID-19 Eviction Moratorium Information Healthcare Provider Information Frequently Asked Questions and Ask a Question Home I am searching for... How Do I...Public Health Orders COVID-19 Data Learn What to Do Businesses and Workplaces Our County Response News Archives FREE COVID-19 Testing COVID-19 Vaccine Quick Links 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 2/20 On August 28, 2020, the State released its Blueprint for a Safer Economy (“Blueprint”), a statewide system of COVID-19 restrictions. Santa Clara County is currently in Tier Three (Orange) of the Blueprint. Under the Blueprint, construction ser vices may operate in Tier Three counties, including Santa Clara County. See the Statewide Public Health Oicer Order here and the State’s Blueprint here . These businesses must follow the mandatory requirements in this Directive, the State and County Health Oicer Orders, and the State’s COVID-19 Industr y Guidance documents, including the State’s COVID-19 Industry Guidance for Construction available here. While the construction industr y is critical to ensuring a safe and suicient supply of residential and commercial space, construction work can also pose significant risks to public health due to the COVID-19 pandemic.  Because construction projects typically involve many workers actively working on a jobsite at the same time, oen in close proximity to one another or sharing equipment, businesses and individuals performing and overseeing construction projects must take extra precautions to reduce the risk of COVID-19 transmission for workers, visitors, and others.  This Directive applies to all construction projects, but the restrictions vary by the size of the project, as specified below. “Construction project” means any work (including a public works project) carried out in connection with the construction, alteration, conversion, fitting-out, remodel, renovation, refurbishment, demolition, decommissioning, or dismantling of a building or other structure; the preparation of a physical site for any such activity; and education or training at which any such Share a Concern 2-1-1 for Coronavirus Questions CDPH Novel Coronavirus Info CDC Novel Coronavirus Updates 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 3/20 activity is taught through onsite practice or experience.  “Construction project” does not include architectural, design, financial, or administrative work related to a construction project, unless that work occurs at the construction jobsite.  “Construction project” also does not include basic repair or maintenance work, which means a repair or maintenance job that requires no more than 2 workers and no more than 2 days, and that is not architecturally, financially, or administratively associated with an active construction project. This Directive explains how construction projects may operate.  This Directive is mandatory, and failure to follow it is a violation of the Health Oicer’s Order issued on October 5, 2020 (“Order”). Construction projects must comply with the Order and all requirements of this Directive. The Order Issued October 5 The Order imposes several restrictions on all businesses and activities to ensure that the County stays as safe as possible, including but not limited to the following: The Social Distancing Protocol: All businesses and governmental entities must fill out and submit a Revised Social Distancing Protocol within 14 days of the Order’s eective date.  The Revised Social Distancing Protocol must be filled out using an updated template, which will be available here .  The Protocol is submitted under penalty of perjur y, meaning that everything written on the form must be truthful and accurate to the best of the signer’s knowledge, and submitting false information is a crime.  The Protocol must be distributed to all workers, and it must be accessible to all oicials who are enforcing the Order. For any business that only performs 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 4/20 services for dispersed facilities or worksites that the business does not own or operate, the business must complete a Social Distancing Protocol for its operation as a whole.  For any business that has a facility, but also provides services at dispersed facilities or worksites that the business does not own or operate, the business must complete a Social Distancing Protocol for its own facility and provide that Protocol to the owners or operators of any facility where it operates. Example: A construction company ser ves as a subcontractor on various jobsites throughout the County and also operates a base facility within the County, where it maintains its vehicles and equipment. The subcontractor must complete a Social Distancing Protocol for its base facility.  It must also distribute the Protocol to the owners or operators of the jobsites to which it sends its workers.  The subcontractor’s workers must be given a copy of, be trained on, and comply with the measures in both the subcontractor’s Social Distancing Protocol and the Social Distancing Protocol for any jobsite at which they are performing work. Signage: All businesses and government entities must print (1) an updated COVID-19 PREPARED Sign and (2) a Social Distancing Protocol Visitor Information Sheet, and both must be posted prominently at all facility entrances. These are available for printing aer online submission of the Revised Social Distancing Protocol. The Revised Social Distancing Protocol specifies additional signage requirements. 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 5/20 Businesses do not need to post these documents if they do not have their own facility or worksite and only perform services for dispersed facilities or worksites that the business does not own or operate. Face Coverings: Everyone must wear face coverings at all times specified in the California Department of Public Health’s mandatory Guidance for the Use of Face Coverings (“Face Covering Guidance”) and in any specific directives issued by the County Health Oicer. Further, even where not required under State or local guidance and orders, face coverings should be worn to the maximum extent possible (1) when indoors and not in one’s own residence and (2) whenever outdoors and within six feet of anyone outside one’s own household. Face coverings must be worn even while working at a construction project unless if it would create a risk to the person related to their work, in accordance with local, state, or federal workplace safety guidelines. Capacity Limitation: All businesses must limit the number of people inside a facility at the same time ensure that everyone is able to maintain at least 6 feet of social distance from everyone outside their household at all times.  This Directive describes a limited exception to the density limitation applicable only to construction project jobsites. See the Order and the FAQ page for more details. In addition to these general requirements applicable to all businesses under the Order, construction projects must comply with the following directives. 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 6/20 Construction Projects on Own Residence Exempted This Directive does not apply to construction projects where a person is performing construction on their current residence alone or solely with members of their own household. Rules for Single-Worker Construction Projects This section lists the requirements for construction projects performed by only 1 worker, such as someone who is working alone on a kitchen remodel project.  This section for single-worker projects does not apply to construction projects that involve multiple workers, even if only 1 worker is at the jobsite at any time; those projects must follow the Rules For All Construction Projects, which are listed in the next section. a. If the worker is working for a business, the worker must comply with the Social Distancing Protocol of that business. b. The worker must maintain 6 feet of social distance from all other people at all times, including when entering and leaving the work area or building. c. The worker must use and properly wear face coverings. In addition, the worker must wear other personal protective equipment (PPE) appropriate for use in construction, including gloves, goggles, and/or face shields. d. To the extent possible, the worker must seal o the work area so that there is a barrier between the worker and any other people in the building. For example, a worker performing construction in the hallway of a residence must install a barrier (such as plastic sheeting) between the area where the worker is working and the rest of the hallway. e. The worker must frequently wash hands with soap and water for at least 20 seconds or use 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 7/20 hand sanitizer with at least 60% alcohol. f. The worker must not work or come to the jobsite if the worker has a fever, cough, or any other COVID-19 symptoms. g. The worker must maintain records of the dates and times the worker was at the jobsite and must make those records immediately available upon request to any County oicial. h. If the worker tests positive for COVID-19, the worker must notify the County Public Health Department within 4 hours of learning of the positive result by following the instructions at www.sccsafeworkplace.org . Rules for All Construction Projects (Except Single- Worker Construction Projects) This section lists requirements for all construction projects (other than single-worker construction projects). *Note: Large Construction Projects must also follow additional requirements, which are described beginning on page 10.* 1. Responsibilities of the General Contractor and Subcontractors a. The business with the responsibility to oversee a construction project, described in this Directive as the “General Contractor,” must complete and submit a Revised Social Distancing Protocol specific to the construction project jobsite. (The General Contractor may also need to submit social distancing protocols for its base facility or for other jobsites subject to this Directive.) b. The General Contractor is responsible for ensuring that all work and operations at the 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 8/20 construction jobsite is performed in compliance with the Order, this Directive, and the jobsite-specific Revised Social Distancing Protocol. c. The General Contractor must train its workers to comply with the Order, this Directive, and the jobsite-specific Revised Social Distancing Protocol. d. Subcontractors do not need to submit their own jobsite-specific Revised Social Distancing Protocols for the same site, but the General Contractor must not allow any subcontractor onto the jobsite unless that subcontractor has given the General Contractor a signed certification that: i. the subcontractor has reviewed the Order and this Directive and will comply with them; ii. the subcontractor has reviewed the General Contractor’s jobsite-specific Revised Social Distancing Protocol and trained its workers on that Protocol; and iii. the subcontractor has completed and submitted its own Revised Social Distancing Protocol covering its operations, and has provided a copy of that Protocol to the General Contractor. 2. General Contractors and Subcontractors Must Report COVID-19 Positive Cases a. Whenever the General Contractor learns that a person who has tested positive for COVID-19 was at the jobsite within 48 hours of the date they were tested or within 48 hours of becoming symptomatic, the 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 9/20 General Contractor must immediately implement the jobsite-specific Revised Social Distancing Protocol’s procedures for when a person tests positive for COVID-19. All positive cases must be reported by following the instructions at www.sccsafeworkplace.org . b. All subcontractors must immediately (within 1 hour, regardless of the time of day) alert the General Contractor as soon as they learn that an employee has tested positive who is currently at the jobsite, or who was at the jobsite within 48 hours of the date they were tested or within 48 hours of becoming symptomatic. This reporting requirement is in addition to the subcontractor’s own reporting requirements under the Order and the procedures in the subcontractor’s Revised Social Distancing Protocol. 3. Cleaning Aer Positive Case Identified Upon learning of a confirmed positive case at the jobsite within the last 48 hours, any location where the infected worker was known to have been present must be immediately closed and sanitized.  Work in these locations must cease until sanitization is complete. 4. General Contractor is Responsible for Ensuring the Jobsite is Operated Safely Following All Legal Requirements a. The General Contractor must ensure that everyone at the jobsite—including its own workers, the subcontractors’ workers, and visitors—complies with the Order, this Directive, the jobsite-specific Revised Social Distancing Protocol, and any other laws and 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 10/20 regulations that apply to the work (for example, OSHA and Cal-OSHA requirements). If there is a conflict in what dierent laws require, the strictest standard applies. b. The General Contractor’s responsibility for ensuring jobsite compliance under this paragraph 4 does not, however, relieve any subcontractors of their own responsibilities under the Order, their Revised Social Distancing Protocol, this Directive, and all other applicable laws and regulations. c. Any worker, or any subcontractor, may file a complaint that the General Contractor has not complied with the Order, this Directive, or the jobsite-specific Revised Social Distancing Protocol, or that the General Contractor has failed to require others to comply. Complaints may be filed at www.sccCOVIDconcerns.org or by calling the County Oice of Labor Standards Enforcement Advice Line at 866-870-7725. 5. Designated COVID-19 Supervisor(s) a. The General Contractor must designate a site-specific COVID-19 Super visor or Supervisors to enforce the jobsite-specific Revised Social Distancing Protocol and this Directive. The designated COVID-19 Supervisor(s) must be present at the jobsite at all times during construction activities.  The COVID-19 Supervisor may be an on-site worker who is designated to ser ve in this role.  The General Contractor must prominently post a sign at all entrances to the jobsite clearly identifying the COVID-19 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 11/20 Supervisor(s) by name and providing their phone number and email address. b. The designated COVID-19 Supervisor(s) must review this Directive and the jobsite- specific Revised Social Distancing Protocol with all workers and other persons at the jobsite. The General Contractor is responsible for making sure this occurs. c. The COVID-19 Supervisor must monitor and ensure implementation at the jobsite of all requirements in this Directive, the jobsite- specific Revised Social Distancing Protocol, and the Order. 6. Seal O Area of Construction Project from Other Parts of Occupied Sites Where construction work occurs within an occupied residential or commercial building, all of the following rules apply: a. Work areas must, to the extent feasible, be sealed o from the remainder of the building (and from the remainder of the unit, if work is performed within a residential unit) with physical barriers such as plastic sheeting or closed doors sealed with tape. b. If possible, workers must access the work area from entry/exit door(s) dierent from the entr y/exit door(s) used by residents or occupants accessing the remainder of the building that is not under construction. c. Available windows and/or doors must be used to ventilate the work area during the workday and any other times work is performed. d. If residents or occupants have access to the work area between workdays, the work area 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 12/20 must be cleaned and sanitized at the beginning and at the end of workdays. e. Ever y eort must be taken to minimize contact between workers and residents or occupants, including maintaining a minimum of at least 6 feet of social distance at all times. 7. Personal Protective Equipment (PPE) The General Contractor must obtain, provide at no cost to workers, and require that all workers use personal protective equipment (PPE) appropriate for use in construction, including gloves, goggles, face shields, and face coverings as appropriate for the activity being performed.  Face coverings must be worn in compliance with the State’s Face Covering Guidance for the Use of Face Coverings and any additional directives issued by the County Health Oicer.  At no time may medical-grade PPE be used at a construction site unless it is required due to the medical nature of the jobsite or local, state, or federal workplace safety requirements. 8. Social Distancing and other Measures a. The General Contractor must: Ensure that workers are able to maintain at least 6 feet social distance at all times, except as strictly and temporarily necessary to safely carry out a specific job function. i. This may require staggering shis, breaks, and trade-specific work as necessar y to reduce density and allow for easy maintenance of at least 6 feet of social distancing. Staggered shis and breaks must comply with applicable wage and hour laws. 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 13/20 ii. Eliminate or resolve “choke points” and “high-risk areas” where workers are unable to maintain at least 6 feat of social distance. The General Contractor must prohibit or limit use of these areas to ensure that 6 feet of social distance can easily be maintained between individuals. iii. If possible, ensure workers eat their meals and take their breaks outdoors, and maintain social distancing during meals and breaks. iv. Prohibit gatherings of any size on the jobsite (except for meetings required by this Directive), including gatherings for breaks or eating. Sharing of any food or beverage is strictly prohibited. v. Cal-OSHA requires employers to provide water. Water must be provided in single-ser ve containers. vi. Prohibit use of microwaves, water coolers, and other similar shared equipment. b. Workers must: i. Unless strictly necessary to carry out a job function, maintain at all times at least 6 feet of social distance at all times from fellow workers and all site visitors, including delivery workers, design professionals and other project consultants, government agency representatives (including building and fire inspectors), and residents at residential construction sites. ii. Not carpool to and from the jobsite except with others living within the same household, or if necessary 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 14/20 because they have no alternative means of transportation. If workers from dierent households must carpool, they must wear face coverings while riding together in the same vehicle, sit at the greatest distance possible, and maintain ventilation by keeping windows open as feasible. 9. Notice for Workers and Visitors of Required Practices The General Contractor must prominently post a notice at all entrances to the jobsite visible to all workers and visitors instructing workers and visitors to do the following: a. Do not touch your face with unwashed hands or with gloves. b. If equipment is shared, it must be fully sanitized before and aer each use. c. Wash your hands oen with soap and water for at least 20 seconds each time, or use hand sanitizer with at least 60% alcohol. d. Clean and disinfect objects and surfaces you touch oen, such as work stations, keyboards, telephones, handrails, machines, shared tools, elevator control buttons, and doorknobs. e. Cover your mouth and nose with a tissue or cloth when you cough or sneeze, or cough or sneeze into your elbow/sleeve – never into your hands. f. Do not enter the jobsite if you have a fever, cough, or other COVID-19 symptoms. If you feel sick, or have been exposed to anyone who is sick, stay at home. 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 15/20 g. Constantly make sure you are staying at least 6 feet away from co-workers at all times, unless it is absolutely necessar y to get closer to safely complete a task for the construction project. h. Do not carpool to and from the jobsite with anyone except members of your own household, or if necessary because you have no alternative means of transportation. If you carpool with people from another household, you must wear a face covering while riding together in the same vehicle. i. Do not share phones or PPE. Posters conforming to this requirement are available for download at https://www.sccgov.org /sites/covid19/Pages/l earn-what-to-do-flyers.aspx . 10. Cooperate with County’s Case Investigation and Contact Tracing Eorts The General Contractor must maintain a daily attendance log of all workers and visitors at the jobsite that includes contact information (including name, phone number, address, and email) and the date, time, and duration of each person’s presence at the jobsite.  If someone on the jobsite tests positive for COVID-19, the General Contractor is legally required to assist the County Public Health Department in any case investigation and contact tracing eorts. 11. Monitor and Inform Supervisors and Subcontractors of Revised Requirements The General Contractor must regularly check for revisions to the Order, this Directive, relevant 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 16/20 industry-specific guidance published by the California Department of Public Health, and other relevant rules or guidance.  The General Contractor must inform all jobsite supervisors (including the designated COVID-19 Supervisor(s), all field supervisors, forepersons, and safety directors) and all subcontractors of any revisions or additions to the requirements for construction projects. Additional Rules for Large Construction Projects This section describes additional requirements that apply only to Large Construction Projects. 12. What is a Large Construction Project? A “Large Construction Project” is a construction project that meets any of the following specifications: a. For residential projects, any single-family, multi-family, senior, student, or other residential construction project consisting of 10 or more units; b. For commercial projects, any construction project consisting of 20,000 or more square feet of floor area; c. For mixed-use construction projects, any construction project that meets either of the specifications above in Subparagraphs (a) and (b); or d. Any infrastructure project that requires 20 or more workers at the jobsite at any one time. 13. COVID-19 Supervisor’s Additional Compliance, Monitoring, and Remediation Responsibilities a. The designated COVID-19 Supervisor must: 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 17/20 i. Conduct daily briefings in person (with proper social distancing) or by teleconference that must cover the following topics: A. New jobsite rules and pre- jobsite travel restrictions for the prevention of COVID-19 community spread. B. Review of sanitizing and hygiene procedures. C. Worker feedback on improving safety and sanitizing. D. Coordination of construction site daily cleaning /sanitization requirements. E. Any newly available information regarding COVID-19. F. Emergency protocols in the event of an exposure or suspected exposure to COVID- 19. ii. Each day, verify and record verification that each jobsite is compliant with this Directive. The General Contractor must collect each written verification, store them for at least 1 year, and make them immediately available upon request to any County oicial. iii. Conduct the following activities to make sure that the jobsite is ready to fix any violations of this Directive: G. Develop a remediation plan; H. If any non-compliance is identified, ensure that the remediation plan is implemented, and post the 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 18/20 remediation plan at all entrances to the jobsite during the remediation period; I. Stop any construction activity until the jobsite is back in compliance; and J. Report repeated non- compliance with this Directive to the appropriate jobsite supervisors and the permitting agency for the local government where the project is located. b. The General Contractor is responsible for making sure the designated COVID-19 Supervisor takes all of these steps. 14. Jobsite Safety Accountability Supervisor (JSAS) The General Contractor must assign a COVID-19 Third-Party Jobsite Safety Accountability Supervisor (JSAS) for the jobsite.  The JSAS may not be an employee of the General Contractor.  The JSAS must at a minimum hold an OSHA-30 certificate and first-aid training, or equivalent credentials, from within the past 2 years. The JSAS must be trained in the requirements in this Directive and the jobsite-specific Social Distancing Protocol and must verify compliance with those requirements, including by visual inspection and random interviews with workers.  The JSAS must inspect the jobsite as oen as needed to ensure consistent compliance, but not less than once per week.  The JSAS must inspect the jobsite during normal construction hours. a. The General Contractor must prominently post a sign at all entrances to the jobsite visible to all workers and visitors that clearly identifies the JSAS for the jobsite by 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 19/20 name and providing their phone number and email address. b. Within 7 calendar days of each jobsite visit, the JSAS must complete a written assessment identifying any failure to comply with this Directive. The written assessment must be copied, stored, and, produced upon request to the County or local permitting agency.  c. If the JSAS discovers that a jobsite is not in compliance with this Directive and the jobsite-specific Revised Social Distancing Protocol, the JSAS must work with the designated COVID-19 Super visor to develop and implement a remediation plan. d. The JSAS must coordinate with the designated COVID-19 Super visor to prohibit continuation of any work activity not in compliance with this Directive or the jobsite-specific Revised Social Distancing Protocol. The JSAS must make sure that the work activity does not resume until the noncompliance is fixed and the continuing work is compliant with this Directive. e. The remediation plan must be sent to the local permitting agency and a designated County oicial within 5 calendar days of the JSAS’s discovery of the failure to comply. 15. Translation for Non-English-Speaking Workers The General Contractor must translate (and, where otherwise required, post) all of the following documents as necessary to ensure that all non-English-speaking workers are able to understand the documents: a. The Notice for Workers and Visitors of Required Practices described in Paragraph 9 3/8/2021 Mandatory Directive for Construction Projects - Novel Coronavirus (COVID-19) - County of Santa Clara https://www.sccgov.org/sites/covid19/Pages/Archive/mandatory-directives-construction.aspx 20/20 (on page 8). b. The remediation plan described in Paragraph 13.a.iii.1 (on page 11). Stay Informed For answers to frequently asked questions about this industry and other topics, please see the FAQ page.  Please note that this Directive may be updated.  For up-to-date information on the Health Oicer Order, visit the County Public Health Department’s website at www.sccgov.org /coronavirus . Last updated: 12/1/2020 11:23 AM Report a problem with this page All Content Copyright © 2021 , County of Santa Clara, CA March 12, 2020 Jeffrey Trybus Senior Code Enforcement Officer City of Cupertino Dear Jeff, Thank you for the opportunity to work with you and the City of Cupertino. Below are our costs for homeless abatement and removal of debris. This is a description of our scope of work included with pricing. These costs are consistent with what we charge other municipalities in the local area. Please let me know if you have any questions. Pre-Cleanup Posting: done by City of Cupertino Cleanup: Supervision 1 person @ 130.00 (Prevailing Wage) Labor rate with tools 120.00/hour each (Prevailing Wage) (The cleanup crew depends on the size of the encampment(s), usually anywhere from 3 to 8 people) Search for important personal items, save and deliver to our storage unit on site. (Clients are asked to contact HomeFirst for retrieval of their items, 408-510-7600) Dismantle structures. Load trash and debris into dumpster or dump truck. Dump truck – 250.00 per half day, 300.00 whole day Dump fees – cost plus 20% 30 yard dumpster @ 950.00 each or current rate Equipment rental if needed is not included at this time. Hazardous waste disposal – cost plus 20% Small trash will be left behind. These items are generally not cost effective to be removed. Pre and post cleanup pictures taken for documentation. Exhibit B Bio: 2 people @ 147.00/hour each (Prevailing Wage) Bio-waste disposal – cost plus 20% There would be additional charge to meet with the Bio Disposal for pickup of bio waste, Post Clean-up: 111.00/hour each (Prevailing Wage) Taking personal items to storage and possible return of items to clients from storage. These, generally, do not take more than an hour or so for each Thank you, Penny Bitcon Service Order Form Due Date: Type of Request: Date Submitted: Applicant Name: Project Number: Project Address: APN: Project Description: Consultant’s Scope of Work: Other: Amount: Deposit Receipt: Transmitted by: Phone No. Other: Exhibit B Service Insurance Requirements for Construction Contracts - $60,000 Version: Sept. 2019  &RQWUDFWRUVKDOOSURFXUHDQGPDLQWDLQIRUWKHGXUDWLRQRIWKHFRQWUDFWand for five years following the completion of the ProjectLQVXUDQFHDJDLQVWFODLPVIRULQMXULHVWRSHUVRQVRUGDPDJHVWRSURSHUW\ZKLFKPD\DULVHIURPRULQ FRQQHFWLRQZLWKWKHSHUIRUPDQFHRIWKHZRUNKHUHXQGHUE\&RQWUDFWRULWVDJHQWVUHSUHVHQWDWLYHVHPSOR\HHVRU VXEFRQWUDFWRUV 0,1,0806&23($1'/,0,72),1685$1&( &RYHUDJHVKDOOEHDWOHDVWDVEURDGDV &RPPHUFLDO *HQHUDO /LDELOLW\ ³&*/´  ,QVXUDQFH 6HUYLFHV 2IILFH ,62 )RUP &* FRYHULQJ&*/ RQDQ ³RFFXUUHQFH´ EDVLVwritten on a comprehensive general liability form, and must include coverage for liability arising from Contractor’s or Subcontractor’s acts or omissions, including Contractor’s protected coverage, blanket contractual, SURGXFWV DQG FRPSOHWHG RSHUDWLRQVvehicle coverage and employer’s non-ownership liability coverage, with limits of at least $2,000,000 per occurrence. The CGL policy must protect against any and all liability forpersonal injury, death, SURSHUW\GDPDJH RUGHVWUXFWLRQDQGSHUVRQDODQGDGYHUWLVLQJLQMXU\,IDJHQHUDO DJJUHJDWH OLPLW DSSOLHV HLWKHU WKH JHQHUDO DJJUHJDWH OLPLW VKDOO DSSO\ VHSDUDWHO\WRWKLV SURMHFWORFDWLRQ ,62 &* RU RUWKHJHQHUDO DJJUHJDWHOLPLWVKDOOEHWZLFHWKHUHTXLUHGRFFXUUHQFHOLPLW D ,W VKDOOEHDUHTXLUHPHQWXQGHUWKLVDJUHHPHQW WKDWDQ\DYDLODEOH LQVXUDQFHSURFHHGVEURDGHUWKDQRULQH[FHVV RI WKHVSHFLILHGPLQLPXPLQVXUDQFHFRYHUDJHUHTXLUHPHQWVDQGRUOLPLWVVKDOO EH PDGH DYDLODEOH WR WKH $GGLWLRQDO ,QVXUHGDQGVKDOO EH  WKHPLQLPXPFRYHUDJHOLPLWVVSHFLILHGLQWKLVDJUHHPHQW RU  WKHEURDGHU FRYHUDJH DQGPD[LPXPOLPLWV RI FRYHUDJH RI DQ\ LQVXUDQFH SROLF\ZKLFKHYHULVJUHDWHU E $GGLWLRQDO ,QVXUHG FRYHUDJH XQGHU &RQWUDFWRU V SROLF\ VKDOO EH SULPDU\ DQG QRQFRQWULEXWRU\ ZLOO QRW VHHN FRQWULEXWLRQIURP&LW\¶V LQVXUDQFHVHOILQVXUDQFH DQGVKDOOEH DW OHDVW DV EURDGDV,62&*  F 7KH OLPLWV RI LQVXUDQFH UHTXLUHGPD\EH VDWLVILHG E\ D FRPELQDWLRQ RI SULPDU\ DQG XPEUHOOD RU H[FHVV LQVXUDQFHSURYLGHGHDFK SROLF\ FRPSOLHV ZLWK WKH UHTXLUHPHQWV VHW IRUWK LQWKLV&RQWUDFW $Q\ XPEUHOOD RU H[FHVV LQVXUDQFH VKDOO FRQWDLQ RUEHHQGRUVHG WRFRQWDLQDSURYLVLRQ WKDW VXFK FRYHUDJH VKDOO DOVR DSSO\ RQ D SULPDU\ EDVLV IRUWKHEHQHILW RI&LW\EHIRUH WKH&LW\¶VRZQ LQVXUDQFHRUVHOILQVXUDQFHVKDOO EH FDOOHG XSRQWR SURWHFW &LW\ DV D QDPHGLQVXUHG $XWRPRELOH /LDELOLW\ ,62 )RUP&$FRYHULQJDQ\DXWR &RGH RULI&RQWUDFWRUKDVQRRZQHG DXWRV WKHQ KLUHGDXWRV &RGH DQGQRQRZQHGDXWRV &RGH ZLWKOLPLWQR OHVVWKDQSHUDFFLGHQWIRUERGLO\ LQMXU\ DQGSURSHUW\GDPDJH :RUNHUV¶&RPSHQVDWLRQ$VUHTXLUHGE\WKH6WDWH RI &DOLIRUQLDZLWK6WDWXWRU\/LPLWV DQG(PSOR\HU¶V /LDELOLW\,QVXUDQFHRIQROHVV WKDQ SHU DFFLGHQW IRU ERGLO\LQMXU\RUGLVHDVH RU DV RWKHUZLVH UHTXLUHGE\ VWDWXWH ,I &RQWUDFWRU LV VHOILQVXUHG&RQWUDFWRUPXVW SURYLGHD&HUWLILFDWH RI 3HUPLVVLRQ WR 6HOI,QVXUH GXO\ DXWKRUL]HGE\WKH ',5 1$LIER[FKHFNHG Contractor provides written verification it has no employees). 4.3URIHVVLRQDO/LDELOLW\ZLWKOLPLWVQROHVVWKDQSHURFFXUUHQFHRUFODLPDQGDJJUHJDWH 1$LIER[FKHFNHG(Contract is not design/build). %XLOGHU¶V5LVN&RXUVHRI&RQVWUXFWLRQLQVXUDQFHXWLOL]LQJDQ³$OO5LVN´ 6SHFLDO3HULOV FRYHUDJHIRUPZLWK OLPLWVHTXDOWRWKHFRPSOHWHGYDOXHRIWKHSURMHFWDQGQRFRLQVXUDQFHSHQDOW\SURYLVLRQV 1$LIER[FKHFNHG(Project does not involve construction or improvements/installations to property). 21&$//PUBLIC WORKS CONSTRUCTION CONTRACTS Small Projects - $60,000 Insurance Requirements: Exhibit & X X Insurance Requirements for Construction Contracts - $60,000 Version: Sept. 2019  &RQWUDFWRUV¶3ROOXWLRQ/HJDO/LDELOLW\DQGRU$VEHVWRV/HJDO/LDELOLW\DQGRU(UURUVDQG2PLVVLRQVZLWKOLPLWV QROHVVWKDQSHURFFXUUHQFHRUFODLPDQGSROLF\DJJUHJDWH 1$LIER[FKHFNHG(Project does not involve environmental hazards). ,I&RQWUDFWRUPDLQWDLQVEURDGHUFRYHUDJHDQGRUKLJKHUOLPLWVWKDQWKHPLQLPXPVVKRZQDERYH&LW\UHTXLUHVDQG VKDOOEHHQWLWOHGWRWKHEURDGHUFRYHUDJHDQGRUKLJKHUOLPLWVPDLQWDLQHGE\WKHFRQWUDFWRU$Q\DYDLODEOHLQVXUDQFH SURFHHGVLQH[FHVVRIWKHVSHFLILHGPLQLPXPOLPLWVRILQVXUDQFHDQGFRYHUDJHVKDOOEHDYDLODEOHWRWKH&LW\ Self-Insured Retentions. 6HOILQVXUHGUHWHQWLRQVPXVWEHGHFODUHGWRDQGDSSURYHGE\&LW\$W&LW\¶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dditional Insured Status 7KH&LW\RI&XSHUWLQRLWV&LW\&RXQFLORIILFHUV RIILFLDOVHPSOR\HHVDJHQWVVHUYDQWVDQGYROXQWHHUVDUHWREHFRYHUHG DVDGGLWLRQDOLQVXUHGVRQWKH &*/ DQGDXWRPRELOHOLDELOLW\SROLFLHV ZLWK UHVSHFW WR OLDELOLW\DULVLQJRXWRIWKH6HUYLFHV SHUIRUPHGE\RURQEHKDOIRI&RQWUDFWRULQFOXGLQJPDWHULDOVSDUWVRUHTXLSPHQWIXUQLVKHG(QGRUVHPHQWRI&*/ FRYHUDJHVKDOOEHDWOHDVWDVEURDGDV,62)RUP&*RULIQRWDYDLODEOHWKURXJKWKHDGGLWLRQRIERWK&* &*&*RU&*DQG&*LIDODWHUHGLWLRQLVXVHG Primary Coverage )RU DQ\FODLPV UHODWHG WR WKLV3URMHFW&RQWUDFWRU¶VLQVXUDQFHFRYHUDJH VKDOOEH³SULPDU\DQG QRQFRQWULEXWRU\´DQG DW OHDVW DVEURDGDV ,62 &*ZLWK UHVSHFWWR &LW\ LWVRIILFHUVRIILFLDOV HPSOR\HHVDQGYROXQWHHUVDQGVKDOO QRWVHHNFRQWULEXWLRQIURP&LW\¶VLQVXUDQFH,IWKHOLPLWVRILQVXUDQFHDUHVDWLVILHGLQSDUWE\8PEUHOOD([FHVV ,QVXUDQFHWKH8PEUHOOD([FHVV,QVXUDQFHVKDOO FRQWDLQRUEHHQGRUVHGWR FRQWDLQDSURYLVLRQWKDWVXFK FRYHUDJH VKDOO DOVRDSSO\RQD³SULPDU\DQGQRQFRQWULEXWRU\´EDVLVIRUWKHEHQHILWRI&LW\ Notice of Cancellation (DFKLQVXUDQFHSROLF\UHTXLUHGVKDOOSURYLGHWKDWFRYHUDJHVKDOOQRWEHFDQFHOHGH[FHSWZLWKQRWLFHWRWKH&LW\(DFK FHUWLILFDWHRILQVXUDQFHPXVW VWDWH WKDWWKHFRYHUDJHDIIRUGHGE\WKHSROLF\LV LQIRUFHDQGZLOOQRWEHUHGXFHGFDQFHOOHG RUDOORZHGWRH[SLUHZLWKRXWDWOHDVWGD\VDGYDQFHZULWWHQQRWLFHWR&LW\XQOHVVGXHWRQRQSD\PHQWRISUHPLXPV LQ ZKLFK FDVH WHQ GD\V DGYDQFH ZULWWHQQRWLFHPXVWEHSURYLGHGWR &LW\ 6XFKQRWLFH PXVWEHVHQW WR &LW\ YLD FHUWLILHG PDLODQGDGGUHVVHGWRWKHDWWHQWLRQRIWKH&LW\0DQDJHU Builder’s Risk &RQWUDFWRUPD\VXEPLW%XLOGHU¶V5LVNLQVXUDQFHLQWKHIRUPRI&RXUVHRI&RQVWUXFWLRQFRYHUDJHZKLFKVKDOOQDPH WKH&LW\DVDORVVSD\HH DV LWVLQWHUHVWPD\DSSHDU7KH%XLOGHU¶V 5LVNSROLF\PXVW EH LVVXHGRQDQ RFFXUUHQFHEDVLV IRUDOOULVNFRYHUDJHRQDFRPSOHWHGYDOXHEDVLVRQWKHLQVXUDEOHSRUWLRQRIWKH3URMHFWZLWKQRFRLQVXUDQFH SHQDOWLHVDQGIRUWKHEHQHILWRI&LW\,IWKH3URMHFWGRHVQRWLQYROYHQHZRUPDMRUUHFRQVWUXFWLRQ&LW\PD\HOHFWDFWLQJ LQLWVVROHGLVFUHWLRQWRDFFHSWDQ,QVWDOODWLRQ)ORDWHUSROLF\LQVWHDGRI%XLOGHU¶V5LVN)RUVXFKSURMHFWVWKH3URSHUW\ ,QVWDOODWLRQ )ORDWHU VKDOOLQFOXGHLPSURYHPHQWUHPRGHOPRGLILFDWLRQDOWHUDWLRQFRQYHUVLRQRUDGMXVWPHQWWR H[LVWLQJ EXLOGLQJVVWUXFWXUHVSURFHVVHVPDFKLQHU\DQGHTXLSPHQWDQGVKDOOSURYLGHSURSHUW\GDPDJHFRYHUDJHIRUDQ\ EXLOGLQJVWUXFWXUHPDFKLQHU\RUHTXLSPHQWGDPDJHGLPSDLUHGEURNHQRUGHVWUR\HGGXULQJWKHSHUIRUPDQFHRIWKH :RUNLQFOXGLQJGXULQJWUDQVLWLQVWDOODWLRQDQGWHVWLQJDWWKH&LW\¶VVLWH X Insurance Requirements for 2Q&DOO3XEOLF:RUNVConstruction Contracts - $60,000 Version:-DQ. 20  Waiver of Subrogation (DFK UHTXLUHGSROLF\PXVWLQFOXGHDQHQGRUVHPHQWSURYLGLQJWKDWWKHFDUULHUDJUHHVWR ZDLYHDQ\ULJKWRI VXEURJDWLRQ LW PD\KDYH DJDLQVW &LW\ &RQWUDFWRUDJUHHV WR ZDLYH ULJKWVRIVXEURJDWLRQZKLFK DQ\LQVXUHURI&RQWUDFWRUPD\DFTXLUH IURP&RQWUDFWRUE\YLUWXHRI WKH SD\PHQWRIDQ\ORVV&RQWUDFWRUDJUHHVWRREWDLQDQ\HQGRUVHPHQWWKDWPD\EH QHFHVVDU\ WR DIIHFW WKLV ZDLYHU RIVXEURJDWLRQ7KH:RUNHUV¶&RPSHQVDWLRQSROLF\ VKDOO EHHQGRUVHGZLWK D ZDLYHU RI VXEURJDWLRQLQIDYRURIWKH &LW\IRUDOOZRUNSHUIRUPHGE\WKH &RQWUDFWRULWVHPSOR\HHVDJHQWVDQGVXEFRQWUDFWRUV Acceptability of Insurers ,QVXUDQFHPXVW EH LVVXHG E\LQVXUHUVDFFHSWDEOH WR &LW\DQGOLFHQVHG WR GR EXVLQHVV LQ WKH6WDWH RI&DOLIRUQLDDQG HDFK LQVXUHUPXVW KDYH DQ$0%HVW¶VILQDQFLDO VWUHQJWKUDWLQJRI³$´ RUEHWWHUDQGDILQDQFLDOVL]H UDWLQJRI³9,,´ RUEHWWHU Verification of Coverage &RQWUDFWRUVKDOOIXUQLVK WKH&LW\ZLWKRULJLQDOFHUWLILFDWHVDQG DPHQGDWRU\HQGRUVHPHQWVRUFRSLHVRI WKHDSSOLFDEOH LQVXUDQFHODQJXDJHHIIHFWLQJFRYHUDJHUHTXLUHGE\WKLVFRQWUDFW$OOFHUWLILFDWHVDQG HQGRUVHPHQWVDUH WR EH UHFHLYHG DQGDSSURYHGE\WKH &LW\EHIRUHZRUNFRPPHQFHV7KH&LW\UHVHUYHVWKH ULJKWWR UHTXLUHFRPSOHWHFHUWLILHGFRSLHVRI DOO UHTXLUHG LQVXUDQFHSROLFLHV LQFOXGLQJ HQGRUVHPHQWVUHTXLUHGE\WKHVH VSHFLILFDWLRQVDW DQ\WLPH Subcontractors &RQWUDFWRUVKDOOUHTXLUHDQG YHULI\WKDWDOOVXEFRQWUDFWRUVPDLQWDLQLQVXUDQFHPHHWLQJDOOWKHUHTXLUHPHQWVVWDWHG KHUHLQDQG&RQWUDFWRUVKDOOHQVXUHWKDW&LW\LV DQ DGGLWLRQDOLQVXUHGRQLQVXUDQFHUHTXLUHGIURPVXEFRQWUDFWRUV)RU &*/FRYHUDJHVXEFRQWUDFWRUVVKDOOSURYLGHFRYHUDJHZLWK D IRUP DWOHDVWDV EURDGDV&*  Surety Bonds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pecial Risks or Circumstances &LW\UHVHUYHVWKHULJKWWRPRGLI\WKHVH UHTXLUHPHQWVEDVHGRQWKHQDWXUHRIWKHULVNSULRUH[SHULHQFHLQVXUHUFRYHUDJH RURWKHUFLUFXPVWDQFHV DATE (MM/DD/YYYY)CERTIFICATE OF LIABILITY INSURANCE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONTACTPRODUCERNAME: FAXPHONE(A/C, No):(A/C, No, Ext): E-MAILADDRESS: INSURER(S) AFFORDING COVERAGE NAIC # INSURER A : INSURED INSURER B : INSURER C : INSURER D : INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ADDL SUBRINSR POLICY EFF POLICY EXPTYPE OF INSURANCE LIMITSPOLICY NUMBERLTR (MM/DD/YYYY) (MM/DD/YYYY)INSD WVD COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ DAMAGE TO RENTEDCLAIMS-MADE OCCUR $PREMISES (Ea occurrence) MED EXP (Any one person) $ PERSONAL & ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER:GENERAL AGGREGATE $ PRO-POLICY LOC PRODUCTS - COMP/OP AGG $JECT $OTHER: COMBINED SINGLE LIMITAUTOMOBILE LIABILITY $(Ea accident) BODILY INJURY (Per person) $ANY AUTO ALL OWNED SCHEDULED BODILY INJURY (Per accident) $AUTOS AUTOS NON-OWNED PROPERTY DAMAGE $HIRED AUTOS (Per accident)AUTOS $ UMBRELLA LIAB EACH OCCURRENCE $OCCUR EXCESS LIAB CLAIMS-MADE AGGREGATE $ $DED RETENTION $ PER OTH-WORKERS COMPENSATION STATUTE ERAND EMPLOYERS' LIABILITY Y / NANY PROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $N / AOFFICER/MEMBER EXCLUDED? (Mandatory in NH)E.L. DISEASE - EA EMPLOYEE $ If yes, describe under E.L. DISEASE - POLICY LIMIT $DESCRIPTION OF OPERATIONS below DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE © 1988-2014 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORDACORD 25 (2014/01) TUCKE-1 OP ID: NL 12/23/2020 Nicolette LeeBozzuto & Associates Insurance 34 S. Second St Campbell, CA 95008 Jennifer Anderson 800-989-8712 408-429-8460 nicolettel@dbinsurance.com Navigators Insurance Company 42307 RSUI Indemnity Company 22314Tucker Construction Inc. 1725 Little Orchard Street #D San Jose, CA 95125 Redwood Fire & Casualty Ins 11673 Westchester Surplus Lines 10172 Ohio Security Insurance Co 24082 AX 1,000,000 X XXLA20CGL167596IC 08/15/2020 08/15/2021 50,000 5,000 1,000,000 2,000,000 X 2,000,000 X 4,000,000 XB NHA250095 08/15/2020 08/15/2021 4,000,000 0X X CXTUWC222677 01/01/2021 01/01/2022 1,000,000 1,000,000 1,000,000 D Pollution Liab G7091542A 003 08/15/2020 08/15/2021 Limit/Ded $1M/$10K E Equipment BMO61600900 09/12/2020 09/12/2021 LSD/RTD 80,000 The City of Cupertino, its City Council, officers, officials, employees, agents, servants and volunteers are listed as additional insured per the attached endorsements on the General Liability policy. Coverage is primary and non-contributory. Waiver of subrogation applies to General Liability and Workers Compensation. CITYCUP City of Cupertino 10300 Torre Avenue Cupertino, CA 95014 CG 20 37 04 13 © Insurance Services Office, Inc., 2012 Page 1 of 2 POLICY NUMBER: LA20CGL167596IC COMMERCIAL GENERAL LIABILITY CG 20 37 04 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s)Location And Description Of Completed Operations Any person or organization for whom you are performing “commercial construction” during the period of this policy and have agreed in a written contract to add as an additional insured for products-completed operations. “Commercial construction” does not include any habitational or residential construction other than hotels or apartments. . .. .. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location designated and described in the Schedule of this endorsement performed for that additional insured and included in the "products-completed operations hazard". However: 1.The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are B.With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1.Required by the contract or agreement; or 2.Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. CG 20 37 04 13 © Insurance Services Office, Inc., 2012 Page 2 of 2 required by the contract or agreement to provide for such additional insured. CG 20 38 04 13 Page 1 of 2© Insurance Services Office, Inc., 2012 COMMERCIAL GENERAL LIABILITY CG 20 38 04 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED – OWNERS, LESSEES OR CONTRACTORS – AUTOMATIC STATUS FOR OTHER PARTIES WHEN REQUIRED IN WRITTEN CONSTRUCTION AGREEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. Section II - Who Is An Insured is amended to include as an additional insured: 1.Any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an additional insured on your policy; and 2.Any other person or organization you are required to add as an additional insured under the contract or agreement described in Paragraph 1. above. Such person(s) or organization(s) is an additional insured only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: a.Your acts or omissions; or b.The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured. However, the insurance afforded to such additional insured described above: a.Only applies to the extent permitted by law; and b.Will not be broader than that which you are required by the contract or agreement to provide for such additional insured. A person's or organization's status as an additional insured under this endorsement ends when your operations for the person or organization described in Paragraph 1. above are completed. B.With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to: 1."Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: a.The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or b.Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of, or the failure to render, any professional architectural, engineering or surveying services. 2."Bodily injury" or "property damage" occurring after: a.All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or Policy Number: LA20CGL167596IC CG 20 38 04 13 Page 2 of 2© Insurance Services Office, Inc., 2012 b. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. C. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement described in Paragraph A.1.; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. CG 20 01 04 13 Page 1 of 1© Insurance Services Office, Inc., 2012 COMMERCIAL GENERAL LIABILITY CG 20 01 04 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NONCONTRIBUTORY – OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to the Other Insurance Condition and supersedes any provision to the contrary: Primary And Noncontributory Insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1)The additional insured is a Named Insured under such other insurance; and (2)You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. Policy Number: LA20CGL167596IC COMMERCIAL GENERAL LIABILITY NPC 711 08 11 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. NPC 711 08 11 Page 1 of 2 GENERAL AGGREGATE LIMIT PER PROJECT WITH AN OVERALL GENERAL AGGREGATE CAP This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Construction Projects: Overall General Aggregate Cap: $5,000,000 All Projects (If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) A.For all sums which the insured becomes legally obligated to pay as damages caused by “occur- rences” under COVERAGE A (SECTION I), and for all medical expenses caused by accidents under COVERAGE C (SECTION I), which can be attributed only to ongoing operations at a single designated construction project shown in the Schedule above: 1.A separate Designated Construction Project General Aggregate Limit applies to each des- ignated construction project, and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations. Subject to the application of the General Aggregate Limit to each of your projects, the maximum amount we will pay under the General Aggre- gate Limit for all claims arising from all projects is the Overall General Aggregate Cap shown in the Schedule above. 2.The Designated Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under COVERAGE A, except damages because of “bodily injury” or “property damage” included in the “products- completed operations hazard”, and for medi- cal expenses under COVERAGE C regard- less of the number of: a.Insureds; b.Claims made or “suits” brought; or c.Persons or organizations making claims or bringing “suits”. 3.Any payments made under COVERAGE A for damages or under COVERAGE C for medical expenses shall reduce the Designated Con- struction Project General Aggregate Limit for that designated construction project. Such payments shall not reduce the General Ag- gregate Limit shown in the Declarations nor shall they reduce any other Designated Con- struction Project General Aggregate Limit for any other designated construction project shown in the Schedule above. 4.The limits shown in the Declarations for Each Occurrence, Fire Damage and Medical Ex- pense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the applicable Designated Con- struction Project General Aggregate Limit. POLICY NUMBER: LA20CGL167596IC Page 2 of 2 NPC 711 08 11 B.For all sums which the insured becomes legally obligated to pay as damages caused by “occur- rences” under COVERAGE A (SECTION I), and for all medical expenses caused by accidents under COVERAGE C (SECTION I), which cannot be attributed only to ongoing operations at a sin- gle designated construction project shown in the Schedule above: 1.Any payments made under COVERAGE A for damages or under COVERAGE C for medical expenses shall reduce the amount available under the General Aggregate Limit or the Products-Completed Operations Aggregate Limit, whichever is applicable; and 2.Such payments shall not reduce any Desig- nated Construction Project General Aggre- gate Limit. C.When coverage for liability arising out of the “products-completed operations hazard” is pro- vided, any payments for damages because of “bodily injury” or “property damage” included in the “products-completed operations hazard” will reduce the Products-Completed Operations Ag- gregate Limit, and not reduce the General Aggre- gate Limit nor the Designated Construction Project General Aggregate Limit. D.If the applicable designated construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contract- ing parties deviate from plans, blueprints, de- signs, specifications or timetables, the project will still be deemed to be the same construction project. E.The provisions of Limits Of Insurance (SECTION III) not otherwise modified by this endorsement shall continue to apply as stipulated. POLICY NUMBER: LA20CGL167596IC COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 CG 24 04 05 09 © Insurance Services Office, Inc., 2008 Page 1 of 1  WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: Any person or organization when you and such person or organization have agreed in writing in a contract or agreement that you will waive any right of recovery against such person or organization. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV – Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products- completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. Endorsement Effective: Policy No.: Insured: WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 99 04 10 C (Ed. 01-19) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT-CALIFORNIA BLANKET BASIS We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) The additional premium for this endorsement shall be calculated by applying a factor of 2% to the total manual premium, with a minimum initial charge of $350, then applying all other pricing factors for the policy to this calculated charge to derive the final cost of this endorsement. This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Blanket Waiver Person/Organization Blanket Waiver –Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. Waiver Premium (prior to adjustments) This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement No.: Premium $ Insurance Company: WC 99 04 10 C Countersigned by ______________________________________ (Ed. 01-19) Job Description All CA Operations Redwood Fire and Casualty Ins Co TUWC222677 2738.00 01/01/2021 4640 <Project Title> 2021 Form PAYMENT BOND <Project Number> Page 30 Payment Bond <________________________________> (“City”) and ________________________ (“Contractor”) have entered into a contract for work on the <_________________________________________________> Project (“Project”). The Contract is incorporated by reference into this Payment Bond (“Bond”). 1. General. Under this Bond, Contractor as principal and ____________________________, its surety (“Surety”), are bound to City as obligee in an amount not less than $_________________, under California Civil Code § 9550 et seq., to ensure payment to authorized claimants. This Bond is binding on the respective successors, assigns, owners, heirs, or executors of Surety and Contractor. 2. Surety’s Obligation. If Contractor or any of its Subcontractors fails to pay a person authorized in California Civil Code § 9100 to assert a claim against a payment bond, any amounts due under the Unemployment Insurance Code with respect to work or labor performed under the Contract, or any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of Contractor and its Subcontractors under California Unemployment Insurance Code § 13020 with respect to the work and labor, then Surety will pay the obligation. 3. Beneficiaries. This Bond inures to the benefit of any of the persons named in California Civil Code § 9100, so as to give a right of action to those persons or their assigns in any suit brought upon this Bond. Contractor must promptly provide a copy of this Bond upon request by any person with legal rights under this Bond. 4. Duration. If Contractor promptly makes payment of all sums for all labor, materials, and equipment furnished for use in the performance of the Work required by the Contract, in conformance with the time requirements set forth in the Contract and as required by California law, Surety’s obligations under this Bond will be null and void. Otherwise, Surety’s obligations will remain in full force and effect. 5. Waivers. Surety waives any requirement to be notified of alterations to the Contract or extensions of time for performance of the Work under the Contract. Surety waives the provisions of Civil Code §§ 2819 and 2845. City waives the requirement of a new bond for any supplemental contract under Civil Code § 9550. Any notice to Surety may be given in the manner specified in the Contract and delivered or transmitted to Surety as follows: Attn: _____________________________________________________ Address: __________________________________________________ City/State/Zip: ______________________________________________ Phone: ___________________________________________________ Email: ____________________________________________________ 6. Law and Venue. This Bond will be governed by California law, and venue for any dispute pursuant to this Bond will be in the <__________________> County Superior Court, and no other place. Surety will be responsible for City’s attorneys’ fees and costs in any action to enforce the provisions of this Bond. [Signatures are on the following page.] <Project Title> 2021 Form PAYMENT BOND <Project Number> Page 31 7. Effective Date; Execution. This Bond is entered into and is effective on __________, 20__. SURETY: ___________________________________ Business Name s/__________________________________ ______________________________ Date ___________________________________ Name, Title (Attach Acknowledgment with Notary Seal and Power of Attorney) CONTRACTOR: ___________________________________ Business Name s/__________________________________ ______________________________ Date ___________________________________ Name, Title END OF PAYMENT BOND <Project Title> 2021 Form PERFORMANCE BOND <Project Number> Page 32 Performance Bond <______________________________> (“City”) and __________________________ (“Contractor”) have entered into a contract for work on the <_______________________________________________> Project (“Project”). The Contract is incorporated by reference into this Performance Bond (“Bond”). 1. General. Under this Bond, Contractor as Principal and ___________________________, its surety (“Surety”), are bound to City as obligee for an amount not less than $__________________ to ensure Contractor’s faithful performance of its obligations under the Contract. This Bond is binding on the respective successors, assigns, owners, heirs, or executors of Surety and Contractor. 2. Surety’s Obligations. Surety’s obligations are co-extensive with Contractor’s obligations under the Contract. If Contractor fully performs its obligations under the Contract, including its warranty obligations under the Contract, Surety’s obligations under this Bond will become null and void. Otherwise, Surety’s obligations will remain in full force and effect. 3. Waiver. Surety waives any requirement to be notified of and further consents to any alterations to the Contract made under the applicable provisions of the Contract Documents, including changes to the scope of Work or extensions of time for performance of Work under the Contract. Surety waives the provisions of Civil Code §§ 2819 and 2845. 4. Application of Contract Balance. Upon making a demand on this Bond for completion of the Work prior to acceptance of the Project, City will make the Contract Balance available to Surety for completion of the Work under the Contract. For purposes of this provision, the Contract Balance is defined as the total amount payable by City to Contractor as the Contract Price minus amounts already paid to Contractor, and minus any liquidated damages, credits, or backcharges to which City is entitled under the terms of the Contract. 5. Contractor Default. Upon written notification from City of Contractor’s termination for default under Article 13 of the Contract General Conditions, time being of the essence, Surety must act within the time specified in Article 13 to remedy the default through one of the following courses of action: 5.1 Arrange for completion of the Work under the Contract by Contractor, with City’s consent, but only if Contractor is in default solely due to its financial inability to complete the Work; 5.2 Arrange for completion of the Work under the Contract by a qualified contractor acceptable to City, and secured by performance and payment bonds issued by an admitted surety as required by the Contract Documents, at Surety’s expense; or 5.3 Waive its right to complete the Work under the Contract and reimburse City the amount of City’s costs to have the remaining Work completed. 6. Surety Default. If Surety defaults on its obligations under the Bond, City will be entitled to recover all costs it incurs due to Surety’s default, including legal, design professional, or delay costs. 7. Notice. Any notice to Surety may be given in the manner specified in the Contract and sent to Surety as follows: Attn: _____________________________________________________ <Project Title> 2021 Form PERFORMANCE BOND <Project Number> Page 33 Address: __________________________________________________ City/State/Zip: ______________________________________________ Phone: ___________________________________________________ Fax: ______________________________________________________ Email: ____________________________________________________ 8. Law and Venue. This Bond will be governed by California law, and venue for any dispute pursuant to this Bond will be in the <___________> County Superior Court, and no other place. Surety will be responsible for City’s attorneys’ fees and costs in any action to enforce the provisions of this Bond. 9. Effective Date; Execution. This Bond is entered into and effective on ____________________, 20___. SURETY: ___________________________________ Business Name s/__________________________________ ______________________________ Date ___________________________________ Name, Title (Attach Acknowledgment with Notary Seal and Power of Attorney) CONTRACTOR: ___________________________________ Business Name s/__________________________________ ______________________________ Date ___________________________________ Name, Title END OF PERFORMANCE BOND